42.1301
General
FAR 42.1301 establishes the framework for handling Government-ordered suspensions, stop-work orders, and claims for unordered delays, ensuring both parties have clear procedures and protections.
Overview
FAR 42.1301 outlines the general framework for handling situations where the Government may need to suspend work or issue a stop-work order during contract performance. It introduces the subpart's purpose: to provide standard contract clauses that address these scenarios and to establish procedures for resolving contractor claims related to unordered, Government-caused delays not otherwise covered by the contract. This section sets the stage for the detailed requirements and processes found in the subsequent clauses of Subpart 42.13.
Key Rules
- Suspension of Work/Stop-Work Orders
- The Government may order a suspension or stoppage of work during contract performance under certain circumstances.
- Settlement of Claims for Delays
- Provides for a clause to address contractor claims arising from unordered Government-caused delays that are not otherwise specified in the contract.
Responsibilities
- Contracting Officers: Must include appropriate clauses in contracts and manage suspension or stop-work situations in accordance with regulations.
- Contractors: Must comply with suspension or stop-work orders and follow procedures for submitting claims related to Government-caused delays.
- Agencies: Ensure oversight and proper application of clauses and claim settlement processes.
Practical Implications
- This section ensures both parties understand their rights and obligations when work is suspended or stopped by the Government.
- It helps prevent disputes by providing clear procedures and contract language for handling delays and claims.
- Contractors should be aware of their rights to claim compensation for certain Government-caused delays and the need to follow prescribed processes.