52.222-1
Notice to the Government of Labor Disputes
Contractors must immediately notify the Contracting Officer of any labor disputes that could delay contract performance, providing all relevant information.
Overview
FAR 52.222-1 requires contractors to promptly notify the Government if they become aware of any actual or potential labor disputes that could delay contract performance. The clause mandates immediate communication with the Contracting Officer, including all relevant details about the dispute. This provision is designed to ensure the Government is informed of any labor issues that may impact contract schedules, allowing for proactive management and mitigation of potential delays.
Key Rules
- Immediate Notification Requirement
- Contractors must notify the Contracting Officer as soon as they know of any actual or potential labor dispute that could delay contract performance.
- Relevant Information Disclosure
- The notice must include all pertinent information regarding the labor dispute, enabling the Government to assess the situation and respond appropriately.
Responsibilities
- Contracting Officers: Receive and act upon notifications of labor disputes; may coordinate with agency leadership or take steps to mitigate impacts.
- Contractors: Must monitor for labor disputes and provide immediate, comprehensive notice to the Contracting Officer if such issues arise.
- Agencies: Oversee contract performance and ensure timely communication channels are maintained.
Practical Implications
- This clause exists to minimize the risk of unexpected contract delays due to labor disputes.
- Contractors must have internal processes to detect and report labor issues quickly.
- Failure to notify can result in noncompliance, potential contract remedies, or reputational harm. Timely communication helps all parties manage risks and maintain contract schedules.