Psst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveCLEATUS Webinar: AI for Government Contracting — Free Webinar — Wednesday, November 11 at 2:00 PM ET

Register Free →

Search

Top

Back to Contracts

Commercial Roofing

Active

State & Local

Response Deadline12/08/2026, 07:30:00 PM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

This commercial roofing subcontract involves the installation of complete, weather-tight roofing systems for prime contractors working on Kentucky Court of Justice facility projects. The work is managed under the Judicial Department of Kentucky and will be performed in Frankfort. The solicitation was posted on November 3, 2026, with a response deadline of December 8, 2026. This opportunity falls under NAICS code 238160 and is accessible through the Kentucky state procurement portal.

General Info

Commercial roofing installation for Kentucky Court of Justice projects in Frankfort, Kentucky.

Agency

Kentucky → Judicial Department

NAICS

238160 - Roofing Contractors

Place of Performance

Frankfort, KY, USA

Set-Aside

NONE

Documents

This scope was carved out of RFB-025-2700000165-3.

The full solicitation package (7 documents), including the RFP, is on the prime solicitation, not on this scope.

View the prime solicitation

RFB-025-2700000165-3 | RFB for the Court of Appeals Building Construction project

AI Contract Breakdown

Uniform Contract Format

No documents to break down

The breakdown needs solicitation documents. None were found from this contract's source.

Timeline

PostedNov 3

subcontract

Response DeadlineDec 8

Submission deadline

Response Deadline

12/08/2026, 07:30:00 PM UTCin about 1 month

Ready to pursue this opportunity?

Get full access to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more

AgencyKentucky → Judicial Department

ContactsNo contacts available

OfficeN/A

Organization / AgencyKentucky → Judicial Department

Office AddressN/A

ContactsNo contact information available

Full Description

Show more

Installs roofing systems for prime contractors on Kentucky Court of Justice facility projects. Delivers a completed, weather-tight roof system.

Similar Contracts

Same NAICS industry code

47971 CONSTRUCTION

Solicitation # 47971

Solicitation 47971, issued by the New York State Office of General Services Design and Construction Group, involves comprehensive construction, HVAC, and electrical work to replace the roof and associated mechanical systems at the Troop F Headquarters located at 55 Crystal Run Road in Middletown, New York. The scope of work includes partial roof removals and installations, the removal and salvage of rooftop units and associated accessories, and the removal of steel dunnage. Additionally, the project requires the installation of facility natural-gas piping, including pipes, fittings, and manual shutoff valves, with specific requirements for gray semigloss exterior alkyd enamel coatings and identification compliance per Section 230553. The project is governed by a detailed set of technical drawings and three addenda issued in October 2026. These modifications updated roof and overflow drain specifications, replaced natural-gas piping specifications under Section 231123, and changed expansion joint coping material to 20oz continuous copper. All work must adhere to local safety and zone differential regulations, manufacturer recommendations, and specific fastener standards, requiring minimum grade M6 for penetrating heavy-duty fasteners. The solicitation was posted on October 30, 2026, with a response deadline of November 18, 2026, and includes a performance requirement to install specific equipment by July 1st.

NYS OGS Design & Construction - Construction Contractors

POSTED

about 4 hours ago

DEADLINE

Solicitation # 47971

Solicitation 47971, issued by the NYS OGS Design and Construction Group, involves comprehensive construction, HVAC, and electrical work to replace the roof and associated mechanical systems at the Troop F Headquarters located at 55 Crystal Run Road in Middletown, New York. The scope of work includes the installation of facility natural-gas piping, the careful disconnection and offsite storage of roof top units for later reinstallation, and the management of piping specialties and manual gas shutoff valves. Contractors are required to provide all necessary tools and materials and must maintain a waterfit condition across all roof areas throughout the project duration. Technical specifications emphasize strict adherence to NFPA 54 for the testing, inspection, and purging of natural gas, with requirements for cast iron valve bodies to comply with ASTM A126 Class B and MSS SP-78. Recent addenda have modified the project drawings to update roof and overflow drain specifications, replace expansion joint coping material with 20oz continuous copper, and refine the removal and salvage processes for exhaust fans and RTU curbs. All work must comply with local safety and zone differential regulations, and the contractor is responsible for obtaining any additional occupancy permits at their own expense.

NYS OGS Design & Construction - Construction Contractors

POSTED

about 4 hours ago

DEADLINE

Building Fabric & Roofing MaintenanceThis subcontract for Building Fabric and Roofing Maintenance involves providing essential maintenance and repair services for the building envelope and external shell of National Grid UK Limited property projects. The scope of work includes conducting building fabric inspections, performing roofing and drainage maintenance, clearing gutters, and executing general building repairs to ensure all structures remain weather-tight and structurally sound. Operating under NAICS code 238160, the contractor will work as a subcontractor to prime contractors to deliver high-quality fabric repairs and envelope integrity. The contract is associated with National Grid UK Limited and was posted on November 4, 2026.

National Grid Uk Limited

POSTED

about 5 hours ago

DEADLINE

Roof Sheet Metal and FlashingThis subcontract for Roof Sheet Metal and Flashing involves the supply and installation of roof flashing and sheet metal trim for prime contractors working on Maryland Department of General Services facility projects. The scope of work includes the installation of new flashing, trim, counterflashings, and penetration flashings in strict accordance with Specifications 07 60 00 and 07 62 00. A critical requirement of the project is that all work must be fully integrated into a 20-year No Dollar Limit warranty to ensure long-term durability and performance. The project falls under NAICS code 238160 and is managed through the state of Maryland. Interested parties must submit their responses by the deadline of November 30, 2026. The ultimate goal of the contract is the delivery of a fully completed and compliant flashing and trim system.

POSTED

about 9 hours ago

DEADLINE

Roof Insulation and Tapered SystemsThis subcontract involves the supply and installation of roof insulation and tapered systems for prime contractors working on Maryland Department of General Services facility projects. The scope of work includes the installation of insulation crickets, fillers, and cans to establish a positive slope toward drains featuring 8-foot by 8-foot sumps. The technical requirements specify the use of 1-ply modified bitumen membrane vapor retarders, a minimum average aged R-Value of 30, and strict compliance with ASTM E 84 fire-test standards. The opportunity is categorized under NAICS code 238160 and was posted on November 4, 2026, with a response deadline of November 30, 2026. The selected provider will be responsible for the full delivery of the installed insulation system across the designated project sites in Maryland.

POSTED

about 9 hours ago

DEADLINE

Asphalt Shingle Roofing InstallationThis subcontract for Asphalt Shingle Roofing Installation involves the installation of architectural limited lifetime warranty shingle roofing systems for prime contractors working on Maryland Department of General Services facility projects. The scope of work includes installing shingles that match existing materials, applying vented insulated sheathing according to manufacturer specifications, and installing new ridge vents and soffits to deliver a fully warranted roof. The contractor is required to provide a 20-year No Dollar Limit warranty along with a 2-year guarantee on workmanship. This opportunity falls under NAICS code 238160, with a response deadline set for November 30, 2026.

POSTED

about 9 hours ago

DEADLINE

SG-000-270-003 Roof Replacement, Repair and Gutter Replacement Red Brick Cottages 1-4

Solicitation # SG-000-270-003

Solicitation SG-000-270-003 is for the roof replacement, repair, and gutter replacement of Red Brick Buildings 1 through 4 at Spring Grove Hospital in Catonsville, Maryland. The scope of work includes the installation of a new roof system and underlayment using Asphalt Architectural Limited Lifetime Warranty Shingles, with a required minimum average aged R-Value of 30. Technical requirements encompass selective structure demolition, gypsum deck restoration, and steel decking, with all materials subject to Architect approval and adherence to ASTM, ADA, and Maryland Accessibility Code standards. Eligibility is strictly limited to Master Contractors in the Central Region who have been awarded a contract under the Indefinite Quantity Contract IQC DGS-25-307-IQC. The award will be granted to the responsible bidder submitting the lowest responsive total bid. A critical requirement for responsiveness is the submission of properly completed MBE documentation, specifically Attachment D-1A, to meet a 20 percent MBE procurement goal. Bids must be submitted via the eMMA portal by November 30, 2026. Contract administration follows the General Conditions for Construction Contracts (July 1, 2022), with payments processed monthly and net 30 days after receipt of a proper invoice. Contractors must remit a 1 percent electronic transaction fee to the State. Performance begins upon receipt of a written Notice to Proceed, and the contractor is responsible for maintaining an adequate inspection system and adhering to prevailing wage laws, which prohibit the employment of helpers or trainees.

POSTED

about 9 hours ago

DEADLINE

RoofingThis subcontracting opportunity with Madera County, California, involves the installation and repair of roofing systems for public works projects. The selected contractor will be responsible for delivering weather-tight roof installations, performing leak repairs, and providing waterproofing services while working under prime contractors. Eligible bidders must hold a California Contractor License Class C-39. The solicitation was posted on November 4, 2026, and requires a response by March 4, 2027. All work will be performed within Madera, California.

Madera County, California

POSTED

about 9 hours ago

DEADLINE

Modified Bitumen Roofing InstallationThis subcontract opportunity involves the installation of new modified bitumen roofing systems at the John Cochran VA Medical Center for the Department of Veterans Affairs. The scope of work requires the removal and demolition of existing roofing across 12 designated areas totaling 44,000 square feet, followed by the installation of membranes that adhere to VA TIL standards and commercial specifications. The selected contractor is responsible for the complete process, including final inspection and clean-up, to deliver a fully installed and tested roofing system. The project is designated as a Service-Disabled Veteran-Owned Small Business set-aside under NAICS code 238160. Interested parties must submit their responses by November 13, 2026, at 8:00 PM. The contract is managed by the Department of Veterans Affairs Network Contract Office 15.

255-NETWORK Contract Office 15 (36C255)

POSTED

about 10 hours ago

DEADLINE

Piping Insulation PatchingThis subcontract opportunity, titled Piping Insulation Patching, involves the repair of damaged fiberglass insulation for prime contractors working on Department of the Interior facility projects in Washington, DC. The scope of work requires patching approximately 50 linear feet of exposed fiberglass insulation on garage piping using specialized insulation adhesives and tape to ensure all piping is properly repaired and sealed. The project is designated as a Total Small Business Set Aside under NAICS code 238160 and is managed by the Ibc Acq Svcs Directorate. All work must be performed in strict adherence to OSHA compliance standards. The solicitation was posted on November 4, 2026, with a response deadline of November 19, 2026.

Ibc Acq Svcs Directorate (00004)

POSTED

about 10 hours ago

DEADLINE

Roof Assessment and Repair at the Albuquerque Area Indian Health Service Healthcare Facilities

Solicitation # 75H70727Q00004

Albuquerque Area Indian Health Svc

POSTED

about 10 hours ago

DEADLINE

in about 1 month

(RFP) for Roofing Job Order Contracts (JOC 2710 and 2711) - Class C39 License

Solicitation # 2027-RFP-00200

County of San Mateo

POSTED

about 10 hours ago

DEADLINE

in about 1 month

More opportunities from Kentucky → Judicial Department

Same awarding agency

HVAC InstallationThis subcontract opportunity involves the installation of heating, ventilation, and air conditioning systems for prime contractors working on Kentucky Court of Justice facility projects. The primary objective is to deliver a fully operational climate control system within the designated facilities located in Frankfort. Managed by the Kentucky Judicial Department under NAICS code 238220, the solicitation was posted on November 3, 2026. Interested parties must submit their responses by the deadline of December 8, 2026.

Plumbing, Heating, and Air-Conditioning Contractors

POSTED

DEADLINE

in about 1 month

Interior Finishes (Drywall, Painting, Flooring)This subcontract opportunity is issued by the Kentucky Judicial Department for interior finishing work on Court of Justice facility projects located in Frankfort. The scope of work involves providing comprehensive interior architectural finishes, specifically focusing on drywall installation, painting, and flooring services to support prime contractors. The solicitation was posted on November 3, 2026, with a response deadline set for December 8, 2026. Classified under NAICS code 238310, this project requires specialized expertise in interior finishing to ensure the successful delivery of completed architectural spaces within the judicial facilities.

Drywall and Insulation Contractors

POSTED

DEADLINE

in about 1 month

Structural Steel Fabrication and ErectionThis subcontract agreement involves the fabrication and erection of structural steel for the Kentucky Judicial Department. The selected contractor will be responsible for supplying and installing the structural steel frame for prime contractors working on Kentucky Court of Justice facility projects located in Frankfort. The solicitation was posted on November 3, 2026, with a response deadline of December 8, 2026. This project falls under NAICS code 238120 and requires the delivery of a fully completed structural steel frame to meet the specifications of the facility projects.

Structural Steel and Precast Concrete Contractors

POSTED

DEADLINE

in about 1 month

Concrete WorkThis subcontract agreement involves the provision of concrete placement and structural concrete work for the Kentucky Judicial Department. The scope of work focuses on delivering completed concrete foundations and structural elements for Kentucky Court of Justice facility projects located in Frankfort. The opportunity is categorized under NAICS code 238110. Interested parties must submit their responses by the deadline of December 8, 2026, following the posting date of November 3, 2026.

Poured Concrete Foundation and Structure Contractors

POSTED

DEADLINE

in about 1 month

Construction Management / Unit Price CoordinationThis subcontract for Construction Management and Unit Price Coordination supports the Kentucky Judicial Department on facility projects located in Frankfort. The primary scope of work involves providing administrative and technical support to prime contractors, specifically focusing on the management of unit price tracking and general requirements. Adhering to Section 01 22 00 and Section 01 43 39, the contractor is responsible for delivering accurate reporting and project coordination logs utilizing AIA Document standards G701 and G702. The opportunity is categorized under NAICS code 236220. Interested parties must submit their responses by the deadline of December 8, 2026. All coordination and reporting efforts are designed to ensure precise financial tracking and operational alignment throughout the duration of the construction projects.

Commercial and Institutional Building Construction

POSTED

DEADLINE

in about 1 month

Electronic Safety and Security CablingThis subcontract agreement involves the supply and installation of specialized low-voltage cabling for electronic safety and security systems at Kentucky Court of Justice facility projects in Frankfort. The selected contractor will work under prime contractors to install conductors and cables in accordance with Section 28 05 13 and the revised specifications outlined in Addendum 1, ensuring all work meets established electronic safety and security standards. Managed by the Kentucky Judicial Department under NAICS code 238210, the project focuses on delivering a complete cable infrastructure for critical security systems. The solicitation was posted on November 3, 2026, with a response deadline set for December 8, 2026.

Electrical Contractors and Other Wiring Installation Contractors

POSTED

DEADLINE

in about 1 month

Facility Water Distribution PipingThis subcontract for Facility Water Distribution Piping involves the installation of water distribution systems for prime contractors working on Kentucky Court of Justice facility projects in Frankfort. The selected contractor is responsible for performing all installations in accordance with Section 22 11 13, adhering to local plumbing codes, and following all specifications set by the Frankfort Plant Board. The scope of work requires the contractor to coordinate all necessary connections with the Frankfort Plant Board to deliver a fully installed and tested facility water distribution system. This opportunity is managed by the Kentucky Judicial Department under NAICS code 238220, with a response deadline set for December 8, 2026.

Plumbing, Heating, and Air-Conditioning Contractors

POSTED

DEADLINE

in about 1 month

Communications Infrastructure (Div 27)This subcontract opportunity is for the installation of communications and data infrastructure in accordance with Division 27 standards for Kentucky Court of Justice facility projects. The selected provider will work under prime contractors to deliver fully completed network cabling and communication systems. The work is to be performed in Frankfort, Kentucky, under the direction of the Kentucky Judicial Department. The solicitation was posted on November 3, 2026, with a response deadline of December 8, 2026. This project falls under NAICS code 238210, focusing on specialized electrical installation and infrastructure. Interested parties can find further details through the Kentucky state vendor portal.

Electrical Contractors and Other Wiring Installation Contractors

POSTED

DEADLINE

in about 1 month

Fire Suppression SystemsThis subcontract opportunity involves the installation of fire suppression and sprinkler systems for prime contractors working on Kentucky Court of Justice facility projects. The primary objective is to deliver a fully certified and operational fire protection system within the designated facilities located in Frankfort. The project is managed by the Kentucky Judicial Department under NAICS code 238220. Interested parties must submit their responses by the deadline of December 8, 2026, following the posting date of November 3, 2026.

Plumbing, Heating, and Air-Conditioning Contractors

POSTED

DEADLINE

in about 1 month

Electrical Systems InstallationThis subcontract agreement involves the installation of electrical systems and power distribution for the Kentucky Judicial Department. The selected contractor will work under prime contractors to deliver complete electrical infrastructure and wiring for Kentucky Court of Justice facility projects located in Frankfort. The opportunity was posted on November 3, 2026, with a response deadline of December 8, 2026. Classified under NAICS code 238210, the project focuses on specialized electrical contracting services to ensure the operational readiness of judicial facilities.

Electrical Contractors and Other Wiring Installation Contractors

POSTED

DEADLINE

in about 1 month

Earth Moving and Site PreparationThis subcontract for the Kentucky Judicial Department involves earth moving, excavation, and site preparation for Court of Justice facility projects located in Frankfort. The selected contractor is responsible for executing earth moving according to Section 31 20 00, performing comprehensive site clearing, and utilizing heavy excavation and compaction equipment to ensure soil under structures and building slabs reaches a minimum compaction of 98 percent as specified in Addendum 1. The primary objective of the contract is to deliver a fully graded and compacted site that is ready for the placement of foundations and slabs. Interested parties must submit their responses by December 8, 2026, for this project categorized under NAICS code 238910.

Site Preparation Contractors

POSTED

DEADLINE

in about 1 month

RFB-025-2700000165-3 | RFB for the Court of Appeals Building Construction project

Solicitation # RFB-025-2700000165-3

The Commonwealth of Kentucky Administrative Office of the Courts is soliciting bids for a general contractor to manage the construction of a new administrative building for the Kentucky Court of Appeals located at 1004 Vandalay Drive in Frankfort, Kentucky. The comprehensive scope of work includes all labor, materials, and services across multiple trades, including earthwork, concrete, HVAC, electrical, plumbing, fire suppression, and electronic safety and security systems. The project is expected to reach substantial completion within 730 calendar days from the date of commencement, with final completion occurring 30 days thereafter. Bids must be submitted in a sealed envelope to the Division of Procurement by December 8, 2026, at 2:30 p.m. Eastern Time. The contract will be awarded to the lowest responsive and responsible bidder with the shortest delivery time, with evaluation points weighted at 90 points for cost and 10 points for daily general conditions or contract time. Selected contractors must provide performance and payment bonds equivalent to 100 percent of the contract sum and maintain certification of authority to conduct business in Kentucky. Payment for undisputed invoices will be made within 30 working days, and the agency is exempt from Federal Excise and Kentucky Sales or Use taxes.

Commercial and Institutional Building Construction

POSTED

DEADLINE

in about 1 month

Earlier notices in this NAICS code

Posted before this notice, open and closed

Thermal and Moisture Protection

POSTED

DEADLINE

City of Raleigh

POSTED

DEADLINE

Commercial Roofing Installation

POSTED

DEADLINE

Custom Metal Flashing and Coping

POSTED

DEADLINE

Roofing Installation Services

POSTED

DEADLINE

Replace Roofs – Administration and Health Services Buildings

Solicitation # 2140483

POSTED

DEADLINE

Replace Roofs – Various Buildings – SUNY New Paltz

Solicitation # 2140482

POSTED

DEADLINE

Specialty Trade Contractor - Roofing

Baldwin Park Unified School District

POSTED

DEADLINE

Roofing Specialty Trade (Class C-39)

PASO ROBLES JOINT USD

POSTED

DEADLINE

Roofing Specialty Trade

Solana Beach School District

POSTED

DEADLINE

Roofing & Waterproofing

SWEETWATER UNION HIGH SCHOOL DISTRICT

POSTED

DEADLINE

Thermal, Moisture, and Glazing

POSTED

DEADLINE

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Join 750+ contractors already using CLEATUS