Psst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveCLEATUS Webinar: AI for Government Contracting — Free Webinar — Wednesday, August 5 at 2:00 PM EDT

Register Free →

Get CLEATUSFree Trial

Get CLEATUSFree Trial

Search

Top

Back to Contracts

Construction Project Management Support

Active

State & Local

Response Deadline08/11/2026, 12:00:00 AM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

The contract supports the construction project management functions for the Department of General Services Real Estate Services Division, specifically focusing on Good Manufacturing Practices development, master scheduling, cost reporting, and on-site oversight using Critical Path Methodology. The work is tied to capital projects under the Project Management and Development Branch and requires expertise in construction scheduling and financial tracking to ensure timely and budget-compliant delivery. Performance is mandated at the Sacramento office with a zip code of 95814, and the subcontract is open for response until August 11, 2026, under NAICS code 541370 which corresponds to architectural, engineering, and related services. The solicitation was posted on July 30, 2026, and is intended to secure qualified subcontractors to provide technical project management support in alignment with state infrastructure goals.

General Info

Contract for construction project management support in Sacramento under NAICS 541370 until August 11, 2026.

Agency

California → Department of General Services (DGS), Real Estate Services Division (RESD), Project Management and Development Branch (PMDB)View Agency

NAICS

541370 - Surveying and Mapping (except Geophysical) ServicesView NAICS

Place of Performance

Sacramento, CA, 95814, US

Set-Aside

NONE

Documents

(0)

No documents available

AI Contract Breakdown

Uniform Contract Format

No contract breakdown available.

Cannot generate Contract Breakdown because no documents were found from this contract's source.

Timeline

PostedJul 30

subcontract

Response DeadlineAug 11

Submission deadline

Response Deadline

08/11/2026, 12:00:00 AM UTCin 9 days

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more

AgencyCalifornia → Department of General Services (DGS), Real Estate Services Division (RESD), Project Management and Development Branch (PMDB)

ContactsNo contacts available

OfficeN/A

Organization / Agency

California → Department of General Services (DGS), Real Estate Services Division (RESD), Project Management and Development Branch (PMDB)

View Agency Profile

Office AddressN/A

ContactsNo contact information available

Full Description

Show more

Support GMP development, master scheduling, cost reporting, and on-site oversight using CPM methodologies.

Similar Contracts

Same NAICS industry code

Surveying and Site Layout ServicesThis contract is for surveying and site layout services under a Total Small Business Set-Aside, reserved exclusively for small businesses as defined by the SBA, with the NAICS code 541370 corresponding to surveying and mapping services. The work involves comprehensive topographic surveying, verification of property boundaries, and exact layout of structures and infrastructure elements to support precise construction and development activities. The solicitation was posted on August 1, 2026, and responses are due by August 24, 2026, with the ordering activity being the ASC Commodities Division under the Department of Defense. The services will be performed at an unspecified location, and while no point of contact or detailed address is provided, the opportunity is publicly accessible through the DIBBS platform. The contract is structured as a subcontract, indicating it may be part of a larger project requiring specialized geospatial and site verification expertise.

ASC COMMODITIES DIVISION

POSTED

about 5 hours ago

DEADLINE

Survey and Mapping Services IDIQThe Port of Seattle is seeking qualified firms or teams to provide Survey and Mapping Services through an Indefinite-Delivery, Indefinite-Quantity (IDIQ) contract, with the solicitation posted on July 31, 2026. All survey work must adhere to strict geographic and vertical datum standards: at Airport facilities, surveys must use the Seattle-Tacoma International Airport Grid System or NAD83, while Seaport facilities require NAD83 or Seattle Tidelands as directed. Vertical control is governed by NGVD 29, STIA Vertical Datum, MLLW, or NAVD88, with any deviations requiring written approval from the Port Manager of Survey and Mapping. All land surveying activities must comply with现行 Washington Administrative Code and Revised Code of Washington regulations. Services will be performed under the direct supervision of the Port Manager of Survey and Mapping Services or their designated representative, encompassing both field and office-based support. The primary point of contact for inquiries is Hala Rabbo, with Ann Davidson listed as the Project Manager, and the contract is classified under NAICS code 541370 for Surveying and Mapping Services.

Construction Management

POSTED

about 5 hours ago

DEADLINE

GPS Mapping and Treatment Record DocumentationThe contract titled GPS Mapping and Treatment Record Documentation requires the creation and ongoing maintenance of precise GPS-mapped records documenting treated areas to ensure strict adherence to the Statement of Work boundaries and established buffer requirements. These records must accurately reflect the spatial extent of all treatment activities and serve as verifiable evidence of compliance with environmental and operational restrictions. The contractor is responsible for generating digital maps and associated logs that capture treatment locations, timing, and scope, and for submitting these materials in a consistent, standardized format on a regular basis to support oversight and audit readiness. This subcontract, issued by the Florida Fish and Wildlife Conservation Commission under NAICS code 541370, is targeted toward vendors capable of delivering geospatial data services with high accuracy and reliability. All work must be performed in alignment with the commission’s regulatory and ecological objectives, and deadlines for response are set for September 10, 2026. While the specific location of performance is not detailed, the scope implies field operations across Florida, with deliverables focused on digital documentation rather than physical infrastructure. The contractor must ensure data integrity, timeliness, and compatibility with the agency’s systems to fulfill compliance obligations throughout the term of the agreement.

Florida Fish and Wildlife Conservation Commission

POSTED

DEADLINE

in about 1 month

Preliminary Engineering & Site Investigation ServicesBroward County is seeking qualified contractors to perform preliminary engineering and site investigation services in support of the conceptual design for a biosolids drying facility. The work encompasses comprehensive site investigations, geotechnical assessments, and environmental due diligence to evaluate site conditions and identify potential constraints or risks that may impact facility design and construction. These services are critical to ensuring the project's technical feasibility, regulatory compliance, and long-term operational success. The contract is classified as a subcontract under NAICS code 541370, and responses must be submitted by August 7, 2026, with the opportunity posted on July 31, 2026. All work is expected to be performed in Florida, though specific location details are not provided in the posting.

POSTED

DEADLINE

Small Business and MBE Participation SupportThe contract titled Small Business and MBE Participation Support is designed to encourage participation from Minority Business Enterprises and small contractors under the Mississippi Department of Finance and Administration’s affirmative action policy. It is classified as a subcontract opportunity tied to NAICS code 541370, which corresponds to other scientific and technical consulting services, and is administered by MPTAP through the state of Mississippi. The solicitation opens on July 31, 2026, with a response deadline of August 27, 2026, providing interested parties with a four-week window to submit proposals. While no specific place of performance or point of contact is listed, the opportunity is structured to promote equitable access and inclusion for underrepresented small businesses within state-funded initiatives. Participation is encouraged as part of broader efforts to enhance economic diversity and support local enterprise development.

POSTED

DEADLINE

Surveying and Layout ServicesThe contract calls for comprehensive site surveying, staking, and alignment verification services essential to the construction of a bridge and its approach structures. Work under this subcontract must ensure precise geometric layout and positional accuracy throughout the project lifecycle, adhering to engineering specifications and regulatory standards for infrastructure development. The services are critical to establishing reference points, controlling grades, and verifying spatial relationships to prevent costly errors during construction. This subcontract is issued under NAICS code 541370, which classifies it as geographic information system and other surveying and mapping services. The solicitation was posted on July 31, 2026, with a response deadline of August 27, 2026, giving potential subcontractors approximately four weeks to prepare and submit proposals. The contracting agency is MPTAP under the Mississippi Department of Transportation, and the work is to be performed in Mississippi, though exact location details are not specified. This opportunity is open to qualified firms with expertise in civil surveying for transportation projects, with no set-aside designation indicated.

POSTED

DEADLINE

Surveying and Layout ServicesThe contract seeks qualified providers to deliver comprehensive surveying and layout services essential for the precise execution of grading and infrastructure placement. Key deliverables include construction layout, boundary verification, elevation control, and as-built surveys to ensure all earthwork and utility installations align with design specifications and regulatory requirements. These services are critical to maintaining accuracy throughout the project lifecycle and minimizing costly rework or alignment errors during construction. The solicitation, categorized under NAICS code 541370 for architectural and engineering services, is structured as a subcontract and has a response deadline of September 8, 2026. The work is associated with the Public Works agency in Virginia, with no specified place of performance listed. Interested parties must submit proposals by the deadline, and while the solicitation number and point of contact details are not provided, the official portal for submission and further information is accessible via the given UI link. The contract does not specify a set-aside type, indicating it is open to all eligible contractors without preference or restriction based on size or ownership classification.

POSTED

DEADLINE

in about 1 month

Right-of-Way (ROW) MappingThe contract titled Right-of-Way (ROW) Mapping requires the preparation of detailed right-of-way maps, plats, and legal documentation to support land acquisition and easement activities for transportation infrastructure projects. The work involves precise surveying, boundary delineation, and documentation required to secure legal access for public transportation initiatives, ensuring compliance with state and federal standards. All deliverables must be accurate, legally defensible, and aligned with engineering and planning requirements for ongoing and future transit development. The opportunity is posted as a subcontract under NAICS code 541370, indicating it falls within the category of surveying and mapping services. The solicitation is open through August 18, 2026, with a submission deadline of 3:30 PM Eastern Time, and it is being managed by Wilco through its Texas organizational unit. While the place of performance and point of contact details are not specified, the nature of the work suggests tasks will be conducted across various transportation project sites within Texas. The contract does not include set-aside provisions, making it open to all qualified subcontractors seeking to provide specialized ROW documentation services.

POSTED

DEADLINE

Surveying ServicesWilco is seeking qualified firms to provide comprehensive land and topographic surveying services for transportation and infrastructure projects across Texas. The scope of work includes boundary surveys, right-of-way delineation, and precise construction layout surveys to support project planning and execution. Respondents must be prepared to deliver accurate, timely, and compliant survey data using recognized industry standards and technologies. The solicitation is structured as a subcontract opportunity with a North American Industry Classification System code of 541370, indicating it falls under surveying and mapping services. Proposals are due by August 18, 2026, at 3:30 PM, with the opportunity posted on July 31, 2026. There is no set-aside designation, and the performance location is unspecified at the state level, but services are expected to be delivered within Texas. Interested parties should access the full solicitation through the provided BonfireHub link.

POSTED

DEADLINE

Testing and Inspection ServicesThe contract requires the provision of certified field testing and inspections to ensure compliance with ASTM standards and IBC Chapter 17, with specific focus on sound transmission testing and verification of steel framing systems. All services must be performed by qualified professionals using approved methodologies to validate structural and acoustic performance in accordance with established codes and industry specifications. The work is intended to support construction quality assurance and regulatory adherence for projects under the jurisdiction of the City of St. Joseph, Missouri. The solicitation is classified as a subcontract under NAICS code 541370 and is open for responses until September 1, 2026. The contract is not subject to any set-aside designation, and performance is expected to occur within the City of St. Joseph, though specific location details are not provided. Interested parties must submit proposals through the agency’s online portal prior to the deadline, and no point of contact information is listed in the solicitation materials.

City Of St. Joseph

POSTED

DEADLINE

in about 1 month

Tree and Shrub CareHarris County is seeking a subcontractor to provide comprehensive tree and shrub maintenance services, including pruning, trimming, disease and pest control, and the removal of dead or hazardous limbs. The contract is open for bids with a submission deadline of August 24, 2026, and was posted on July 31, 2026, under the NAICS code 541370 for landscaping services. All work must be performed within Harris County, Texas, though specific locations are not detailed. The opportunity is structured as a subcontract and does not have a set-aside designation, meaning any qualified vendor may respond. Interested parties should submit proposals through the designated online portal before the deadline to be considered for selection.

POSTED

DEADLINE

Surveying and Site Planning ServicesThe contract seeks specialized surveying and site planning services for the development of new storage yards, rail spurs, and equipment installations, with focus on topographic surveying, boundary verification, and precise layout work to support infrastructure expansion. The work is scoped to ensure accurate geographic and cadastral data is collected and applied to facilitate safe, compliant, and efficient construction planning, adhering to state and federal standards for land use and transportation infrastructure. All deliverables must meet rigorous technical specifications to support long-term operational integrity and regulatory compliance. This subcontract, posted by the Florida Department of Transportation under NAICS code 541370, is open for proposals with a response deadline of August 31, 2026. The place of performance is within the state of Florida, though specific locations are not detailed in the posting. Bidders must have proven experience in geospatial surveying and site layout for transportation-related infrastructure projects and be prepared to deliver timely, high-accuracy field data and mapping products. The contract is not set aside for any specific category of business, and all responses must be submitted via the official Florida Marketplace portal.

Florida Department of Transportation

POSTED

DEADLINE

More opportunities from California → Department of General Services (DGS), Real Estate Services Division (RESD), Project Management and Development Branch (PMDB)

Same awarding agency

Security & Life Safety Systems IntegrationThe contract titled Security & Life Safety Systems Integration requires the provision of specialized expertise in security monitoring and alarm systems, with a focus on ensuring full compliance with life safety standards. The primary responsibility involves coordinating directly with the State Fire Marshal and the Division of the State Architect to align all systems and operations with state-mandated safety codes and regulations. This subcontract is linked to the Department of General Services Real Estate Services Division and must be performed in Sacramento, California, at the designated zip code 95814. The work is classified under NAICS code 238210, indicating construction services for electrical and wiring installations, reflecting the technical and integrative nature of the required systems. The bid response deadline is August 20, 2026, and the opportunity was posted on July 30, 2026, with no set-aside provisions indicated, making it open to all qualifying respondents.

Electrical Contractors and Other Wiring Installation Contractors

POSTED

DEADLINE

Regulatory & Environmental Compliance Coordination (CEQA)The contract involves coordinating with agencies and consultants to ensure full compliance with the California Environmental Quality Act (CEQA) and other applicable regulatory requirements, focusing on environmental review and permitting processes. The work is subcontracted under the Department of General Services, Real Estate Services Division, Project Management and Development Branch, and requires close collaboration to navigate state environmental mandates tied to public infrastructure and development projects. Performance is centered in Sacramento, with the primary location identified as 95814, indicating on-site engagement with state facility and land-use initiatives. The contract is classified under NAICS code 541620, reflecting environmental consulting services, and is posted for a response deadline of August 20, 2026, with the solicitation originally posted on July 30, 2026. It is specifically designated as a subcontract, meaning the awardee will operate under the primary contractor’s umbrella to support broader state projects. While no set-aside details or point of contact are provided, the work demands technical expertise in environmental regulations, strong沟通 skills with regulatory bodies, and the ability to manage documentation and timelines critical to CEQA compliance. All activities must align with California’s environmental planning standards to facilitate lawful project advancement.

Environmental Consulting Services

POSTED

DEADLINE

Project Controls & Schedule ManagementThe contract titled Project Controls & Schedule Management involves the development and ongoing maintenance of the Project Master Schedule, with a focus on identifying and tracking the critical path to ensure timely project delivery. The contractor will be responsible for managing all change orders, ensuring accurate documentation and impact analysis, and producing regular progress dashboards that provide clear visibility into budget status, milestone achievement, and emerging risks. These deliverables are critical for informed decision-making and effective project oversight by the California Department of General Services, Real Estate Services Division, Project Management and Development Branch. Work under this subcontract is to be performed primarily in Sacramento, California, with a zip code of 95814, and is classified under NAICS code 541611 for Management Consulting Services. The solicitation was posted on July 30, 2026, and responses are due by August 20, 2026. This engagement supports the state’s real estate and infrastructure development initiatives and requires a specialized skill set in project controls to align scheduling, budgeting, and risk management activities with broader program objectives. All activities must adhere to state standards and reporting protocols established by the agency.

Administrative Management and General Management Consulting Services

POSTED

DEADLINE

Construction Inspection & Quality Assurance (QA) OversightThe contract requires on-site construction observation, material testing oversight, and comprehensive quality assurance services to ensure all work complies with the contract documents, applicable building codes, and industry standards. The scope centers on maintaining adherence to project specifications through direct field supervision and verification of materials and construction methods, with emphasis on consistency, safety, and regulatory alignment throughout the project lifecycle. The contract is issued by the California Department of General Services, Real Estate Services Division, Project Management and Development Branch, with performance required at a Sacramento location with a zip code of 95814. It is classified as a subcontract under NAICS code 541340, which corresponds to architectural, engineering, and related services. The proposal deadline is August 20, 2026, and the solicitation was posted on July 30, 2026. Interested parties must submit responses through the BidAmerica platform using the provided web link.

Drafting Services

POSTED

DEADLINE

Commissioning Agent Services (Cx)The contract calls for independent commissioning services covering mechanical, electrical, and building automation systems to verify that all systems operate as designed, meet energy efficiency targets, and comply with applicable codes and standards. The work is being procured as a subcontract under the California Department of General Services, Real Estate Services Division, Project Management and Development Branch, with performance required in Sacramento, California, specifically at the 95814 zip code location. The services will ensure that newly constructed or renovated facilities achieve optimal performance through systematic testing, documentation, and coordination throughout the project lifecycle. The opportunity was posted on July 30, 2026, with a response deadline of August 20, 2026, and falls under NAICS code 541330 for engineering services. There is no designated set-aside classification, and the contract is open to eligible subcontractors responding to the solicitation. All work must align with the state’s requirements for performance, reliability, and regulatory adherence, with the commissioning agent expected to provide objective oversight from design through occupancy. Interested parties must submit proposals via the provided BidAmerica portal before the deadline.

Engineering Services

POSTED

DEADLINE

Sustainability & Green Building Certification Management (LEED, ZNE, ZNC)The contract requires leading efforts to attain LEED, Zero Net Energy, and Zero Net Carbon certifications for a project under the Department of General Services in California, with performance based in Sacramento. Responsibilities include managing all documentation, coordinating energy modeling activities, and providing full support for third-party certification processes to ensure compliance with sustainability standards. The work demands deep technical expertise in green building systems and a proven ability to navigate complex certification requirements across multiple frameworks. This is a subcontract opportunity with a NAICS code of 541620, targeting firms specializing in environmental consulting and sustainable design services. The solicitation was posted on July 30, 2026, with a hard deadline for responses on August 20, 2026. Performance will center on a state facility in Sacramento, and while no set-aside designation is specified, the scope indicates a need for specialized knowledge in energy efficiency, carbon accounting, and green building documentation. All deliverables must align with the state’s broader sustainability goals and be executed with precision to meet certification benchmarks.

Environmental Consulting Services

POSTED

DEADLINE

Progressive Design-Build Entity (DBE) Evaluation & Selection SupportThe contract supports the prime contractor in evaluating and selecting a Design-Build contractor for a state-funded project under the Department of General Services in California, specifically managed by the Real Estate Services Division’s Project Management and Development Branch. The scope includes conducting comprehensive technical and financial reviews of prospective Design-Build entities, assessing potential risks associated with each bidder’s proposal, and analyzing team alignment to ensure compatibility and capability to deliver the project successfully. The evaluation process is designed to support an informed, data-driven selection that aligns with project goals, budget constraints, and risk tolerance thresholds. The work is to be performed in Sacramento, with a response deadline of August 20, 2026, and falls under the NAICS code for architectural, engineering, and related services. This subcontract role requires expertise in design-build procurement methodologies, financial modeling, risk mitigation strategies, and stakeholder coordination to assist the prime in identifying the most qualified Design-Build team. The successful bidder will operate under the overarching requirements of the California Department of General Services, ensuring compliance with state procurement standards and project delivery objectives.

Administrative Management and General Management Consulting Services

POSTED

DEADLINE

Preconstruction Cost Estimating & Budget DevelopmentThe contract requires the development and validation of initial cost estimates to support the formation of a Guaranteed Maximum Price during the design development phase, ensuring alignment with project budgetary goals and funding constraints. The selected contractor will provide expert cost control services throughout the design process, identifying potential cost drivers, analyzing alternatives, and delivering timely, accurate financial assessments to facilitate informed decision-making by the project team. This subcontract is issued by the California Department of General Services, Real Estate Services Division, Project Management and Development Branch, for work to be performed in Sacramento with a zip code of 95814. The NAICS code 541620 indicates the scope involves architectural, engineering, and related services, specifically focused on cost estimating and budget development. Responses are due by August 20, 2026, and the work is intended to support public infrastructure projects under the state’s oversight, with no set-aside classification specified.

Environmental Consulting Services

POSTED

DEADLINE

Construction Project Management O Street State Parking Garage

Solicitation # RESD PMDB 2026-06

The Contract solicitation 20260729048 for Construction Project Management services for the O Street State Parking Garage in Sacramento, California, is a qualifications-based procurement issued by the California Department of General Services, Real Estate Services Division, Project Management and Development Branch. The project involves managing a 750-space parking structure with an estimated total design-build budget of $40 million over a 29- to 32-month timeline, including 5 to 8 months of preconstruction and a 24-month progressive design-build phase. Offerors must demonstrate experience in progressive design-build delivery, sustainable building standards such as LEED, Zero Net Energy (ZNE), and Zero Net Carbon (ZNC), as well as compliance with state regulations including CEQA, Labor Code §1774 for prevailing wages, and oversight from the Division of the State Architect and State Fire Marshal. Submission requirements include a letter of interest, a three-page executive summary, Federal Form 330 for both prime and subcontractor entities, and a twelve-page project approach detailing qualifications in key areas such as cost estimating, scheduling, project management systems, regulatory compliance, quality assurance, and leadership. Proposals must be submitted electronically as a single PDF via the DGS Box.com portal by August 19, 2026, at 5:00 p.m. PDT, with no hand deliveries or email submissions accepted. Evaluation will be based on sixteen criteria including firm and key personnel experience, resource availability, ability to work with other entities, use of Big Room and Lean methodologies, commissioning agent capabilities, and project management software proficiency, though no weights or scoring thresholds are disclosed. The selection process typically involves evaluating written responses, shortlisting the top three firms for oral interviews, and then negotiating fees with the selected firm prior to award. Special contractual obligations include mandatory DIR registration for all contractors, submission of certified payroll reports, 10% retention on progress payments with escrow provisions after 60 days of delayed payment, and strict disclosures regarding use of Generative AI in deliverables. Firms must also certify they are not subject to U.S. or California economic sanctions related to Russia. Organizational conflict of interest is mitigated through a contract clause that excludes the selected firm and its affiliates from future design-build contracts for the same project. The point of contact for contractual matters is Therese Dominguez and Nora Sandstedt, while Nick Rossi handles technical inquiries. The work is to be performed entirely at

Engineering Services

POSTED

DEADLINE

Small & DVBE Participation OpportunitiesThe Department of General Services, Real Estate Services Division, Project Management and Development Branch, is soliciting participation from Small and Disabled Veteran Business Enterprises for subcontracting opportunities across various trades under NAICS code 238210. These opportunities are tied to projects managed by the agency in Sacramento, California, with a posting date of July 30, 2026, and a mandatory response deadline of August 11, 2026. The solicitation is specifically designed to facilitate inclusion and access for eligible small and disabled veteran-owned businesses, encouraging their involvement in construction-related subcontracts without specifying a formal set-aside classification. Interested parties must submit their responses through the official BidAmerica portal before the deadline to be considered for potential subcontracting roles on state-funded projects managed by the agency. There is no designated point of contact listed, and the place of performance is centered in Sacramento with a zip code of 95814.

Electrical Contractors and Other Wiring Installation Contractors

POSTED

DEADLINE

Civil/Structural Inspection & Quality AssuranceThe contract requires the provision of comprehensive civil and structural inspection and quality assurance services, including the full scope of Inspector of Record duties, to ensure compliance with engineering standards and project specifications. The work is focused on construction activities within Sacramento, California, with a place of performance identified as ZIP code 95814, and is issued under the NAICS code 541370 for architectural, engineering, and related services. The contract is classified as a subcontract and is being solicited by the California Department of General Services, Real Estate Services Division, Project Management and Development Branch, which oversees public infrastructure and building projects. Respondents must submit proposals by August 11, 2026, and the solicitation is open to qualified third-party firms capable of delivering impartial, diligent, and code-compliant inspection services throughout the project lifecycle. The successful vendor will be expected to act as the official Inspector of Record, verifying material authenticity, construction techniques, structural integrity, and adherence to approved plans, with full accountability for documentation and reporting. All work must align with state and local regulations, and the contractor will be required to maintain a high standard of professionalism, accuracy, and responsiveness to ensure the safety and longevity of public infrastructure.

Surveying and Mapping (except Geophysical) Services

POSTED

DEADLINE

General Contractor & Construction ExecutionThe contract outlines the full scope of construction execution for a project under the Department of General Services, specifically managed by the Real Estate Services Division’s Project Management and Development Branch in California. The work includes comprehensive site preparation, demolition of existing structures, structural framing, interior and exterior finishes, and full coordination of all trade contractors to ensure seamless integration and timely completion. All activities must be performed at the designated place of performance in Sacramento, with a ZIP code of 95814, and are governed under the NAICS code 236220 for commercial and institutional building construction. This is a subcontract opportunity with a response deadline of August 11, 2026, and bidders are expected to demonstrate capability in managing complex construction phases while adhering to established standards and timelines. The solicitation is accessible via the BidAmerica platform for further details and submission procedures.

Commercial and Institutional Building Construction

POSTED

DEADLINE