This Combined Synopsis/Solicitation opportunity from Department Of Defense was posted on July 8, 2026. The submission period has ended. Browse the details below for market research, or find similar active opportunities.
Full Window Replacement, Building 674, U.S. Army Garrison Devens Reserve Forces Training Area (RFTA)
Contract Overview
Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.
Active Opportunities Like This One
AI Contract Overview
The contract pertains to a full window replacement project at Building 674 within the Devens Reserve Forces Training Area in Massachusetts, issuing a 100% small business set-aside under NAICS code 238350 with a $19.5 million size standard. The work entails the complete removal of existing windows and installation of approximately 282 vinyl, single-hung, dual-pane, low-E insulated replacement windows featuring a dark bronze finish, 3-1/4-inch depth, 7/8-inch insulated glass with Argon gas filling, and full-size insect screens. Ancillary work includes installation of flashing, sealants, shims, trim, and restoration of all affected surfaces to as-found condition. The project is governed by a firm-fixed-price structure with a 365-day period of performance commencing upon written Notice to Proceed. Environmental compliance is mandatory under Section 01 57 20, requiring hazardous waste minimization, proper disposal protocols, and immediate reporting of spills to the Devens DPW Environmental Specialist. All work must adhere to EM 385-1-1, ASSE/SAFE A10.6, and EPA standards, with strict prohibitions against burning debris or discharging materials into sewer or storm systems. Contractor responsibilities include daily cleanup, dust control, and submission of five copies of Material Safety Data Sheets for all hazardous materials used. All proposals must be submitted electronically by July 1, 2026, at noon, and structured into two volumes: Volume I is a 15-page searchable PDF detailing the technical approach to demolition, environmental controls, and installation, including subcontractor identification and compliance with FAR 52.219-14; Volume II contains the SF 1442, completed Contractor Cost Breakdown Form listing labor categories per the Davis-Bacon wage determination MA20260001 for Middlesex County, MA, along with equipment, materials, overhead, and profit rates, and CLIN pricing for both the window replacement and bond reimbursement. A bid bond equivalent to 20% of the bid price or $3 million, whichever is less, is required. Upon award, the contractor must submit 100% performance and payment bonds within ten calendar days. Liquidated damages of $275 per day of delay apply. A mandatory site visit is scheduled for June 22 and 23, 2026, and all
General Info
Agency
NAICS
Place of Performance
MA, 01434, USASet-Aside
Timeline
Submission Closed
Organization & Contact Information
Full Description
Amendment 0003:
The purpose of this amendment is to extend solicitation due date and answer vendor questions.
Amendment 0002:
The purpose of this amendment is to answer vendors' questions. Please see attachement Solicitation Amendment W15QKN26RA0560002 SF 30. Hazard Surveys are not a part of this amendment, to the best of our knowledge, there is no asbestos within the building.
The purpose of this amendment is to extend the response due date. Please see attachement Solicitation Amendment W15QKN26RA0560001 SF 30 for full details.
Project Title: Full Window Replacement, Building 674, Devens Reserve Forces Training Area (RFTA)
Notice Type: Solicitation Notice
1. General Information
- Product Service Code (PSC): Z2AZ – Maintenance, Repair, or Alteration of Other Residential Buildings
- NAICS Code: 238350 – Finish Carpentry Contractors
- Small Business Size Standard: $19.5 Million
- Set-Aside Status: 100% Set-Aside for Small Business Concerns (pursuant to FAR 19.502-2)
- Contract Type: Single, Firm-Fixed-Price (FFP) Construction Contract
- Period of Performance (PoP): Exactly 365 calendar days from receipt of the written Notice to Proceed (NTP)
- Place of Performance: Building 674, Devens Reserve Forces Training Area (RFTA), 30 Quebec Street, Devens, MA 01434
2. Detailed Requirement Description & Scope of Work
The Contractor shall provide all plant, labor, supervision, materials, equipment, tools, and transportation necessary to complete a full window replacement at Building 674, Devens RFTA, MA.
Core Project Requirements:
- Demolition & Prep: Complete removal of all existing windows at Building 674 in strict accordance with SOW Section 02 41 00 (Demolition), ensuring rubbish and debris are removed from Government property daily.
- Window Installation: Supply, deliver, and install approximately 282 vinyl, single-hung, dual-pane, low-E insulated replacement windows with a dark bronze finish, 3-1/4-inch depth, and 7/8-inch insulated glass with Argon gas filling.
- Ancillary Work: Provide and install all associated flashing, sealants, shims, trim, and insect screens for each operable window to form a completely weather-tight joint.
- Environmental Controls: Strict adherence to Section 01 57 20 (Environmental Protection) is required, including hazardous waste minimization, proper solid waste/chemical disposal, and immediate spill/release reporting to the Devens DPW Environmental Specialist.
- Important Site Inconsistency Clarification: SOW/PWS Section 1.1 contains a clerical error referencing window removals in "Buildings 646 and 653." Offerors are formally notified that this requirement is restricted solely to Building 674. Any references to other buildings in the attachments are declared null, void, and completely overridden.
3. Site Visit & Access Control Procedures
A site visit is highly encouraged to perform dimensional verifications. Failure to inspect the site will not constitute grounds for post-award claims for differing site conditions or dimensional errors.
- Primary Site Visit: Monday, June 22, 2026, from 10:00 AM to 11:00 AM (Local Time)
- Alternate Site Visit: Tuesday, June 23, 2026, from 10:00 AM to 11:00 AM (Local Time)
- Location: Building 674, Devens RFTA, Devens, MA 01434
- Installation Access Requirements: All attendees must complete the Request for Fort Devens Access Control Visitors Pass (Attachment 0004) and submit it at least forty-eight (48) hours prior to the scheduled site visit date to both points of contact:
- Zygmunt Osiecki, DPW Director: zygmunt.v.osiecki.civ@army.mil | (978) 615-6104
- Paul A. Lavoie, Engineer Technician: paul.a.lavoie3.civ@army.mil | (520) 717-2442
4. Submission Instructions & Proposal Structure
Offers must be submitted electronically via email to Contract Specialist Nelia Shyshak (nelia.shyshak.civ@army.mil) and Contracting Officer Edward Sherwood (edward.l.sherwood.4@army.mil) by the deadline. Proposals shall consist of two (2) separate volumes:
- Volume I – Technical Proposal (15-Page Limit, Searchable PDF):
- PWS Understanding & Execution Plan: A detailed technical narrative outlining the step-by-step approach to window removal, hazardous waste environmental controls (complying with SOW Section 01 57 20), surface patching, and window installation.
- Subcontractor Identification: If utilizing subcontractors, identify companies, percentage of work to be performed, and verify compliance with FAR 52.219-14 (Limitations on Subcontracting).
- Volume II – Price Proposal (No Page Limit):
- Standard Form (SF) 1442: Signed and fully completed (Blocks 14, 15, 16, 20a, 20b, and 20c).
- Attachment 0003 – Contractor Cost Breakdown Form: Fully completed line-item pricing detailing labor categories (complying with Davis-Bacon Wage Determination MA20260001 for Middlesex County, MA), equipment, material quantities, and separately identified Overhead/G&A and Profit rates. Note that the cost breakdown template is provided as an intentionally blank sheet to support performance-based proposals.
- CLIN Pricing: FFP CLIN 0001 (Full Window Replacement) and FFP CLIN 0002 (BOND – reimbursement of actual bond premiums).
- Bid Guarantee: Documentation of a Bid Bond in the amount of 20% of the bid price or $3 Million, whichever is less, in accordance with FAR 52.228-1.
5. Key Terms & Evaluation Criteria
- Source Selection Process: Lowest Price, Technically Acceptable (LPTA) source selection process (FAR 52.212-2).
- Performance and Payment Bonds: The successful awardee must furnish a Performance Bond (SF 25) and a Payment Bond (SF 25A) equal to 100% of the contract price within ten (10) calendar days after contract award (FAR 52.228-15).
- Liquidated Damages: $275.00 per calendar day of delay (FAR 52.211-12).
- Wage Determination: Davis-Bacon Act Wage Determination General Decision Number MA20260001, updated May 18, 2026, applies.
6. Critical Milestones & Deadlines
Primary Site Visit June 22, 2026 10:00 AM – 11:00 AM
Alternate Site Visit June 23, 2026 10:00 AM – 11:00 AM
Questions Deadline June 24, 2026 4:00 PM (16:00)
Proposal Submission Deadline July 1, 2026 12:00 PM (Noon)
More opportunities from Department Of Defense → W6QK Acc-Pica
Same awarding agency
Find Active Opportunities Like This
Get AI-powered intelligence on the opportunities still open
Every page of the solicitation package shredded into a compliance breakdown
AI-powered matching based on your capabilities and past performance
Competitor and incumbent history on the requirement
Automated alerts on amendments, Q&A deadlines, and award
Join 650+ contractors already using CLEATUS