This Solicitation opportunity from Department Of Defense was posted on February 21, 2024. The submission period has ended. Browse the details below for market research, or find similar active opportunities.

Top

P-1238 CONSTRUCTION OF GRID STABILITY & RESILIENCY 10 MW BATTERY ENERGY STORAGE, VARIOUS BUILDINGS AT MARINE CORPS AIR GROUND COMBAT CENTER (MCAGCC), TWENTYNINE PALMS, CA

Closed

N6247322R4005Federal

Submission Closed05/03/2023, 09:00:00 PM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

Active Opportunities Like This One

NAICS: 237130

New

AAL-1440-01 RCO Relocation Hooper Bay - BNATCS

Solicitation # AAL-1440-01

Solicitation AAL-1440-01, managed by PTSI Managed Services Inc., is for the RCO relocation project located in Hooper Bay, Alaska. The scope of work involves specialized construction activities, specifically focusing on foundation work, duct bank installation, and grounding work. The estimated magnitude of the construction is valued between 100,000 and 250,000 dollars, with a proposed start date of December 10, 2026. This opportunity is designated as an SBA set-aside, open to Small Businesses, including certified Veteran Owned, Service-Disabled Veteran Owned, Women-Owned, and HUBZone Small Businesses. The project falls under NAICS code 237130. Interested firms should coordinate with Masanori Akers, the Parsons Subcontract Administrator, regarding participation. The solicitation was posted on October 20, 2026, with a response deadline of November 14, 2026.

PTSI Managed Services Inc.

POSTED

DEADLINE

Term Agreement with 4 Options to Renew - Fiber Optic Maintenance, Repair and Modernization for IT, Transportation, and Water Departments

Solicitation # REQ00003176

The City of Garland is soliciting bids for a term agreement under solicitation REQ00003176 to provide fiber optic maintenance, repair, and modernization services for its IT, Transportation, and Water Departments. The contract consists of an initial twelve-month term with four optional twelve-month renewal periods. The City intends to award the contract to the two highest-ranked respondents, designating one as the primary contractor and the other as the secondary contractor to ensure redundancy and emergency response capacity. Award decisions are based on best value, evaluated through overall qualifications, client references, and relevant project examples. The scope of work requires the contractor to provide all labor, materials, and equipment for installation, troubleshooting, and emergency repairs of critical infrastructure, including public safety and SCADA systems. Critical priority outages require a two-hour response time. Deliverables include schematic diagrams, OTDR test files, and as-built drawings, with a minimum two-year workmanship warranty required for all services. Bidders must submit comprehensive bids on all items to be considered responsive, adhering to Texas Government Code Chapter 2258 for prevailing wage rates. Materials are to be billed at actual cost plus a markup not exceeding 10 percent. All submissions must be made electronically via the IonWave portal by November 5, 2026.

POSTED

DEADLINE

Water Treatment Equipment InstallationThis subcontract for Water Treatment Equipment Installation involves the supply and installation of specialized water treatment systems for prime contractors working on City of Hollywood Public Utilities projects. The scope of work includes the removal of existing sludge drum thickeners and dust collectors, followed by the installation of new units. To ensure full functionality, the contractor is responsible for performing field testing and calibration under the direct supervision of the manufacturer to deliver fully operational systems. The project falls under NAICS code 237130 and is managed by the Public Utilities agency in Florida. Interested parties must submit their responses by the deadline of November 25, 2026. Further details regarding the solicitation can be accessed through the provided procurement portal.

POSTED

DEADLINE

Horizontal Directional Drilling (HDD) ServicesThis subcontract for Horizontal Directional Drilling (HDD) Services involves performing specialized boring and conduit installation for prime contractors on City of Ukiah Department of Electric Utility projects. The scope of work requires the execution of 1,375 linear feet of HDD boring and the subsequent installation of conduits utilizing professional drilling rigs and guidance tracking systems. To be eligible for this project, contractors must possess a valid California Class A Contractor's License and maintain current DIR Registration. The project is located in Ukiah, California, with a response deadline set for December 1, 2026.

POSTED

DEADLINE

North State And Hwy 101 Utility Infrastructure Boring Project

Solicitation # 26-02

The City of Ukiah, Department of Electric Utility, is soliciting bids for the North State and Hwy 101 Utility Infrastructure Boring Project (Solicitation #26-02). This project involves the installation of utility infrastructure through horizontal directional drilling (HDD) and trenching at North State Street and Highway 101 in Ukiah, California. The scope of work includes 1,375 linear feet of HDD and 142 linear feet of trenching, backfilling, and compaction. Key deliverables include the installation of various HDPE and PVC conduits ranging from 1.25 to 6 inches and the installation of six fiber service vaults. The contract will be awarded to the lowest responsive and responsible bidder based on the lowest Base Bid. Eligible bidders must possess a valid State of California Class A Contractor's License and be registered with the Department of Industrial Relations. Submission requirements include a detailed proposal with unit pricing, a Fair Employment Practices Certification, a notarized Non-Collusion Affidavit, and a statement of experience. Bids must be accompanied by a 10 percent bid security. Upon award, the contractor is required to provide a performance bond for 100 percent of the total contract price, as well as a payment bond and appropriate insurance certificates. The City will provide engineering personnel for inspections, and the contractor is responsible for ensuring all materials are stored to preserve quality and fitness for the work. The response deadline for this solicitation is December 1, 2026.

POSTED

DEADLINE

Broadband Implementation Project - FFA

Solicitation # 2001063

The Broadband Implementation Project - FFA, solicitation number 2001063, is a comprehensive infrastructure initiative for the City of San Luis Obispo, California. The project involves the installation of aerial and underground fiber optics, including directional boring for conduit, deep bore casing, and the installation of 288 CT fiber cable. The scope of work encompasses the placement of various sized vaults, copper clad ground rods, pole risers, down guys, anchors, and new wooden poles, as well as cut and kick operations for existing poles. Additional requirements include potholing, tree trimming, public notification, and strict compliance with CPUC grant reporting and archaeological monitoring. The project is structured with a base bid and five additive alternates covering specific street segments, with award decisions based on a total project bid hierarchy capped at 2,400,000 dollars. Contractors must adhere to stringent technical and regulatory standards, including CPUC General Order 95, Caltrans 2024 specifications, and the City of San Luis Obispo 2025 Engineering Standards. Key requirements include the submission of OTDR bi-directional testing results prior to acceptance and the employment of directional drilling personnel with at least two years of experience. Bidders must provide a bid guaranty of 10 percent of the bid amount and, upon award, provide performance and payment bonds equal to 100 percent of the contract price. Compliance with California Labor Code is mandatory, requiring registration with the Department of Industrial Relations and adherence to prevailing wage laws. Sealed bids are due by 11:00 a.m. on November 19, 2026, to the Public Works Administration Office in San Luis Obispo.

City of San Luis Obispo

POSTED

DEADLINE

Marine Stadium Electrical Infrastructure

Solicitation # R-7292

Solicitation R-7292 is a project for the City of Long Beach, California, to provide electrical infrastructure for the Marine Stadium parking lot adjacent to Paoli Way. The scope of work includes installing new transformers and switchgear at three locations, removing existing transformers, and constructing new low-voltage power distribution systems. Additional requirements involve pavement trenching and restoration, concrete site work, and the use of ground penetrating radar for mapping. The project is subject to prevailing wage rates and requires a local Coastal Development Permit from the California Department of Fish and Wildlife. To be eligible for award, contractors must demonstrate minimum qualifications by having completed at least three projects of similar scope and value, each totaling at least 600,000 dollars, within the last five calendar years. Bidders must submit their proposals electronically via the city's bidding portal by the November 18, 2026, deadline, including a bid security of at least 10 percent of the bid. Awarded contractors must provide faithful performance and labor and material bonds. Payment will be processed using AIA format invoices, requiring detailed itemization of earned amounts, retention, and supporting documentation such as construction photographs and partial lien releases.

POSTED

DEADLINE

Power Line Relocation and ReconductoringThis subcontract through the National Energy Technology Lab of the Department of Energy focuses on power line relocation and reconductoring to enhance grid resilience. The scope of work involves removing existing lines and installing advanced, low-sag conductors designed to withstand high-load and high-heat events, while relocating lines to safer corridors. All work must be performed by a credentialed workforce in strict accordance with Davis-Bacon Act prevailing wage requirements to deliver upgraded transmission and distribution infrastructure. The project falls under NAICS code 237130 and was posted on October 20, 2026, with a response deadline of February 18, 2027. This opportunity is intended for firms capable of supporting prime contractors in executing critical energy infrastructure upgrades to ensure a more stable and resilient power grid.

National Energy Technology Lab

POSTED

DEADLINE

Microgrid Design and InstallationThis subcontract for the National Energy Technology Lab under the Department of Energy focuses on the design and installation of distributed energy resource microgrids to enhance grid resilience. The selected provider will serve as a subcontractor to prime contractors, performing engineering, procurement, and construction for microgrid controllers and switchgear. A primary objective is the integration of local generation sources to enable islanding capabilities, ensuring that critical loads remain powered during outages. All work must strictly adhere to NERC CIP standards and the NIST Cybersecurity Framework to ensure system security and reliability. The project falls under NAICS code 237130 and requires the delivery of a fully operational microgrid system. Interested parties should note the response deadline of February 18, 2027.

National Energy Technology Lab

POSTED

DEADLINE

HG&E Contract #26-17 - Electric Line Contractor Annual Contract

Solicitation # BD-24-1895-HGE00-HGE01-134588

Holyoke Gas & Electric is soliciting bids for an annual Electric Line Contractor contract under solicitation number BD-24-1895-HGE00-HGE01-134588. The scope of work encompasses comprehensive construction and maintenance services for overhead distribution lines up to 34.5 kV, including street light maintenance, overhead transmission lines up to 115 kV, and underground lines up to 34.5 kV. This open market solicitation is managed by the agency in Holyoke, Massachusetts, with a response deadline and bid opening date of November 24, 2026. Bidders are required to adhere to prevailing wage rates and must submit a bid deposit based on their specific scope of work: 15,000 dollars for overhead transmission only, 17,500 dollars for overhead distribution or underground line work, and 50,000 dollars for those bidding on all three service areas. Additionally, the successful contractor must provide a payment bond equivalent to 50 percent of the total estimated annual value of the awarded contract. Performance and administration are centered at the Holyoke Gas & Electric facilities on Suffolk Street.

HGE001 - Holyoke Gas & Electric

POSTED

DEADLINE

Solicitation # 24-17.11

The City of Piqua, Ohio, is soliciting bids for Project No. 24-17.11, which involves the construction of the Washington Road 69kV Transmission Line. The scope of work includes the furnishing and installation of approximately 2.0 miles of 69kV transmission line terminating at a new 69kV/13.8kV substation. Key technical requirements include a 12.47kV distribution underbuild from Pole P1 through Pole P18, the installation of all-dielectric self-supporting fiber optic cable along the entire line, and the use of both contractor-furnished materials and owner-furnished self-supporting steel poles. The project has an engineer's estimate of $1,900,000 and requires adherence to the National Electrical Safety Code and various ASTM standards for ductile iron poles and fiberglass crossarms. Bidders must provide evidence of financial and performance experience and are required to submit a bid bond of at least 10% of the total bid amount. The successful contractor must post a combined performance and payment bond for 100% of the contract value. Compliance with State of Ohio Prevailing Wage laws, the Americans with Disabilities Act, and Drug-Free Workplace certifications is mandatory. Bids must be submitted via Bid Express, email, or sealed hard copy by October 29, 2026. All equipment must be delivered FOB Destination to the City of Piqua, and any bids specifying FOB Factory will be rejected.

POSTED

DEADLINE

Solicitation # 24-17.10

The City of Piqua, Ohio, is soliciting bids for project 24-17.10, which involves the electrical construction of the Piqua 69kV The Site Substation. With an engineer's estimate of $1,310,000, the scope of work includes furnishing and installing major equipment such as liquid-filled step-down transformers, circuit breakers, and switches, as well as the construction of 69kV incoming, switch, metering, and bus support structures. The contractor is responsible for comprehensive site work, including minor clearing, excavation, structural fill, grounding for all equipment, and the installation of above-ground conduits. The project also requires assistance with the start-up and commissioning of all mechanical, electrical, and electronic systems. Bidders must adhere to strict compliance standards, including State of Ohio Prevailing Wage laws, the Americans with Disabilities Act, and Drug-Free Workplace certifications. A bid bond of no less than 10 percent is required, and the successful contractor must provide performance and payment bonds equal to the full contract price. Award selection will be based on a comparison of relative merits and the lowest and best bid. Technical execution must follow NESC, NEC, IEEE, and ANSI standards, with specific quality controls for concrete foundations and equipment shipment integrity. Performance penalties of $500 per calendar day apply for deliveries exceeding the designated completion date.

City of Piqua

POSTED

1 day ago

DEADLINE

in 9 days

General Info

Agency

Department Of Defense → Navfacsyscom Southwest

NAICS

237130 - Power and Communication Line and Related Structures Construction

Place of Performance

Twentynine Palms, CA, 92277, USA

Set-Aside

NONE

Documents

Amendment 0001 to Solicitation N624732R4005

amendment

High

Amendment 0002 to Solicitation N6247322R4005

amendment

High

Amendment 0003 - N6247322R4005

amendment

High

Amendment 0004 to Solicitation N6247322R4005

amendment

High

Amendment 0005 to Solicitation N6247322R4005

amendment

High

Amendment 0006 - N6247322R4005

amendment

High

Amendment 0007 to Solicitation N6247322R4005

26 pages · amendment

High

Amendment 0008 to Solicitation N6247322R4005

amendment

High

Amendment 0009 to Solicitation N6247322R4005

26 pages · amendment

High

Amendment 0010 to Solicitation N6247322R4005

26 pages · amendment

High

Amendment 0011 to Solicitation N6247322R4005

2 pages · amendment

High

Amendment 0012 - N6247322R4005

27 pages · amendment

High

Amendment 0013 to Solicitation N6247322R4005

2 pages · amendment

High

Amendment 0014 - Solicitation N624732R4005

amendment

High

Exhibit A: Offeror Team Composition and Management (N62473-22-R-4005)

specifications

High

Exhibit B - Construction and Design Experience Project Data Sheets (N62473-22-R-4005)

past-performance

High

Exhibit F - Safety Data Sheet (N62473-22-R-4005)

specifications

High

N6247322R4005 - Construction of Grid Stability & Resiliency 10 MW Battery Energy Storage

109 pages · ifb

High

NAVFAC/USACE Past Performance Questionnaire (Form PPQ-0)

past-performance

Low

RFI Form - N6247322R4005 (Grid Stability & Resiliency Battery Energy Storage)

5 pages · q-and-a

Low

AI Contract Breakdown

Uniform Contract Format

Contract not broken down yet

CLEATUS splits the solicitation into Uniform Contract Format (UCF) sections: scope, pricing, deliverables, and evaluation criteria.

Timeline

20 updates

PhaseClosed

PostedSep 8

Solicitation

Notice updatedSep 12

Notice details unchanged. Attachments may have changed.

Notice updatedSep 13

Notice details unchanged. Attachments may have changed.

Notice updatedSep 13

Notice details unchanged. Attachments may have changed.

Notice updatedSep 19

Notice details unchanged. Attachments may have changed.

Deadline changedOct 11

Response deadline changed from Oct 12, 2022 to Oct 26, 2022.

Deadline changedOct 25

Response deadline changed from Oct 26, 2022 to Nov 9, 2022.

Deadline changedNov 7

Response deadline changed from Nov 9, 2022 to Nov 30, 2022.

Deadline changedNov 28

Response deadline changed from Nov 30, 2022 to Dec 14, 2022.

Deadline changedDec 12

Response deadline changed from Dec 14, 2022 to Jan 11, 2023.

Deadline changedJan 4

Response deadline changed from Jan 11, 2023 to Jan 25, 2023.

Deadline changedJan 19

Response deadline changed from Jan 25, 2023 to Feb 8, 2023.

Notice updatedJan 19

Notice details unchanged. Attachments may have changed.

Notice updatedJan 19

Notice details unchanged. Attachments may have changed.

Deadline changedFeb 1

Response deadline changed from Feb 8, 2023 to Mar 1, 2023.

Deadline changedFeb 27

Response deadline changed from Mar 1, 2023 to Mar 15, 2023.

Deadline changedMar 14

Response deadline changed from Mar 15, 2023 to Apr 12, 2023.

Deadline changedMar 31

Response deadline changed from Apr 12, 2023 to May 3, 2023.

Notice updatedApr 20

Notice details unchanged. Attachments may have changed.

Response DeadlineMay 3

Deadline has passed

Notice updatedFeb 21

Notice details unchanged. Attachments may have changed.

Notice updatedFeb 21

Notice details unchanged. Attachments may have changed.

Submission Closed

05/03/2023, 09:00:00 PM UTC

Find active opportunities like this

Start your free trial to discover similar active contracts, track opportunities, and build proposals with AI assistance.

Organization & Contact Information

AgencyDepartment Of Defense → Navfacsyscom Southwest

Contacts1 person available

OfficeSAN DIEGO, CA, 92132-0001, USA

Organization / AgencyDepartment Of Defense → Navfacsyscom Southwest

Office AddressSAN DIEGO, CA, 92132-0001, USA

Contacts

Vincent Nazzal

contact@example.gov

Full Description

The work to be acquired under this solicitation is for the Design-Build Construction Contract to install 10 MW of battery energy storage systems (BESSs) that will enhance energy security at various locations at Marine Corps Air Ground Combat Center (MCAGCC) in Twentynine Palms, California. The BESSs shall be capable of powering numerous mission critical and support facilities at the distribution level during a utility grid outage. There are approximately 54 BESSs (each of which will include high energy density batteries, bidirectional inverters, and the associated controls) that will be standalone modular packaged units connected to one or more solar photovoltaic (PV) arrays. The BESSs will be connected to the solar PV systems for clean energy charging as well as to the Project P-1238 Construction of Grid Stability & Resiliency 10 MW Battery Energy Storage, Various Buildings at Marine Corps Air Ground Combat Center, Twentynine Palms, California Apr 15, 2022 12:03:02 AM GMT 1 installation's electric distribution system for utility power or on-site cogeneration system charging. The BESSs will be tied into the installation's microgrid (being built via project P-1232) so the battery energy can be discharged to level solar PV variability and stabilize the grid (electrical distribution system reliability), provide power to support black-start and islanding events (energy resilience), and reduce energy costs during peak demand/energy pricing periods (energy management/efficiency). Also, the BESS controls will be accredited to ensure the energy systems remain cyber secure. The goal for this project is to integrate BESSs into an electrical distribution microgrid on MCAGCC. The project installs and fully permits new BESSs capable of parallel operation, each located in proximity to existing PV systems.