Psst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveCLEATUS Webinar: AI for Government Contracting — Free Webinar — Wednesday, August 19 at 2:00 PM EDT

Register Free →

Search

Top

Back to Contracts

Reinforced Concrete Construction

Active

Federal

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

This contract involves the subcontract for reinforced concrete construction, specifically the forming, pouring, and finishing of reinforced concrete for foundations, floors, and various structural elements. It is associated with the Department of Defense, under the agency designation W076 Endist Little Rock, with the work to be performed in Fort Smith. The contract falls under NAICS code 238110, which covers concrete contractors. The solicitation was posted on December 12, 2025, but no solicitation number or set-aside type is specified. Details such as the office address and point of contact are not provided. The contract focuses on providing specialized concrete work critical to structural integrity and foundational construction within a military or government project context.

General Info

Subcontract for reinforced concrete work on foundations and structures at Fort Smith, DoD project.

Agency

Department Of Defense → W076 Endist Little RockView Agency

NAICS

238110 - Poured Concrete Foundation and Structure ContractorsView NAICS

Place of Performance

Fort Smith, AR, USA

Set-Aside

NONE

Documents

(0)

No documents available

AI Contract Breakdown

Uniform Contract Format

No contract breakdown available.

Cannot generate Contract Breakdown because no documents were found from this contract's source.

Timeline

PostedDec 12

subcontract

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more

AgencyDepartment Of Defense → W076 Endist Little Rock

ContactsNo contacts available

OfficeN/A

Organization / Agency

Department Of Defense → W076 Endist Little Rock

View Agency Profile

Office AddressN/A

ContactsNo contact information available

Full Description

Show more

Forming, pouring, and finishing of reinforced concrete for foundation, floors, and structural elements.

Similar Contracts

Same NAICS industry code

Concrete Forming and Placement

ASC COMMODITIES DIVISION

POSTED

about 7 hours ago

DEADLINE

Concrete Formwork and PlacementThe contract titled Concrete Formwork and Placement involves the full scope of activities related to forming, reinforcing, pouring, and finishing both structural and architectural concrete elements for a project under the Nuclear Reactor Program within the Department of Defense. It is issued as a subcontract with a Total Small Business Set-Aside designation, meaning only small businesses as defined by the Small Business Administration are eligible to respond. The North American Industry Classification System code 238110 applies, indicating a classification within the concrete work specialty trade. Performance of the work is required at a site in San Diego, California, with a zip code of 92136-3581. The solicitation was posted on August 5, 2026, and responses must be submitted by August 14, 2026, with no point of contact specified. The opportunity is accessible through the DIBBS platform via a public link for interested contractors.

NUCLEAR REACTOR PROGRAM

POSTED

about 7 hours ago

DEADLINE

Concrete Formwork and Placement

Defense Logistics Agency

POSTED

about 7 hours ago

DEADLINE

Concrete Forming and PouringThe contract titled Concrete Forming and Pouring seeks a subcontractor to perform formwork, reinforcement, and concrete placement for foundations, slabs, and other structural elements at a location in Tracy, California, with a ZIP code of 95304-5000. Work is classified under NAICS code 238110, which pertains to concrete work contractors, and is issued by the Department of Defense under the organization name CONSTRUCTION & EQUIPMENT MANU & CON. The solicitation was posted on August 5, 2026, with responses due by August 17, 2026, and is intended for subcontracting purposes without a specific set-aside designation. Interested parties must submit proposals through the DIBBS portal using the provided link to ensure proper consideration. All work must comply with federal construction standards and be performed in accordance with technical specifications expected for military infrastructure projects.

CONSTRUCTION & EQUIPMENT MANU & CON

POSTED

about 7 hours ago

DEADLINE

Biffy Facility ImprovementsThe contract titled Biffy Facility Improvements involves comprehensive upgrades to a facility to meet stringent safety and sanitation standards, focusing on the construction of a new non-combustible and explosion-proof structure with full interior and exterior lighting, ventilation, and space heating for freeze protection. The facility will include cameras, access doors for equipment, and surfaces that are sanitizable in accordance with NFPA 820 and FDA guidelines. Critical safety features include an emergency eyewash and emergency shower station with tempered water, fire extinguishers, and a fully redundant pump system with a duplicate backup pump and biffy tank to prevent system failure and ensure backflow prevention. Electrical and mechanical infrastructure will be modernized, and new channel drains and wet well cleaning systems will be installed to enhance operational reliability and compliance. All components are designed for durability, safety, and ease of maintenance in a high-risk environment. The work will be executed under the oversight of the Aviation Project Management Group of the Port of Seattle, with Point of Contact Jay Kim serving as the primary liaison and Rishiraj Savita listed as the Project Manager. The contract falls under NAICS code 238110, indicating construction of building contractors for specialized trades, and is publicly forecasted with a posted date of July 31, 2026. No set-aside type has been designated, and while specific performance location details are not provided, the project is expected to occur at a facility managed by the Port of Seattle. All aspects of the project are geared toward achieving operational continuity, regulatory compliance, and enhanced worker safety in a mission-critical infrastructure setting.

Aviation Project Management Group

POSTED

about 7 hours ago

DEADLINE

Concrete Foundations and Anchor Bolts for Sign StructuresThe contract seeks subcontractors to perform excavation, formwork, rebar installation, concrete pouring, and curing services for foundations that support large sign structures, with work governed by industry standards for durability and structural integrity. The scope centers specifically on preparing and constructing robust concrete bases designed to securely anchor sign posts and related infrastructure, ensuring long-term stability under environmental and load stresses. All work must comply with applicable engineering specifications and safety protocols to meet the operational demands of roadside signage systems. Submitted by the Texas Department of Transportation under NAICS code 238110 for site preparation and foundation work, this is a subcontract opportunity with a response deadline of September 3, 2026. While no set-aside provisions or specific geographic location details are provided, the project is tied to infrastructure projects within Texas and requires vendors to meet rigorous quality and timing expectations. Interested parties must review the full solicitation through the provided Texas SmartBuy portal to understand additional technical requirements, compliance obligations, and deliverable expectations before submitting proposals.

Texas Department of Transportation

POSTED

about 8 hours ago

DEADLINE

Concrete Formwork and PlacementThe contract titled Concrete Formwork and Placement encompasses the full scope of forming, reinforcing, and pouring structural concrete for foundations, slabs, and elevated structures, supporting critical infrastructure needs. Work is specifically designated for performance in Warner Robins, Georgia, with a NAICS code of 238110 indicating construction of electrical and structural concrete work. This is a Small Business Set Aside contract under the SBA program, meaning only qualified small businesses are eligible to bid, ensuring opportunities for smaller enterprises within the defense construction sector. The solicitation was posted on August 5, 2026, with proposals due by August 14, 2026, creating a narrow ten-day window for submissions. The contract is classified as a subcontract under the Department of Defense, specifically tied to the FA8501 Opl Contracting AFSC/PZIO entity, suggesting alignment with broader Air Force logistics or facility modernization initiatives. Though no point of contact or detailed agency address is provided, the place of performance and federal sponsorship confirm the project’s strategic importance within defense-controlled infrastructure development.

FA8501 Opl Contracting Afsc/pzio

POSTED

about 12 hours ago

DEADLINE

Concrete Barrier and Median Installation

POSTED

about 12 hours ago

DEADLINE

Concrete Forming and Placement

Oregon State Office

POSTED

about 12 hours ago

DEADLINE

Concrete Forming and PlacementThe contract titled Concrete Forming and Placement involves the complete formation, reinforcement, and pouring of concrete for foundations, slabs, and other structural elements required for construction projects under the Department of Defense. This subcontract, posted on August 5, 2026, requires detailed execution of concrete work in accordance with technical specifications, with all work to be performed at the designated location in San Diego, California, 92136. The North American Industry Classification System code 238110 confirms the scope pertains to foundation, structure, and building exterior contractors. All responses must be submitted no later than September 4, 2026, at 5:00 PM local time, and the project is managed by the Southwest Regional Maintenance Center as part of its broader infrastructure and maintenance responsibilities.

Southwest Regional Maintenance Center

POSTED

about 12 hours ago

DEADLINE

Precast Concrete Structure Supply and Erection

Texas State University System

POSTED

DEADLINE

in about 1 month

Concrete Forming and PlacementThe contract titled Concrete Forming and Placement involves the execution of formwork installation, reinforcement assembly, and the pouring of structural concrete elements for construction projects under the oversight of the Board of Regents of the University System of Georgia. This is a subcontract opportunity with a North American Industry Classification System code of 238110, indicating it falls under the structural concrete contracting category. Work is expected to be performed within Georgia, though specific location details are not provided, and interested parties must submit responses by the deadline of August 25, 2026, at 7:00 PM Eastern Time. The solicitation was posted on August 4, 2026, and all proposals must align with the technical and compliance requirements for structural concrete works as defined by the university system’s standards and practices.

Board Of(university System of Georgia) Regents

POSTED

DEADLINE

More opportunities from Department Of Defense → W076 Endist Little Rock

Same awarding agency

IDIQ Liquid Waste Removal and Disposal Greers Ferry Project

Solicitation # W9127S26QA047

This contract is an Indefinite Delivery Indefinite Quantity (IDIQ) award for liquid waste removal and disposal services at the Greers Ferry Project Office and associated facilities across 13 parks and key sites including the Greers Ferry Powerhouse, William Carl Garner Visitor Center, and multiple lake access points in Heber Springs, Arkansas. The contractor is responsible for providing all personnel, equipment, transportation, supplies, and non-personal services necessary to conduct routine and emergency pumping of holding tanks and vaults, ensuring complete and spill-free evacuation in compliance with federal, state, and local environmental regulations, OSHA standards, and EM 385-1-1 safety protocols. Performance is governed by a detailed Performance Work Statement supported by eleven technical exhibits that define deliverables, sampling procedures, quality assurance surveillance, mileage charts, disposal site distances, security requirements, and inspection criteria. Contract line items specify base and four option periods for 100 normal and 10 emergency 1,500-gallon loads per period, with a minimum guarantee of $5,000 for the base period and no stated ceiling. Payment will be made electronically via SAM in accordance with EFT requirements, and small business subcontractors are eligible for accelerated payments. The work is subject to rigorous quality control and assurance standards, where critical defects trigger payment deductions and non-critical issues are monitored through daily reports, surveillance checklists, and customer complaint records. The contractor must maintain qualified personnel, report any organizational conflicts of interest, safeguard government property including keys and equipment, comply with strict information systems security clauses, and adhere to affirmative action and pay equity mandates including paid sick leave under Executive Order 13706 and DEI discrimination prohibitions. All offerors must represent their small business status under a SBA total set aside, submit UEI information, and comply with postaward reporting obligations. Proposals are due by August 19, 2026, via email as a single PDF, and must include signed provisions and pricing schedules without page limits. The contract allows for option period extensions and includes provisions for contract termination, protest after award, and application of federal law for breach claims.

Septic Tank and Related Services

POSTED

DEADLINE

IDIQ Boundary Maintenance Beaver Lake Project

Solicitation # W9127S26QA039

The Contractor is responsible for providing all necessary labor, equipment, materials, tools, and supplies to clear and mark surveyed boundary lines of Government property around Beaver Lake, with the exception of any items specifically noted otherwise. As part of the service, the Contractor must identify and document any trespass or encroachment activities discovered on Government land and submit detailed reports on a weekly basis. All work is triggered through delivery orders issued by the Government, each tied to a specific Scope of Work that outlines the locations and tasks to be completed using firm fixed-price contract line item numbers. No work may begin until the Contractor formally receives a delivery order from the Contracting Officer, ensuring all activities are authorized and properly scoped prior to commencement. This procurement is structured as an Indefinite Delivery/Indefinite Quantity (IDIQ) contract titled IDIQ Boundary Maintenance Beaver Lake Project, solicited under number W9127S26QA039 with a response deadline of June 11, 2026. The effort is set aside exclusively for small businesses under the SBA’s Total Small Business Set-Aside program, identified by NAICS code 561730. The project is managed by the Department of Defense through the Office of the U.S. Army Corps of Engineers in Little Rock, Arkansas, with point of contact for inquiries provided by Deborah Oswalt and Carole Householder. Performance is expected to occur in the Beaver Lake area, with all work governed by the terms of the delivery orders and associated Scope of Work documents issued by the Government.

Landscaping Services

POSTED

DEADLINE

US Armed Forces Recruiting Lease Renewal - Ft. Smith, AR

Solicitation # W9127REAQR262

The U.S. Government is seeking lease options for approximately 4,000 rentable square feet of retail space in Fort Smith, Arkansas, to establish an Armed Forces Career Center, as its current lease is nearing expiration. The preferred location is within a five-mile radius of Interstate 540, with the Government considering relocation only if it offers economic advantages over renewing the existing lease. The Government requires a full-service lease for a term not to exceed five years and retains the right to terminate the lease early. The space must include non-exclusive, 24/7 on-site parking for fifteen government vehicles and meet all standard Government lease requirements. Relocation costs—including moving expenses, replicating tenant improvements and telecommunications infrastructure, and potential downtime—are being weighed as part of the decision-making process. Interested parties, including building owners or their exclusive representatives, must submit proposals no later than 12:00 PM CST on August 14, 2026. Representatives must provide documentation proving their exclusive right to act on behalf of the property owner, such as an exclusivity agreement or listing contract. This solicitation is classified as a sources-sought notice, aimed at gathering market information to inform future procurement decisions. Proposals should be directed to LaTasha Rideout, Realty Specialist with the U.S. Army Corps of Engineers, Little Rock District, via email or mail, with the solicitation number W9127REAQR262 referenced. The place of performance is confirmed as Fort Smith, Arkansas, with the awarding office located in Little Rock.

Lessors of Nonresidential Buildings (except Miniwarehouses)

POSTED

DEADLINE

Intent to Sole Source, Upgrade Access Control and Intercom System, USACE Emergency Management Office

Solicitation # W9127S26PA054

The U.S. Army Corps of Engineers Little Rock District intends to award a sole-source, Firm-Fixed Price contract to ALARMCO INC for the furnishing, installation, and integration of a new intercom system and upgraded access control readers at the Emergency Management Office within the Federal Office Building in Little Rock, Arkansas. This action is justified under Revolutionary FAR Overhaul 12.102(a), leveraging ALARMCO’s existing role as the original system integrator to ensure seamless compatibility, continued warranty coverage, and operational continuity. The agency requires a cleared contractor with Department of Homeland Security vetting, which ALARMCO has already obtained, making it the only qualified entity to perform this sensitive security work. The contract will be executed under a Small Business Set Aside classification, affirming ALARMCO’s status as a small business capable of meeting the requirement. While this notice is not a solicitation for competitive bids, any responsible source may submit a capability statement or quotation by 12:00 PM CDT on August 12, 2026, to brooke.s.thomason@usace.army.mil for consideration in determining whether future competition is warranted. The solicitation number is W9127S26PA054, and the point of contact for all submissions is Brooke Thomason. The work will be performed at the Federal Office Building in Little Rock, with no specified place of performance beyond the identified site. The notice was posted on July 29, 2026, under the Department of Defense’s Little Rock office, and the action remains classified as a presolicitation with no NAICS code assigned.

Security Systems Services (except Locksmiths)

POSTED

DEADLINE

US AF Hub Recruiting Lease Renewal - North Little Rock, AR

Solicitation # W9127REAQR261

The U.S. Government is seeking a full-service lease for approximately 2,400 rentable square feet of retail space to house an Armed Forces Career Center in North Little Rock, Arkansas, within a ten-mile radius of Highway 167 and McCain Boulevard. The lease term cannot exceed five years and must include government termination rights. The space must accommodate non-exclusive on-site parking for up to six government vehicles available 24 hours a day, seven days a week. The government is evaluating whether relocating to alternate space is economically advantageous, factoring in costs such as physical relocation, replication of tenant improvements and telecommunications infrastructure, and potential downtime. Interested parties, including building owners or exclusively authorized representatives, must provide proof of exclusive representation such as an exclusivity agreement, representation letter, or listing contract with their submission. Responses are due no later than 12:00 PM CST on August 14, 2026, and should be directed to LaTasha Rideout, Realty Specialist at the U.S. Army Corps of Engineers, Little Rock District.

Nonresidential Property Managers

POSTED

DEADLINE

Marine Corps Recruit Depot Initial Outfitting Project

Solicitation # W9127S26QA048

This solicitation, numbered W9127S26QA048, is an 8(a) Small Business Set-Aside for the Marine Corps Recruit Depot Initial Outfitting Project, issued under NAICS code 337127 for Institutional Furniture Manufacturing with a size standard of 500 employees. Offers must be submitted no later than September 1, 2026, at 1600 Eastern Time, and all quotes must comply with the Nonmanufacturer Rule, requiring at least 50 percent of the contract value to consist of end items manufactured or processed by domestic small businesses. Contractors must confirm that all supplied commodities meet this requirement, and if any item lacks a qualified small manufacturer, they must immediately notify the Contracting Officer to seek a waiver before submitting their quote. Failure to comply may result in protest, delay, or cancellation of the award. The acquisition is governed by commercial item clauses including RFO 52.212-4 and its addendum, and the Buy American Act applies. A site visit is scheduled for August 12, 2026, at 1100 Pacific Time, and interested parties should contact Timothy Pighee or Vonda Rogers via email to register. The contractor awarded this contract will be subject to evaluations under the Contractor Performance Assessment Reporting System (CPARS), and must ensure financial stability to absorb potential delays from the broader construction schedule, for which the Government is not responsible. While USACE manages the Initial Outfitting, the IO Contractor is expected to align procurement and delivery timelines with the General Contractor’s schedule to avoid cost overruns and operational disruptions. The Government encourages contractors to exhaust their own resources before seeking financial assistance such as prepayments or interest compensation, though consideration may be given under applicable laws and regulations. All terms and evaluation criteria are outlined in the incorporated provisions, including RFO 52.212-1 and RFO 52.212-2, and no separate written solicitation will be issued. This solicitation is the sole source of information for offerors.

Institutional Furniture Manufacturing

POSTED

DEADLINE

US Armed Forces Recruiting Lease Renewal - Conway, AR

Solicitation # W9127REACQR263

The U.S. Government is seeking proposals for a full-service lease of approximately 3,000 rentable square feet of retail space in Conway, Arkansas, to house an Armed Forces Career Center, with the lease term not exceeding five years and including government termination rights. The space must be located within a five-mile radius of Interstate 40 and Highway 64, and must provide non-exclusive, 24/7 on-site parking for up to eight government vehicles. The current lease is expiring, and the government is evaluating whether relocating to new space is economically advantageous, taking into account costs such as moving, replicating tenant improvements and telecommunications infrastructure, and potential downtime. Respondents must be building owners or their exclusively authorized representatives, who must submit documentation proving their exclusive right to represent the property owner. Proposals are due no later than 12:00 PM CST on August 14, 2026, and inquiries should be directed to LaTasha Rideout, Realty Specialist with the U.S. Army Corps of Engineers, Little Rock District.

Lessors of Nonresidential Buildings (except Miniwarehouses)

POSTED

DEADLINE

Pool 2 Park Cleaning Services Pine Bluff Project Office/Arkansas Post Field Office

Solicitation # W9127S26QA031

The contract entails providing comprehensive park cleaning services across parks and facilities within the Pine Bluff Site Office and Arkansas Post Field Office area, requiring regular inspection, ground policing, and facility cleaning. The contractor is responsible for supplying all necessary personnel, management, supervision, tools, equipment, vehicles, materials, and supplies needed to perform services in full compliance with contract specifications, applicable laws, regulations, and directives. Work must meet established performance standards, with no exceptions unless explicitly stated. The contract structure includes a base period followed by two optional extension periods, allowing for continued service based on performance and funding availability. This is a Small Business Set Aside under NAICS code 561210, issued by the U.S. Army Corps of Engineers through the Department of Defense’s Office in Little Rock, Arkansas. The solicitation number is W9127S26QA031, posted on July 28, 2026, with responses due by August 28, 2026. The primary point of contact is Deborah Oswalt, reachable via email and phone, and the primary place of performance is in the 71611 zip code area. Interested parties must refer to the attached Combined Synopsis/Solicitation for details on the mandatory site visit and full terms. All work must adhere to the requirements outlined in the official documentation referenced in the solicitation.

Facilities Support Services

POSTED

DEADLINE

Excitation System Replacement, Greers Ferry Dam

Solicitation # W9127S26RA071

The U.S. Army Corps of Engineers, Little Rock District, is soliciting proposals for the replacement of the excitation system at Greers Ferry Dam on the Little Red River in Cleburne County, Arkansas, under solicitation number W9127S26RA071. This is a competitive total small business set-aside under NAICS code 335312, with a size standard of 1,250 employees, and is being conducted as a Request for Proposals using the Revolutionary FAR Overhaul framework. The contract will be awarded on a firm-fixed-price basis using the Best Value – Trade Off evaluation method, with an estimated construction value between $1 million and $5 million. The contractor must complete all work within 365 calendar days from the start of performance. All offerors must be registered in the System for Award Management (SAM) and are responsible for regularly monitoring the solicitation site for amendments issued through PIEE/GPE. The contract requires compliance with the Cybersecurity Maturity Model Certification Level 1 (CMMC Level 1 – Self), meaning any contractor or subcontractor information system that processes, stores, or transmits Federal Contract Information must meet this certification standard prior to award. Contractors must submit their CMMC Unique Identifier (UID) from the SPRS database as proof of compliance. The place of performance is designated by ZIP code 72543, and all inquiries should be directed to Shelby Henson at the provided contact information. Proposals are due by August 28, 2026, and the solicitation was posted on July 15, 2026.

Motor and Generator Manufacturing

POSTED

DEADLINE

Excitation System Replacement, Table Rock Dam, White River Basin, Taney County Missouri

Solicitation # W9127S26RA070

The U.S. Army Corps of Engineers, Little Rock District, is soliciting proposals under W9127S26RA070 for the replacement of the excitation system at Table Rock Dam in Taney County, Missouri, with work to be completed within 435 calendar days. This is a competitive total small business set-aside under NAICS Code 335312, Motor and Generator Manufacturing, with a size standard of 1,250 employees, and the estimated construction value falls between $1 million and $5 million. The solicitation is issued under FAR Parts 12 and 15 as a Request for Proposals, using the Best Value – Trade Off method to evaluate submissions, resulting in a firm-fixed price contract. All offerors must be registered in the System for Award Management and are responsible for regularly monitoring the procurement site for amendments issued via PIEE/GPE. Compliance with the Cybersecurity Maturity Model Certification Level 1 is required for any information system that will process, store, or transmit Federal Contract Information, and contractors must submit their CMMC UID issued by SPRS prior to award. The point of contact for inquiries is Shelby Henson, reachable at the provided email and phone number, and the place of performance is at Table Rock Dam with a zip code of 65616. Proposals must be submitted no later than August 21, 2026.

Motor and Generator Manufacturing

POSTED

DEADLINE

Safety and Quality Control OversightThe contract titled "Safety and Quality Control Oversight" involves providing on-site safety monitoring, OSHA compliance, and quality assurance services throughout the duration of a construction project. It is a subcontract opportunity issued by the Department of Defense, specifically through the W076 Endist Little Rock office, with the place of performance located in Fort Smith. The focus of the contract is to ensure adherence to safety regulations and maintain high standards of quality control during construction activities. Classified under NAICS code 541620, which pertains to environmental consulting services, the contract emphasizes proactive management and oversight to prevent workplace incidents and ensure compliance with applicable safety standards. Although some administrative details such as solicitation number and office address are not provided, the core requirements revolve around maintaining a safe working environment and verifying that construction practices meet all regulatory and quality benchmarks. This reflects the Department's commitment to safeguarding personnel and assets while ensuring the successful execution of the construction project.

Environmental Consulting Services

POSTED

DEADLINE

Construction Materials Supply (Concrete, Steel, etc.)This contract involves the supply of essential construction materials including ready-mix concrete, structural steel, and other bulk materials required for construction projects. It is classified as a subcontract under the NAICS code 327320, which pertains to concrete manufacturing. The Department of Defense, specifically the W076 Endist Little Rock office, is the agency overseeing this contract. The materials are intended for use at a location in Fort Smith, indicating the geographic area where the project will be executed. The contract was posted on December 12, 2025, and is aimed at providing critical construction resources to support defense-related infrastructure or projects. While the solicitation number and set-aside status are not specified, the focus on concrete and steel highlights the contract's role in foundational and structural aspects of construction efforts within the Department of Defense's jurisdiction.

Ready-Mix Concrete Manufacturing

POSTED

DEADLINE