Remote Control Slope Mower

The Air Force Test Center, Installation Operational Contracting Division, Eglin AFB, Florida intends to solicit and award a firm-fixed price for two (2) each remote controlled slope mowers. The contractor shall provide all resources, material, equipment, and transportation required to provide a complete remote control mower system meeting the salient characteristics provided in this solicitation. This is a combined synopsis/solicitation for commercial items prepared under Federal Acquisition Regulation (FAR) Subpart 12.6, Streamlined Procedures as supplemented with additional information included in this notice. This announcement for solicitation number FA2823-17-Q-4040 constitutes the only solicitation; offers are being requested and a written solicitation will not be issued. All FAR references are based off of FAC 2005-95, Effective 19 Jan 2017 and include FAC 2005-94 effective 19 Jan 2017. Set-Aside notice. Who Can Participate? This solicitation is a total 100% small business set-aside for concerns eligible under small business program under the associated NAICS code is code is 333112 with a Small Business Size Standard of 1500 Employees. Refer to FAR Clause 52.219-6, Notice of Total Small Business Set-Aside, accessible via the internet at http://farsite.hill.af.mil. NOTE: Funds are not presently available for this effort. An award will be NOT made under this combined synopsis/solicitation until certified funds are available. The Government reserves the right to cancel this combined synopsis/solicitation, before or after the closing date. In the event the Government cancels this solicitation, the Government has no obligation to reimburse an offeror for any costs. Please review this solicitation in its entirety (Note: additional instructions are also included in provision FAR 52.212-1 and Addendum to FAR 52.212-1). Specific offer submission instructions and instructions for submitting questions, responses, exceptions to terms and conditions, amendment acknowledgement, and discrepancies may be referenced at the Addendum to FAR 52.212-1 provided herein. PROVISIONS AND CLAUSES PROVISIONS INCORPORATED BY REFERENCE Reference Description 252.203-7005 Representation Relating to Compensation of Former DoD Officials 252.204-7004, Alternate A System for Award Management 252.204-7011 Alternative Line Item Structure 252.213-7000 Notice to Prospective Suppliers on Use of Past Performance Information Retrieval System-Statistical Reporting in Past Performance Evaluations 252.239-7017 Notice of Supply Chain Risk PROVISIONS INCORPORATED BY FULL TEXT 52.252-1 - Solicitation Provisions Incorporated by Reference (Feb 1998): This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this address: http://farsite.hill.af.mil. (End of Provision) FAR 52.212-1 and Addendum to 52.212-1 - Instructions to Offerors- Commercial Items (Jan 2017) (a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet (SF 1449). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees. (b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show -- (1) The solicitation number; (2) The time specified in the solicitation for receipt of offers; (3) The name, address, and telephone number of the offeror; (4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary; (5) Terms of any express warranty; (6) Price and any discount terms; (7) "Remit to" address, if different than mailing address; (8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically); (9) Acknowledgment of Solicitation Amendments; (10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and (11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration. (c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for until 03 October 2017 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation. (d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing. (e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions, including alternative line items (provided that the alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation), or alternative commercial items for satisfying the requirements of this solicitation. Each offer submitted will be evaluated separately. (f) Late submissions, modifications, revisions, and withdrawals of offers. (1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due. (2) (i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is "late" and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and- (A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or (B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or (C) If this solicitation is a request for proposals, it was the only proposal received. (ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted. (3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel. (4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume. (5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers. Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer (g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror's initial offer should contain the offeror's best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received. (h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer. (i) Availability of requirements documents cited in the solicitation. (1) (i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to-- GSA Federal Supply Service Specifications Section Suite 8100 470 L'Enfant Plaza, SW Washington, DC 20407 Telephone (202) 619-8925) Facsimile (202 619-8978). (ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision. Additional copies will be issued for a fee. (2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites-- (i) ASSIST (https://assist.dla.mil/online/start/ ). (ii) Quick Search (http://quicksearch.dla.mil/). (iii) ASSISTdocs.com (http://assistdocs.com). (3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by- (i) Using the ASSIST Shopping Wizard ( https://assist.dla.mil/wizard/index.cfm ); (ii) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or (iii) Ordering from DoDSSP, Building 4 Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone (215) 697/2197, Facsimile (215) 697-1462. (4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance. (j) Unique entity identifier. (Applies to all offers exceeding $3,500, and offers of $3,500 or less if the solicitation requires the Contractor to be registered in the System for Award Management (SAM) database.) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation "Unique Entity Identifier" followed by the unique entity identifier that identifies the Offeror's name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable. The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for unique entity identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier. (k) System for Award Management. Unless exempted by an addendum to this solicitation, by submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance and through final payment of any contract resulting from this solicitation. If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. Offerors may obtain information on registration and annual confirmation requirements via the SAM database accessed through https://www.acquisition.gov. (l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable: (1) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer. (2) The overall evaluated cost or price and technical rating of the successful and debriefed offeror and past performance information on the debriefed offeror. (3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection. (4) A summary of rationale for award; (5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror. (6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency. Addendum to 52.212-1 - Instructions to Offerors-Commercial Items (Oct 2015) THIS SECTION IS FOR SOLICITATION PURPOSES ONLY. THIS SECTION WILL BE PHYSICALLY REMOVED FROM ANY RESULTANT AWARD, BUT WILL BE DEEMED INCORPORATED BY REFERENCE INTO ANY RESULTANT CONTRACT. Your attention is directed to the functional relationship between FAR 52.212-1, Instructions to Offerors - Commercial Items and FAR 52.212-2 Evaluation - Commercial Items. FAR 52.212-1 provides information for the purpose of organizing and submitting an offer and is not intended to be all-inclusive. FAR 52.212-2 describes evaluation factors and the basis of award, to include the evaluation procedures for responsiveness to the solicitation, ranking of price, and evaluation of non-price factors. PROPOSALS THAT DO NOT CONTAIN THE INFORMATION REQUESTED BY THIS PROVISION RISK ELIMINATION. I. OFFEROR PREPARATION INSTRUCTIONS System for Award Management (SAM): Paragraph (k) of 52.212-1 is revised as follows: By submission of an offer/quotation, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to the date and time established for receipt of Quotations, during performance and through final payment of any contract resulting from this solicitation. If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. Offerors may obtain information on registration and annual confirmation requirements via the SAM database accessed through https://www.sam.gov. Period of Acceptance of offers: Paragraph 52.212-1(c), Period for Acceptance of Quotations. The paragraph is tailored as follows: "The offeror agrees to hold the prices in its quotation firm until 30 September 2017." Delivery Schedule. The delivery date must occur within 90 days of award date. *Note: The requested delivery date is not later than 90 days after receipt of contract/order. If you are unable to deliver within the requested 90 days, please provide an alternate delivery lead time as an inquiry not later than the closing date for submission of questions/inquires stated below. 1. Questions/Inquiries: The contracting officer listed below is the Government's sole point of contact for this acquisition. If necessary, all questions, request for clarifications and/or information concerning this solicitation shall be received in writing by email at the following email addresses no later than Friday, September 8, 2017 1:00 PM CST. The decision whether to respond to questions and requests for clarification made after Friday, September 8, 2017 1:00 PM CST will be at the sole discretion of the Contracting Officer. Questions received timely and subsequent Government responses will be posted to the Government Point of entry system, https://www.fbo.gov/ as an Amendment to this solicitation notice. Offerors are responsible for monitoring FedBizOpps for updates. If no questions are submitted, the Government will assume that the offerors fully understand all requirements of this notice. Emails must be received by the Contracting Officer: Ms. Carrie Eastburn, carrie.eastburn@us.af.mil and Contract Specialist: SrA Nathan McMillen, nathan.mcmillen@us.af.mil on the date and time specified above. Submission of offers: Electronic Submission of offers are required and shall be received via email. Offers shall be received in writing by the following: Contract Specialist, SrA Nathan McMillen at nathan.mcmillen@us.af.mil and the Contracting Officer, Ms. Carrie Eastburn, carrie.eastburn@us.af.mil not later than Wednesday, September 13, 2017, 1:00 PM CST. Offerors shall submit a clear and complete quotation, and include only information that is relevant to this notice. Offer Requirements. The following information at a minimum shall be included with each offer: 1. The name, address, telephone number and email address of the offering firm's point of contact 2. Remittance Address. Remittance Address, if different from the offeror's address 3. Discount Terms (for payments prior to Net 30, if applicable); 4. CAGE Code and DUNS number; 5. Representations/Certifications. Completion of the necessary fill-ins, representations and certifications as set forth in the solicitation; and Teaming Agreement information (if applicable): Subcontractor Name, Cage Code, DUNS number. 6. Technical. In accordance with, FAR 52.212-1(b)(4), Offerors shall provide enough documentation to verify compliance with the required specifications/salient characteristics in this notice. This may include product literature, or other documents, if necessary. 7. Lead Time (if different than stated above in Delivery Schedule) 8. Coordination Instructions. Offeror shall agree to coordinate a date with government POCs to set up equipment (as quoted below) upon delivery for inspection. Coordination shall be arranged before successful delivery of equipment. 9. Price. Offerors shall submit a firm-fixed priced offer for the below Contract Line Item Number, (CLIN) 0001. Offers shall include FOB Destination. Offerors shall provide both the unit price and extended amount (total price) in the below table. CLIN 0001 QTY UNIT Unit Price Extended Amount Remote Control Slop Mowers 2 Each $ $ Salient Characteristics: All products offered shall meet the below outlined characteristics required by the Government. Required Salient Characteristics: - Capable of cutting at least 44-48 inches wide - Capable of adjusting cutting height from 3-5 inches - Weigh between 500-800 pounds with ground preassure less than 2 pounds per square inch - Have at least a 20 Horse Power engine - Fuel capacity of 2-4 gallons - Engine designed to work when on steep terrain - Fuel injection or battery powered - Capable of rotating 360 degrees - Made of metal construction and cutting action has to be a direct driven mulcher operation - Work on slopes of 50 degrees - Have all control of the machine from the wireless remote control at 300 feet to include, Height adjustments, start/stop, emergency stop, travel, speed - Have multiple speed options - Electronic brakes - Capable of operating in 12 inches of water - Have either tracks or aggressive off road tires - All radio receivers and batteries included - All training, maintenance, and operating manuals included - Standard Warranty - Mower deck wings must fold to enable transport of mower on roadway - Adjustable mowing height can be adjusted from 3/4" to 4-1/2" for different applications by changing the spacers on caster wheel spindles 10. Exceptions to Terms and Conditions: Offerors shall identify and explain any exception, deviation, or assumption to the solicitation terms and conditions and provide accompanying rationale. Offerors are cautioned that it is not the Government's intent to incorporate the offeror's proposal in the resulting award. 11. Amendment Acknowledgement. The Government reserves the right to revise or amend the solicitation and attachments prior to the offer closing time. Such amendments will be issued electronically by email. If such amendments require material changes in quantities or prices, the offer closing date may be postponed by enough days to enable offerors to revise their quotations. In such cases, the amendment will include an announcement of the new closing date and time. The offeror MUST acknowledge all amendments issued. Sign, acknowledge, and submit the original amendment for all amendments issued with the offer. 12. Discrepancies. If an offeror believes that the requirements in these instructions contain an error, omission, or are otherwise unsound, the offeror shall immediately notify the Contracting Officer in writing with supporting rationale as well as the remedies the offeror is asking the Contracting Officer to consider as related to the omission or error. The offeror is reminded that the Government reserves the right to award this effort based on the initial proposal, as received, without discussion. 13. Email Format: The subject line of all emails that comprise the quotation shall be formatted as follows: Subject: FA2823-17-Q-4040/Company Name/Email X of X (insert number of the email and total number of emails). (1) File Size. Individual emails shall not exceed 4MB in size. Offerors shall submit multiple emails as necessary to stay under the 4MB limit. Failure to stay under this limit may cause a rejection of the email. (End of Provision) 52.212-3 - Offeror Representations and Certifications - Commercial Items The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at http://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision. (a) Definitions. As used in this provision-- "Administrative merits determination" means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "Arbitral award or decision" means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "Civil judgment" means-- (1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction. (2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "DOL Guidance" means the Department of Labor (DOL) Guidance entitled: "Guidance for Executive Order 13673, - Fair Pay and Safe Workplaces' ". The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces. "Economically disadvantaged women-owned small business (EDWOSB) concern" means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program. "Enforcement agency" means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are-- (1) Department of Labor Wage and Hour Division (WHD) for-- (i) The Fair Labor Standards Act; (ii) The Migrant and Seasonal Agricultural Worker Protection Act; (iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act; (v) 41 U.S.C. chapter 67, formerly known as the Service Contract Act; (vi) The Family and Medical Leave Act; and (vii) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors); (2) Department of Labor Occupational Safety and Health Administration (OSHA) for-- (i) The Occupational Safety and Health Act of 1970; and (ii) OSHA-approved State Plans; (3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for-- (i) Section 503 of the Rehabilitation Act of 1973; (ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and (iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity); (4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and (5) Equal Employment Opportunity Commission (EEOC) for-- (i) Title VII of the Civil Rights Act of 1964; (ii) The Americans with Disabilities Act of 1990; (iii) The Age Discrimination in Employment Act of 1967; and (iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act). "Forced or indentured child labor" means all work or service- (6) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or (7) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties. "Highest-level owner" means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner. "Immediate owner" means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees. "Inverted domestic corporation," means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c). "Labor compliance agreement" means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters. "Labor laws" means the following labor laws and E.O.s: (1) The Fair Labor Standards Act. (2) The Occupational Safety and Health Act (OSHA) of 1970. (3) The Migrant and Seasonal Agricultural Worker Protection Act. (4) The National Labor Relations Act. (5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act. (6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act. (7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity). (8) Section 503 of the Rehabilitation Act of 1973. (9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974. (10) The Family and Medical Leave Act. (11) Title VII of the Civil Rights Act of 1964. (12) The Americans with Disabilities Act of 1990. (13) The Age Discrimination in Employment Act of 1967. (14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors). (15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html). "Labor law decision" means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of "labor laws". "Manufactured end product" means any end product in product and service codes (PSCs) 1000-9999, except- (1) PSC 5510, Lumber and Related Basic Wood Materials; (2) Product or Service Group (PSG) 87, Agricultural Supplies; (3) PSG 88, Live Animals; (4) PSG 89, Subsistence; (5) PSC 9410, Crude Grades of Plant Materials; (6) PSC 9430, Miscellaneous Crude Animal Products, Inedible; (7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products; (8) PSC 9610, Ores; (9) PSC 9620, Minerals, Natural and Synthetic; and (10) PSC 9630, Additive Metal Materials. "Place of manufacture" means t...