This Solicitation opportunity from Texas was posted on June 26, 2025. The submission period has ended. Browse the details below for market research, or find similar active opportunities.

Top

Roof Replacement for Building 550 at San Angelo State Supported Living Center

Closed

HHS0016171State & Local

Submission Closed08/04/2025, 12:00:00 AM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

Active Opportunities Like This One

NAICS: 238160

New

Inland Empire Job Corps-Request for Quote Roof Design & Build

Solicitation # inland-empire-job-corps-request-quote-roof-design-build

Management & Training Corporation is seeking quotes for a fixed-price design-build subcontract to construct an over-build enclosure for the lower roof of Building G at the Inland Empire Job Corps Center in San Bernardino, California. The project involves designing and installing a roof covering approximately 800 gross square feet, featuring a 3% sloped roof with a single ply, EPDM 60 mil roofing system over wood or metal decking. The scope includes structural framing that extends existing bearing walls or utilizes a new post-beam system, the installation of three LED strip light fixtures with one emergency backup, and strict adherence to OSHA safety standards and the Architectural Barriers Act Accessibility Standard of 2007. The total period of performance is 240 days, with a requirement to complete the work within 100 consecutive business days following the Notice to Proceed. Bids are due by November 2, 2026, and will be evaluated based on overall best value. This is a small business set-aside opportunity open to various SBA certifications. For bids equal to or greater than $25,000, a bid bond of 20% of the base bid is required, and the awarded contractor must provide performance and payment bonds from a surety with at least an A- rating. Bidders must conduct a physical site visit and sign an attendance roster to be eligible. The project is subject to Construction Wage Rate Requirements, necessitating compliance with California prevailing wages and the submission of weekly certified payroll reports. Additionally, all inspections and testing must be conducted by an independent, third-party agency registered in California. Required insurance minimums include 1 million dollars per occurrence for general liability, 1 million dollars for auto, and 500,000 dollars for workers compensation.

Inland Empire Job Corps

POSTED

DEADLINE

Flat Roof Replacement Services

Cobb County Board of Education

POSTED

DEADLINE

Roof Waterproofing Installation

Leicester City Council

POSTED

DEADLINE

Roofing and Flashing Contractor

Capital Buildings Projects

POSTED

DEADLINE

Roofing and Flashing Installation

Capital Buildings Projects

POSTED

DEADLINE

Residential Roofing Installation

POSTED

DEADLINE

Roofing Tear-off and Debris Removal

Mitchell County Board of Commissioners

POSTED

DEADLINE

PVC Single-Ply Roofing Installation

Mitchell County Board of Commissioners

POSTED

DEADLINE

Solicitation # 47971 - C

Solicitation 47971-C, issued by the New York State OGS Design and Construction, seeks a contractor for the replacement of the roof and associated mechanical systems at the Troop F Headquarters located at 55 Crystal Run Road, Middletown, New York. The scope of work encompasses the full replacement of the roof and its accessories, the installation of new HVAC and mechanical systems, and interior work involving reflected ceiling plans, including necessary removals and abatement. The project is categorized under NAICS code 238160 and was posted on October 16, 2026, with a response deadline of November 18, 2026. All work must be performed in strict accordance with local codes, regulations, and the provided technical drawing set, which includes site staging plans and design notes. Key performance requirements include installing all materials and finishes per manufacturer recommendations and ensuring all penetrating heavy-duty fasteners meet a minimum grade of M6. The contractor is responsible for the final inspection of roof trusses, sheathing, tiles, gutters, downspouts, and the storm drainage system to verify compliance with design specifications. Safety and zone differential regulations of the local code, as well as National Voyage Plan standards for fire and lighting safety, govern the execution of the project.

NYS OGS Design & Construction - Construction Contractors

POSTED

DEADLINE

Solicitation # 47971 - C

Solicitation 47971-C is a construction project issued by the New York State OGS Design and Construction for the replacement of the roof and associated mechanical systems at the Troop F Headquarters in Middletown, New York. The scope of work encompasses comprehensive architectural, electrical, and structural modifications, including the removal of specific skylights and roof framing, the application of various waterproof and general surface finishes, and abatement work related to the first-floor reflected ceiling plan. Electrical requirements include the installation of keyed systems, the relocation of equipment for HVAC engineers, and the installation of permanent conductive fiber optic cables. The contractor is responsible for providing all necessary tools, equipment, and materials, as well as procuring all permits required for the final certificate of occupancy. All work must adhere to applicable building codes, local safety and zone differential regulations, and manufacturer recommendations. Key deliverables include the final inspection of roof trusses, sheathing, tiles, gutters, downspouts, and storm drainage systems, with final acceptance of the fastening system requiring written approval from the Owner and Architect. The solicitation was posted on October 16, 2026, with a response deadline of November 18, 2026.

NYS OGS Design & Construction - Construction Contractors

POSTED

DEADLINE

Firestopping & Smoke Sealing

242-NETWORK Contract Office 02 (36C242)

POSTED

DEADLINE

Commercial Roofing Replacement (Building 51)This SDVOSB set-aside subcontract involves the complete removal and replacement of a 56,000 square foot roof system at Building 51 of a Department of Veterans Affairs medical facility in St. Louis. The scope of work includes the installation of new roofing, projections, and entrance roofs, culminating in the delivery of a leak-free system backed by a 20-year NDL warranty and comprehensive as-built record drawings in PDF and CAD formats. Because the project takes place within an occupied 24/7 healthcare environment, the contractor must strictly implement phasing plans, infection control measures, and HVAC-intake protection. This project is managed under the 255-NETWORK Contract Office 15 and falls under NAICS code 238160.

255-NETWORK Contract Office 15 (36C255)

POSTED

about 8 hours ago

DEADLINE

in 11 days

AI Contract Overview

The contract involves the selection of a qualified general contractor through a competitive sealed proposal process to perform roofing replacement and related construction services at Building 550 within the San Angelo State Supported Living Center, managed by the Texas Health and Human Services Commission. The scope encompasses installing a new 72-mil PVC membrane over existing roof components, including coverboard, insulation, vapor retarders, and sheet metal flashings, gutters, and fascia. The project also requires replacing three roof trusses and repairing decking, with all work adhering to design drawings, specifications, and applicable building codes. The estimated construction cost is approximately $148,000, and the project is scheduled to commence around October 6, 2025. The owner emphasizes strict compliance with procurement procedures, including mandatory site visits, optional pre-proposal webinars, and detailed submission requirements, with proposals due by August 4, 2025. The procurement process is governed by Texas state laws and regulations, with evaluation criteria weighted heavily on pricing (40%), construction experience and capability (30%), and proposed methodology (25%), alongside safety programs and other qualitative factors. The contract will be awarded based on the best value to the state, not solely on lowest bid, with the potential for interviews and best-and-final offers. The contract will be a fixed-price agreement under the Owner’s standard general construction contract, incorporating Texas-specific general conditions and supplementary provisions. The legal framework specifies that all disputes are subject to Texas law, with venue in Travis County, and includes provisions for force majeure delays and prompt refunding of any erroneous payments. Respondents must submit comprehensive proposals in strict accordance with the detailed instructions, including exhibits covering affirmations, safety, pricing, and HUB subcontracting plans, with the process designed to ensure transparency, fairness, and adherence to state procurement policies.

General Info

Agency

Texas Health & Human Services Commission

NAICS

238160 - Roofing Contractors

Place of Performance

TX, USA

Set-Aside

NONE

Documents

RFP HHS0016171 Roof Replacement for Building 550

27 pages · rfp

High

ESBD_431007_1750866636542_HHS0016171_Exhibits.zip

ESBD_431007_1750866670324_HHS0016171_Attachments.zip

AI Contract Breakdown

Uniform Contract Format

BSupplies or Services and Prices/Costs

DPackaging and Marking

EInspection and Acceptance

GContract Administration Data

KRepresentations, Certifications, and Other Statements of Offerors or Respondents

Timeline

PhaseClosed

PostedJun 26

Solicitation

Response DeadlineAug 4

Deadline has passed

Submission Closed

08/04/2025, 12:00:00 AM UTC

Find active opportunities like this

Get full access to discover similar active contracts, track opportunities, and build proposals with AI assistance.

Organization & Contact Information

AgencyTexas Health & Human Services Commission

Contacts1 person available

OfficeN/A

Organization / AgencyTexas Health & Human Services Commission

Office AddressN/A

Contacts

David Moran

contact@example.gov

+1 (555) 000-0000

Full Description

Introduction The Health and Human Services Commission (“Owner”), for and on behalf of its Health and Specialty Care System Division (“HSCS”), is soliciting Competitive Sealed Proposals (“Proposals”) for selection of a General Contractor (“Contractor”) to provide general construction and construction administration services to the Owner for Project No. 24-125-SGL, Roof Replacement for Building 550 at San Angelo State Supported Living Center (the “Project”), in accordance with the terms, conditions, and requirements set forth in this Solicitation. Project Location, Summary, and Budget Project Location: San Angelo State Supported Living Center 11640 N US Hwy 87, Building 550Carlsbad, TX, 76934 Project Summary: The Scope of Work includes, but is not limited to, the following: Furnish and install a new 72-mil ‘Feltback’ fully adhered PVC membrane over new coverboard, insulation, and vapor retarder, with new PVC flashings and new sheet metal (fascia metal, perimeter metal, gutters, downspouts, counter-flashings, etc.) as shown per deck assemblies on drawings. Replace three trusses and repair decking. Perform all work as specified in accordance with the design drawings, specifications, and governing building codes. Include installation of roof access scaffolding for the duration of the construction project. Project Estimate: The approximate cost for construction of the Project is $148,000.00. Optional Pre-Proposal Webinar HHSC will conduct one (1) optional pre-proposal webinar that will be held at the date and time described below. Attendance at the pre-proposal webinar is optional. July 9, 2025, at 2:00 p.m. Central TimePlease register at: https://attendee.gotowebinar.com/register/6813798250188487260 After registering, you will receive a confirmation email containing information about joining the webinar. Mandatory Facility Site Visit and Walk Through Logistical InformationAll Respondents are required to attend one Facility Site Visit as specified in Section 2.2 (Schedule of Events). Failure to attend in person will result in the disqualification of a Respondent. Proposals received from Respondents not listed on the attendance log will not be considered. Potential Respondents must be prepared to complete one of the scheduled tours; additional tours will not be offered. Site Visit No. 1:July 10, 2025, at 10:00 a.m. Central Time Pre-registration is requested to allow for space accommodations.Please register for the site visit at: https://forms.office.com/r/nUV34AT3sV Site Visit No. 2:July 11, 2025, at 10:00 a.m. Central TimePre-registration is requested to allow for space accommodations.Please register for the site visit at: https://forms.office.com/r/Vpb7k4jQKs Refer to Section 2.1 (Project Location, Summary, and Budget), of the RFP, for a physical address of Project location. See Exhibit H, Site Visit Map for Site Visit parking and check in logistics. Park in the area indicated and meet in the Maintenance building (B681). Schedule of Events Event Date/Time Issuance of the RFP (Date of Release) June 26, 2025 Optional Pre-Proposal Webinar July 9, 2025, at 2:00 p.m. Central Time Mandatory Site Visit #1 July 10, 2025, at 10:00 a.m. Central Time Mandatory Site Visit #2 July 11, 2025, at 10:00 a.m. Central Time Deadline for Submitting Questions July 15, 2025, by 3:00 p.m. Central Time Deadline for Courtesy HSP Review July 22, 2025, by 2:00 p.m. Central Time Deadline for Submission of Proposals (Note: Proposals MUST be received by Owner by the deadline.) August 4, 2025, by 10:30 a.m. Central Time Deadline for Submission of HSP (Note: HSPs MUST be received by Owner by the deadline.) August 5, 2025, by 10:30 a.m. Central Time Opening of Proposals - Proposals will be publicly opened by Webinar at the date and time specified. Webinar Link is: https://register.gotowebinar.com/register/2528295550280599129. Respondents’ pricing information will be sent by email to all respondents and attendees of the public opening. August 6, 2025, at 10:00 a.m. Central Time Anticipated Notice of Award September 8, 2025 Anticipated Contract Start Date October 6, 2025