Travel Trailer Purchase

1. This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in FAR Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; proposals are being requested and a written solicitation will not be issued. 2. This solicitation is for a firm fixed price for one Travel Trailer and components as listed in the "Trailer Specifications" for USDA APHIS WILDLIFE Services, Sacramento CA. Quoted price shall include all components and delivery of trailer. 3. This solicitation document has incorporated provisions and clauses that are in effect through Federal Acquisition Circular FAR FAC 2005-97 January 24, 2018. 4. This solicitation has been set-aside and the associated NAICS code 336214 and small business size standard. Product Service Code 2330. 5. Trailer Specifications: Approximate usable Square Feet 222 - Must meet the following standard criteria: Hitch Weight 523pounds GVWR 7,400 Cargo (Gross) 2,078 Exterior Length (Overall) 28' 5" Exterior Height 131" Exterior Width 97" Exterior Width (Slides Out) 135" Fresh Water (Gal.) 52 Gray Water (Gal.) 29 Waste Water (Gal.) 29 LP Capacity (LBS) 40 Tire Size 15" Radial Awning Size 15' Request to have the following included: ULTRA PACKAGE - 26" Full Width Entry Doors (2), Dometic Brisk II 13.5k BTU Air Conditioner w/"Quick Cool" Feature (Main A/C), Enclosed Underbelly, LP Quick Connect, No Reveal "Automotive Style" Baggage Doors (Exclusive), Prepped for Observation Camera, Solera Power Awning w/LED Light and Integrated Speakers, Furrion DV5600 Entertainment System, Furrion LED TV, LED Interior Can Lighting, Lino Throughout Unit (No Carpet), Pressed Membrane Countertops Throughout w/Surf(X), Push Back Recliners (2710RL), Residential Dinette Light, Skylight(s) -- Kitchen & Bath, Slider Windows in Slide Room End Walls, ATWOOD 18 GPH Quick Recovery Gas/Electric Water Heater, Radius Corner Shower w/Glass Doors (2604,2710) 15,000BTU CENTRAL A/C UNIT keeps you cool in the hotter months and climates! CUSTOMER CONVENIENCE PACKAGE - 15" Aluminum Wheels, 3/4 Front Cap, Black Tank Flush System, Heated & Enclosed Dump Gate Valves, Power Tongue Jack, Purpose-Built Sink Cover/Cutting Board, Spare Tire Carrier and Cover, Thermal Package 6. Place of delivery: This item may change and pick up may be arranged. (pending and will be announced in an amendment) USDA APHIS Wildlife Services Attn: John Turman 3419A Arden Way Sacramento, CA 95825 7. The Government will adhere to FAR 52.212-2 Evaluation-Commercial Items (Oct 2014). a) Award will be made to the responsible quoter representing the Lowest?Priced Technically Acceptable (LPTA) quote. Quotes will be evaluated in accordance with FAR Part 13 Simplified Acquisition Procedures. Each technical evaluation factor must be found to be "acceptable" in order for the quotation to be found technically acceptable. Quotes will not be ranked. Missing, incomplete, or ambiguous information may result in a rating of "unacceptable" for that factor. Evaluation factors are listed below: (i) Price (ii) Product Conformance to Specifications. The proposed product will receive a rating of "acceptable" or "unacceptable". The product must conform to all specification requirements to receive an "acceptable" rating. 8. Interested vendors shall submit the completed pricing and the confirmation with a completed copy of the provision FAR 52.212-3, Offeror Representations and Certifications -- Commercial Items with offer. 9. FAR 52.212-4, Contract Terms and Conditions -- Commercial Items, applies to this acquisition and a statement regarding any addenda to the clause. 10. FAR 52.212-5, Contract Terms and Conditions Required To Implement Statutes Or Executive Orders -- Commercial Items, applies to this acquisition and a statement regarding which, if any, of the additional FAR clauses cited in the clause are applicable to the acquisition. 11. Requested due date for completion will be pending on all materials availability. 12. ANY QUESTIONS PERTAINING TO THIS Request for Quotes (RFQ) SHALL BE DIRECTED TO TOM WESLEY, BY EMAIL TO thomas.j.wesley@aphis.usda.gov no later than 2 days before quotes are due. RFQ return date Thursday, 27th December 2018, 3:30 P.M. CST. No late submissions will be accepted. 13. Because the synopsis and solicitation are contained in a single document, it is not necessary to publicize a separate synopsis 15 days before the issuance of the solicitation. 14. YOU MAY EMAIL YOUR QUOTE DIRECTLY TO TOM WESLEY before the time specified on the solicitation. Send quotes to: thomas.j.wesley@aphis.usda.gov CLAUSES BY REFERENCE: 52.204-18 - Commercial and Government Entity Code Maintenance (Jul 2016) 52.212-4 - Contract Terms and Conditions -- Commercial Items (Oct 2018) 52.232-1 - Payments (Apr. 1984) 52.232-40 - Providing Accelerated Payments to Small Business Subcontractors (Dec 2013) 52.243-1 - Changes -- Fixed Price (Aug 1987) CLAUSES IN FULL TEXT 52.252-2 - Clauses Incorporated by Reference (Feb 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address (es): www.acquisition.gov or http://farsite.hill.af.mil/ (End of Clause) 52.212-5 -- Contract Terms and Conditions Required to Implement Statutes or Executive Orders -- Commercial Items (Oct 2018) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91). (3) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015) (4) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553). (5) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77, 108-78 (19 U.S.C. 3805 note)). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] ___ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402). ___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509). ___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009). __X_ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2018) (Pub. L. 109-282) (31 U.S.C. 6101 note). ___ (5) [Reserved] ___ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). ___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). ___ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (31 U.S.C. 6101 note). ___ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) (41 U.S.C. 2313). ___ (10) [Reserved] ___ (11) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a). ___ (ii) Alternate I (Nov 2011) of 52.219-3. ___ (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a). ___ (ii) Alternate I (Jan 2011) of 52.219-4. ___ (13) [Reserved] _X__ (14) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644). ___ (ii) Alternate I (Nov 2011). ___ (iii) Alternate II (Nov 2011). ___ (15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644). ___ (ii) Alternate I (Oct 1995) of 52.219-7. ___ (iii) Alternate II (Mar 2004) of 52.219-7. ___ (16) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C. 637(d)(2) and (3)). ___ (17) (i) 52.219-9, Small Business Subcontracting Plan (Aug 2018) (15 U.S.C. 637 (d)(4)). ___ (ii) Alternate I (Nov 2016) of 52.219-9. ___ (iii) Alternate II (Nov 2016) of 52.219-9. ___ (iv) Alternate III (Nov 2016) of 52.219-9. ___ (v) Alternate IV (Aug 2018) of 52.219-9. ___ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)). ___ (19) 52.219-14, Limitations on Subcontracting (Jan 2017) (15 U.S.C. 637(a)(14)). ___ (20) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). ___ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657f). _X__ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)). ___ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)). ___ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)). _X__ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755). _X__ (26) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan 2018) (E.O. 13126). _X__ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). _X__ (28) (i) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246). ___ (ii) Alternate I (Feb 1999) of 52.222-26. ___ (29) (i) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212). ___ (ii) Alternate I (July 2014) of 52.222-35. ___ (30) (i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). ___ (ii) Alternate I (July 2014) of 52.222-36. ___ (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212). ___ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). _X__ (33) (i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627). ___ (ii) Alternate I (Mar 2015) of 52.222-50, (22 U.S.C. chapter 78 and E.O. 13627). ___ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) ___ (35) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ___ (36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O.13693). ___ (37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693). ___ (38) (i) 52.223-13, Acquisition of EPEAT -Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514 ___ (ii) Alternate I (Oct 2015) of 52.223-13. ___ (39) (i) 52.223-14, Acquisition of EPEAT -Registered Television (Jun 2014) (E.O.s 13423 and 13514). ___ (ii) Alternate I (Jun 2014) of 52.223-14. ___ (40) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b). ___ (41) (i) 52.223-16, Acquisition of EPEAT -Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514). ___ (ii) Alternate I (Jun 2014) of 52.223-16. _X__ (42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011) (E.O. 13513). ___ (43) 52.223-20, Aerosols (Jun 2016) (E.O. 13693). ___ (44) 52.223-21, Foams (Jun 2016) (E.O. 13696). ___ (45) (i) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a). ___ (ii) Alternate I (Jan 2017) of 52.224-3. _X__ (46) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83). ___ (47) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43). ___ (ii) Alternate I (May 2014) of 52.225-3. ___ (iii) Alternate II (May 2014) of 52.225-3. ___ (iv) Alternate III (May 2014) of 52.225-3. ___ (48) 52.225-5, Trade Agreements (Aug 2018) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). _X__ (49) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). ___ (50) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). ___ (51) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150). ___ (52) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). ___ (53) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505), 10 U.S.C. 2307(f)). ___ (54) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)). _X__ (55) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (Oct 2018) (31 U.S.C. 3332). ___ (56) 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management (Jul 2013) (31 U.S.C. 3332). ___ (57) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332). ___ (58) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a). ___ (59) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(12)). ___ (60) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). ___ (ii) Alternate I (Apr 2003) of 52.247-64. ___ (iii) Alternate II (Feb 2006) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] ___ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495) ___ (2) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter 67.). ___ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). ___ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (Multiple Year and Option Contracts) (Aug 2018) (29 U.S.C.206 and 41 U.S.C. chapter 67). ___ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). ___ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67). ___ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67). ___ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O. 13658). ___ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706). ___ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). (d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509). (ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (iii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91). (iv) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (v) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (1) of FAR clause 52.222-17. (vi) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). (vii) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246). (viii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212). (ix) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). (x) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212). (xi) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (xii) 52.222-41, Service Contract Labor Standards (Aug 2018), (41 U.S.C. chapter 67). (xiii) (A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627). (B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 E.O. 13627). (xiv) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.) (xv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67) (xvi) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989). (xvii) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015). (xviii) 52.222-62, Paid sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706). (xix) (A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a). (B) Alternate I (Jan 2017) of 52.224-3. (xx) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). (xxi) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (xxii) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. (End of Clause) SOLICITATION PROVISIONS INCLDUED BY REFERENCE 52.204-16 - Commercial and Government Entity Code Reporting. (Jul 2016) 52.212-1 - Instructions to Offerors - Commercial Items (Oct 2018) 52.216-1 Type of Contract (Apr 1984) 52.237-1 - Site Visit (Apr 1984) 52.237-2 Protection of Government Buildings, Equipment, and Vegetation (Apr 1984) INCLUDED BY FULL TEXT 52.252-1 - Solicitation Provisions Incorporated by Reference (Feb 1998) This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): http://farsite.hill.af.mil/ (End of Provision) 52.212-2 Evaluation-Commercial Items. (Oct 2014) a) Award will be made to the responsible quoter representing the Lowest?Priced Technically Acceptable (LPTA) quote. Quotes will be evaluated in accordance with FAR Part 13 Simplified Acquisition Procedures. Each technical evaluation factor must be found to be "acceptable" in order for the quotation to be found technically acceptable. Quotes will not be ranked. Missing, incomplete, or ambiguous information may result in a rating of "unacceptable" for that factor. Evaluation factors are listed below: (i) Price (ii) Product Conformance to Specifications. The proposed product will receive a rating of "acceptable" or "unacceptable". The product must conform to all specification requirements to receive an "acceptable" rating. (End of provision) 52.212-3 Offeror Representations and Certifications-Commercial Items (Jan 2017) The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) website located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision. (a) Definitions. As used in this provision- "Administrative merits determination" means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "Arbitral award or decision" means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "Civil judgment" means- (1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction. (2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "DOL Guidance" means the Department of Labor (DOL) Guidance entitled: "Guidance for Executive Order 13673, - Fair Pay and Safe Workplaces'". The DOL Guidance was initially published in the Federal Register on August 25, 2016, and significant revisions will be published for public comment in the Federal Register. The DOL Guidance and subsequent versions can be obtained from www.dol.gov/fairpayandsafeworkplaces. "Economically disadvantaged women-owned small business (EDWOSB) concern" means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program. "Enforcement agency" means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are- (1) Department of Labor Wage and Hour Division (WHD) for- (i) The Fair Labor Standards Act; (ii) The Migrant and Seasonal Agricultural Worker Protection Act; (iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act; (iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act; (v) The Family and Medical Leave Act; and (vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors); (2) Department of Labor Occupational Safety and Health Administration (OSHA) for- (i) The Occupational Safety and Health Act of 1970; and (ii) OSHA-approved State Plans; (3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for- (i) Section 503 of the Rehabilitation Act of 1973; (ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and (iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity); (4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and (5) Equal Employment Opportunity Commission (EEOC) for- (i) Title VII of the Civil Rights Act of 1964; (ii) The Americans with Disabilities Act of 1990; (iii) The Age Discrimination in Employment Act of 1967; and (iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act). "Forced or indentured child labor" means all work or service- (6) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or (7) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties. "Highest-level owner" means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner. "Immediate owner" means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees. "Inverted domestic corporation", means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c). "Labor compliance agreement" means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters. "Labor laws" means the following labor laws and E.O.s: (1) The Fair Labor Standards Act. (2) The Occupational Safety and Health Act (OSHA) of 1970. (3) The Migrant and Seasonal Agricultural Worker Protection Act. (4) The National Labor Relations Act. (5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act. (6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act. (7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity). (8) Section 503 of the Rehabilitation Act of 1973. (9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974. (10) The Family and Medical Leave Act. (11) Title VII of the Civil Rights Act of 1964. (12) The Americans with Disabilities Act of 1990. (13) The Age Discrimination in Employment Act of 1967. (14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors). (15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html). "Labor law decision" means an administrative merits determination, arbitral award or decision, or civil judgmen...