5th Floor East Courtroom Repairs & Alterations - Charles L. Brieant Jr. Court House in White Plains, NY

This Amendment No. 0001 is being issued to: i) Add Requirements of Joint Venture Offerors in Section II Proposals to the solicitation; ii) Add Evaluation of Joint Ventures in Section VI Method Of Award to the solicitation; iii) To change Section I.C. Authorized Representatives of the solicitation; iv) re-issue Option 1 AV & SOW as originally uploaded document had display errors; v) issue revised Attachment C-Key Personnel Qualifications Resume Form; vi) to provide Price Breakdown Microsoft Excel Format to be submitted in the price proposal package; vii) to provide clarifications to inquiries raised during site visits by prospective offerors on this procurement; and to provide response to RFIs received. Please see attached Amendment 0001 for details. ________________________________________________________________________________________________________ THIS IS A SOLICITATION. The General Services Administration, Region 2, Public Buildings Service, intends to issue a Request for Proposal (RFP) # TBD, for a Design-Build Services to renovate the 5th floor District Courtroom Suite 521 at Charles L. Brieant Jr. Court House. The Honorable Charles L. Brieant Jr. Federal Building and Courthouse is a United States Federal Office Building and Courthouse located at 300 Quarropas Street in downtown White Plains, New York. It is a 6-story building mainly comprised of brick and stone and o'icially opened in 1995. It is named for Charles L. Brieant Jr., a former federal judge at the White Plains courthouse who also practiced lawv and was involved in politics in Westchester County. The United States District Court for the Southern District of New York (SDNY) hears cases in the courthouse. The Courthouse serves six county areas: Westchester, Rockland, Putnam, Orange, Dutchess and Sullivan Counties with a population of over 1.8 million people. Both U.S. District Judges and U.S. Magistrate Judges preside over cases filed at the White Plains Courthouse. The GSA, on behalf of the United States District Court for the Southern District of New York, is seeking Design-Build Services to renovate the 5th floor District Courtroom Suite 521. The space is approximately 3,100 square-feet. The Design-Build (DB) Contractor shall provide any and all labor, material, equipment, and professional services to plan, design and construct the renovations of the 5th Floor East Courtroom. Minimum objectives for this project include, but are not limited to the following: Using Design Intent Drawings (DIDs) and reference materials, the DB Contractor shall develop comprehensive construction documents, specifications, plans, and details to include but not limited to; architectural plans, reflected ceiling plans with elevations, electrical modifications, audio/visual, security, telephone & data provisions, furniture plans, signage plans, millwork plans, security plans, and finish plans. The DB Contractor shall then complete selective demolition work and construct the space as indicated in construction drawings submitted by the DB Contractor and approved by the GSA. A key objective of this renovation is to match the renovations & finishes with recently completed renovations on the 6th Floor East and West Courtrooms. The DB Contractor will be provided with reference documentation and access to other courtrooms to facilitate this project. Field conditions between 5th floor and 6th floor may differ; the DB Contractor shall be responsible to examine field conditions as part of design services to ensure renovations of 5th floor East Courtroom meet the objectives of this project. Construction documents shall be tailored specifically for renovations to the 5th floor East Courtroom with close coordination from project stakeholders. Utmost attention shall be given to the finishes and craftmanship of the courtroom renovations to include, but not limited to, wood species, stain color, veneer cut, carpet and ceiling tiles. Renovations shall provide underlying infrastructure to modernize the courtroom to include necessary trenching and penetrations for IT and AV equipment. Each IT and AV equipment shall have dedicated homerun conduits to/from terminations with pull strings for cable installation. An IT & AV designer shall be an integral part of the DB Contractor'sConstruction Documents for IT & AV equipment installation for approval as part of DB Contractor design services prior to construction. Electrical distribution shall be modified as required to accommodate new layout to include new receptables and wiring. Option Work: Furnishing and installation of AV wiring, terminations, and end-user equipment. AV equipment must be installed after base contract infrastructure is installed and, in a dust-free environment. This option may be exercised at the end of the project at the discretion of the GSA and SDNY. Period of Performance: All Base Bid Work and Option Work (if awarded) must be Substantial Complete no later than four hundred & forty-eight (448) calendar days after the Notice of Award is issued. A Final Inspection will be performed after all work is complete to the satisfaction of GSA and SDNY. The Substantial Completion Date will be established by the Contracting Officer after the Contracting Officer's Representative (COR) verifies that the project objectives have been met, and warranties, certifications, testing reports, and related documents indicating project completion has been received. TYPE OF SET-ASIDE: 100% Total Small Business set-aside. TYPE OF CONTRACT AND NAICS: This RFP is for one (1) Firm-Fixed-Price (FFP) contract. The North American Industrial Classification System Code (NAICS) for this procurement is 236220 - Commercial and Institutional Building Construction with a size standard of $39.5 Million. SELECTION PROCESS: The proposals will be evaluated using a Best Value Trade Off source selection process. The technical information contained in the O'eror's proposal will be reviewed, evaluated, and rated by the Government. The proposal for this procurement, at a minimum, will consist of the following: Experience, Past Performance, Staffing Plan, and price. Pro Forma Information such as bonding and financial capability is also required to meet the minimum requirements of the solicitation. All evaluation factors, other than price, when combined, are considered equal to price. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $1,000,000.00 and $5,000,000.00 in accordance with FAR 36.204. DISCUSSIONS: The Government intends to award without discussions, but reserves the right to conduct discussion should it be deemed in the Government's best interest. To be eligible for any federal contract award, a firm must be registered in the System Award Management (SAM) at http://www.sam.gov.