AIRCRAFT COMPONENTS AND ACCESSORIES (HC27J

FAC 2021-02 EFFECTIVE 23 November 2020 Date: 12/09/2020 Year: 2020 Contracting Office Zip Code: 27909-5001 Classification Code: 16 - Aircraft Components & Accessories Contracting Office Address: USCG, ALC, MRS, Elizabeth City, NC 27909-5001 Subject: Aircraft Parts and Accessories Proposed Solicitation Number: 70Z03821QW0000031 Closing Response Date: 12/21/2020 Primary Point of Contact: Denise Coley Contract Award and Solicitation Number: To be assigned at time of award 70Z03821QW0000031 Contract Line Item Number(s): 3 Description: Aircraft Parts and Accessories Set-aside Status: TOTAL SBSA This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Federal Acquisition Regulation (FAR) Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotes are being requested and a written solicitation will not be issued. This Request for Quote (RFQ) 70Z03821QW0000031 incorporates provisions and clauses in effect through Federal Acquisition Circular AUG 2020. The applicable North American Industry Classification Standard (NAICS) Code is 336413. The small business size standard is 1,250 employees. This requirement consists of the following spare parts utilized on the HC144 USCG aircraft. All or none. ****ATTENTION ALL VENDORS QUOTING RFQ 70Z03821QW0000031: MUST STATE YOU HAVE PROVING STOCK ON HAND. MUST BE AN OEM DISTRIBUTOR OF 53117. NSN: 1560-01-525-9586, WINDSHIELD, P/N NP-1091-01-8, QTY 2 EACH. NSN: 1560-15-202-6168, GLASS, LH LAM NO 3 L, P/N NP-1091-03-1, QTY 2 EA. NSN: 1560-15-202-6172, GLASS, LH, LAM6UPREAR, P/N NP-1091-06-11, QTY 2 EA. Offerors should include the following: NSN, PART NUMBER, NOMENCLATURE, UNIT PRICE, EXTENDED PRICE, DISCOUNTS, DELIVERY TIME, WARRANTY (IF APPLICABLE), FOB POINT, CAGE CODE, DUNS NUMBER, BUSINESS SIZE, MINORITY CLASSIFICATION (IF APPLICABLE), FACTORY NEW. MUST STATE TRACEABLE TO THE OEM. The United States Coast Guard (USCG) anticipates award of a Firm-Fixed Price Purchase Order to the Original Equipment Manufacturer (OEM), or a distributor that can provide documented traceability for the components. The United States Coast Guard (USCG) anticipates award of a Firm-Fixed Price Purchase Order to the Original Equipment Manufacturer (OEM), or a distributor that can provide documented traceability for the components. Award will be made to the offeror quoting the lowest price technically acceptable to the USCG. All responsible sources may submit a quote which shall be considered by the USCG. Only new items are acceptable. Reconditioned or used items are not acceptable. Offerors must be able to provide necessary certification including traceability to the OEM and provide a Certificate of Conformance (COC) to ensure parts are in airworthy condition, suitable for installation on USCG aircraft. Prospective vendors who are not the OEM must provide traceability for the materials. Traceability means a clear, complete, documented, auditable paper trail which traces each step from an OEM or distributor to its current location. Required delivery schedule is IN STOCK or less after receipt of order. The offerors shall propose a delivery schedule. All requests for time extension shall be in writing and shall include substantiation of the need for such time extension in accordance with FAR 52.212-4 (f), Excusable delays. If nonperformance is not covered by an excusable delay, the Contractor and the Contracting Officer shall negotiate consideration for the approval of the extended delivery date at which time a modification will be issued to reflect the consideration and extension. Drawings or specifications are not available and cannot be furnished by the Government. F.O.B. Destination is requested as the FOB point for Deliverables. Quotes submitted offering F.O.B. Origin should include estimated shipping charges to the USCG. Partial and early deliveries are acceptable if at no additional cost to the USCG. The offeror shall furnish a Certificate of Conformance (COC) in accordance with FAR clause 52.246-15. Certificate of Conformance must be submitted in the format specified in the clause. Packaging, Marking and Preservation The offeror shall comply with ASTM D3951-10 (August 01, 2011), Standard Practice for Commercial Packaging. Packaging, packing, and preservation shall be in accordance with best commercial practices to enable shipment to destination and transshipment to USCG units without repackaging or incurring damage during shipment and handling. Items shall be individually packaged and labeled. Packaging material shall not consist of the following: popcorn, shredded paper, Styrofoam of any type, or peanut packaging. The internal packaging material shall be sufficient to prevent damage during shipment, handling, and storage. Preservation protection must be sufficient to prevent corrosion, deterioration, or decay during warehouse storage. Also, The Forms should be "attached to or included with the part and a copy placed on the outside of the shipping container". Packing Slip At the time of delivery of supplies, the offeror shall furnish the Government a completed packing slip. Labeling shall include the National Stock Number, Part Number, Serial Number, Nomenclature, Quantity, Contract Line Item Number, and Contract Number. Labeling data shall be attached to the outside of the shipping container. Bar coding is not required. Certificate of Conformance (COC) shall be placed on the outside of individual containers. Shipping Instructions Items shall be shipped to the following address: USCG Aviation Logistics Center Receiving Section, Bldg. 63 Elizabeth City, NC 27909-5001 Mark For: Purchase Order No. ____________________________ (To be assigned at time of award) 52.212-1 Instructions to Offerors - Commercial Items (JUN 2020) Consistent with FAR Provision 52.212-1: (c) Period for acceptance of offers. Prices must remain effective for 90 days after closing of solicitation. (h) Multiple awards. The Government reserves the right to make more than one award (multiple awards) for different line items, if, after considering the additional administrative cost to the Government of awarding and administering separate contracts, it is determined that the multiple awards will result in the lowest overall cost to the Government. For purposes of evaluating the cost of making multiple awards, it is assumed that the administrative cost of awarding and administering a contract is $500. 52.212-2 Evaluation-Commercial Items (OCT 2014) Quotes will be evaluated and contract awarded to the lowest priced technically acceptable quote. Technically Acceptable: Quotes must be for new manufactured commercial items from sources able to provide a Certificate of Conformance (COC) or traceability to the aircraft OEM. Only exact part numbers and no substitutes will be acceptable. Only the lowest priced offer will be evaluated for Technical Acceptability. Should the lowest priced offer not receive an acceptable technical or past performance rating, the process will continue in order of lowest priced offer until the lowest priced, technically acceptable offer with acceptable or neutral past performance is identified. 52.212-3 Offeror Representations and Certification - Commercial Items (NOV 2020) An offeror shall complete only paragraphs (b) of this provision if the offeror has completed the annual representations and certificates electronically via http://www.acquisition.gov . If an offeror has not completed the annual representations and certifications electronically at the System for Award Management (SAM) website, the offeror shall complete only paragraphs (c) through (o) of this provision. 52.212-4 Commercial Terms and Conditions - Commercial Items (OCT 2018) with the following included by Addendum: (a) Inspection/Acceptance. Inspection and acceptance of items under this contract shall be performed at destination by USCG, Aviation Logistics Center (ALC) Receiving section personnel and consist of count and condition only. Certificate of Conformance (COC) shall be required for all items provided on this contract. (g) Invoice. The original contractor invoice shall be submitted to the designated billing office address stated below or emailed to the email address below. Submitting invoices for payment electronically is the preferred method. FAR 52.246-15 Certificate of Conformance Apr 1984 FAR 52.252-2 Clauses Incorporated by Reference Feb 1998 52.252-1 Solicitation Provisions Incorporated by Reference (FEB 1998) This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address https://www.acquisition.gov/far. https://www.acquisition.gov/far/index.html. FAR 52.204-7 System for Award Management Oct 2018 FAR 52.204-13 Service Contract Reporting Requirements Oct 2016 FAR 52.204-16 Commercial and Government Entity Code Reporting Aug 2020 FAR 52.204-18 Commercial and Government Entity Code Maintenance Aug 2020 FAR 52.204-21 Basic Safeguarding of Covered Contractor Information Systems Jun 2016 FAR 52.252-6 Authorized Deviations in Clauses Nov 2020 FAR 52.225-8 Duty Free Entry Oct 2010 FAR 52.232-40 Providing Accelerated Payments to Small Business Subcontractors Aug 2020 FAR 52.247-34 F.O.B. Destination Nov 1991 FAR 52.247-29 F.O.B. Origin Feb 2006 Reimbursable Transportation for FOB Origin, Freight Prepaid Orders For material that is to be delivered f.o.b. supplier's plant, shipment to destination(s) shall be prepaid and subject to reimbursement. The transportation cost shall be shown as a separate item on the invoice. If shipping charges exceed $100.00, they must be supported by a freight bill, a copy of which must accompany the invoice. Parcel Post shipment requires a notation on the invoice giving the mail rate and parcel zone. 52.217-7 Option for Increased Quantity-Separately Priced Line Item (MAR 1989) The Government may require the delivery of a numbered (additional) line item, identified in the schedule, in the quantity and at the price stated in the schedule. Via Modification to the contract, the Contracting Officer may exercise the option by written notice to the Contractor within one year from __12/30/2020 to __12/30/2021. Delivery of added item shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree. (End of clause) 52.212-5 Contract Terms and Conditions Required to Implement Statutes or Executive Orders-Commercial Items. As prescribed in 12.301(b)(4), insert the following clause: CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS-COMMERCIAL ITEMS (NOV 2020) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (JUL 2018) (Section 1634 of Pub. L. 115-91). (3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (AUG 2020) (Section 889(a)(1)(A) of Pub. L. 115-232). (4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015). (5) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).