Top

Barn Construction

Active

State & Local

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

General Info

Agency

California → Santa Clara County

NAICS

236210 - Industrial Building ConstructionView NAICS

Place of Performance

CA, 95120

Set-Aside

NONE

Documents

This scope was carved out of Single-family residence, Barn, Stables, ADU and JADU.

The full solicitation package (2 documents), including the RFP, is on the prime solicitation, not on this scope.

View the prime solicitation

AI Contract Breakdown

Uniform Contract Format

No contract breakdown available.

Cannot generate Contract Breakdown because no documents were found from this contract's source.

Timeline

PostedAug 11

subcontract

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

AgencyCalifornia → Santa Clara County

ContactsNo contacts available

OfficeN/A

Organization / Agency

California → Santa Clara County

Office AddressN/A

ContactsNo contact information available

Full Description

Construction of an 8,600 sq. ft. barn including structural framing, roofing, ventilation, and access systems.

Similar Contracts

Same NAICS industry code

NAICS: 236210

New

Federal

LCAAP Contaminated Waste Plant W519TC-26-R-ACWP

Solicitation # W519TC26RACWP

The Army Contracting Command Rock Island Arsenal is soliciting proposals for the development of a Contaminated Waste Plant at the Lake City Army Ammunition Plant in Independence, Missouri. This project, issued as an Other Transaction Agreement under 10 U.S.C. 2808a, involves the construction of a new decontamination facility, the demolition and replacement of the pyrotechnic waste treatment facility, the refurbishment of the neutralized explosive wastewater treatment facility, and the replacement of a neutralized explosive wastewater lift station. The scope includes permitting, site preparation, commissioning, and turnover, with an anticipated completion date no later than November 4, 2030. Award will be based on best value through an integrated assessment of technical approach and performance and pricing. A mandatory requirement is that offerors must self-perform at least 30 percent of the construction work. Proposals must be submitted electronically via DoD SAFE by August 25, 2026, and must be organized into a cover letter, a performance and pricing volume, and a technical volume. Funding will be obligated as appropriated, and payments will be processed through the WAWF/PIEE system via Electronic Funds Transfer. The project is unclassified but requires strict compliance with ITAR and other export regulations, and the government limits liability to direct damages only.

POSTED

DEADLINE

Tinker AFB 2026 Multiple Award Construction Contract (MACC)

Solicitation # FA8137-26-R-0040

The Tinker AFB 2026 Multiple Award Construction Contract (MACC) is an indefinite delivery indefinite quantity (IDIQ) vehicle aimed at delivering a wide array of sustainment, maintenance, repair, renovation, and minor construction services across real property facilities at Tinker Air Force Base in Oklahoma. The contract will support complex projects requiring coordination among multiple construction trades and may involve engineering design by licensed professionals. Work will be executed under three methods: Design-Build, where the contractor develops the full design from a 15% schematic baseline; Construction with Limited Design, where the government provides a 35% to 65% design and the contractor completes remaining design elements; and Construction Only, where the government delivers a complete 100% design package. Contractors must furnish all materials, labor, equipment, testing, and quality control necessary to deliver a fully functional end product as specified in each task order. The contract includes a five-year base period with a potential five-year option, and it is governed under NAICS code 236210 with a small business size standard of $45 million. It is structured as a partial small business set-aside, reserving a portion of opportunities for qualified small businesses. Offerors must maintain active registration in the System for Award Management (SAM) to remain eligible for award, with non-compliance potentially leading to disqualification. The government commits to timely negotiation of equitable adjustments following change orders, with a target of 120 days to definitize such adjustments from receipt of a complete proposal. Proposals are due by August 12, 2026, and while the notice does not constitute a commitment to award, it sets the foundation for future task order solicitations under the MACC, with primary contact information provided for inquiries and submissions.

POSTED

DEADLINE

U-Haul Expansion & Amendment to Approved Use Permit ProjectThis project involves a Conditional Use Permit and Oak Resource Management Plan for U-Haul to expand its operations across two parcels at 17350 and 17400 Cattle Drive. The expansion includes the construction of 137 mini storage units across four buildings (A-D) totaling 29,057 square feet on a crushed gravel base. The development will occupy approximately 1.84 acres of the new parcel, while the remaining area will be preserved as open space. Both parcels will function as a single operation, sharing access via Cattle Drive and utilizing existing management, retail, and trash facilities. Additionally, the project seeks an amendment to an existing use permit to allow for outdoor vehicle storage consisting of 33 paved parking spaces and the retention of three shielded, downward-facing exterior light poles. The plan includes a comprehensive landscaping strategy with 1,257 plantings and an oak mitigation plan to address the removal of 17 trees. The facility will maintain its current operating hours of 8 a.m. to 5 p.m. seven days a week with a maximum staff of five employees.

POSTED

DEADLINE

General Contractor Unit Price Portwide 2026-1

Solicitation # SW-0322909

The Port of Seattle has issued solicitation SW-0322909 for a General Contractor to provide portwide building and facility restoration, remodeling, reconfiguration, demolition, and maintenance services. This unit-price, indefinite-delivery/indefinite-quantity contract has an estimated value not to exceed $350,000, excluding Washington State Sales Tax. The initial term is one year from the date of signing, with an option to extend for an additional 12 months. The award will be granted to the lowest responsible and responsive bidder. The scope of work includes providing all labor, materials, and equipment necessary for tasks authorized via individual Work Authorizations, though it explicitly excludes work involving asbestos-containing materials. Contractors must adhere to strict security and safety protocols, including obtaining TWIC credentials and Port-issued biometric badges for restricted area access. Key personnel requirements include a qualified Safety Representative with OSHA certifications and mandatory Air Operations Orientation for supervisors. All hazardous materials must be stored in secondary containment and permanently labeled. Payment is processed via direct deposit (ACH) on a monthly basis or within 30 days of work completion, with retainage governed by RCW 60.28.011. Bidders must provide a Washington State Unified Business Identifier and certify compliance with prevailing wage laws and Title VI non-discrimination standards. Proposals must be submitted as PDFs via email by August 25, 2026.

Port of Seattle General

POSTED

DEADLINE

MARS Payload Processing Facility Decontamination Shower Design Build - RFP 27.140100-001-001

Solicitation # DB-123899

The Virginia Commercial Space Flight Authority is seeking qualified contractors to design and build a dedicated 160 square foot decontamination room at the Mid Atlantic Regional Spaceport Payload Processing Facility on Wallops Island, Virginia. The facility will support controlled environment decontamination of personnel and equipment, requiring a purpose-built space that meets strict operational and safety standards. The solicitation, identified as RFP 27.140100-001-001 with solicitation number DB-123899, falls under NAICS code 236210 for commercial construction and is open to all eligible Respondents without specific set-aside restrictions. Proposals must be submitted by August 13, 2026, at 9:00 PM EDT, with the opportunity to respond posted on July 22, 2026. All work must be performed at the designated location on Wallops Island, and inquiries should be directed to Shelley Tucker via email at shelley.tucker@vaspace.org or phone at 757-999-9085. The project demands a turnkey design-build approach with emphasis on compliance, durability, and integration within the existing facility’s operational framework.

Virginia Commercial Space Flight Authority

POSTED

DEADLINE

Bundle 13 B3147 Cafe RenovationThe contract pertains to the renovation of a cafe under Bundle 13 B3147, categorized under NAICS code 236210 for commercial and institutional building construction. It is a forecasted opportunity issued by the Naval Information Warfare Systems through NIWC Atlantic, with the place of performance located in Charleston. The contracting officer is Adam Christopher, reachable at adam.w.christopher4.civ@us.navy.mil, and Jeffrey Nieding serves as the secondary point of contact. The solicitation was posted on August 10, 2026, and while it is not yet active for bidding, it signals an upcoming procurement need for facility renovation services. No set-aside details or specific funding information are available at this stage, and the contract is not yet open for submissions.

POSTED

DEADLINE

Asphalt Paving Program BuildingThe Federal Prison System under the Bureau of Prisons has forecasted a sole-source contracting opportunity under the 8(a) program for an Asphalt Paving Program Building, with the NAICS code 236210 indicating construction of commercial and institutional buildings. This opportunity is reserved exclusively for an 8(a) certified small business, meaning only eligible businesses participating in the SBA’s 8(a) Business Development program may respond. The work is anticipated to be performed in Yazoo City, Mississippi, and the contract will involve pavement and related infrastructure improvements. The solicitation is posted as a forecast and has not yet been issued as a formal request for proposals, with a posted date of August 10, 2026. Primary point of contact for inquiries is J Holt, reachable at jholt2@bop.gov, while Sarah Dean serves as the Small Business Specialist for assistance with 8(a) program-related questions. All potential bidders must be aware that this is a non-competitive, single-source procurement and that formal submission windows will be announced separately.

Federal Prison System / Bureau Of Prisons

POSTED

DEADLINE

CONSTRUCT TOC PAD - ARLINGTON HEIGHTS IL - Pre-Solicitation

Solicitation # W912EK26BA016

The US Army Corps of Engineers - Rock Island District is preparing to solicit competitive bids for the construction of a TOC pad at the 88th RD COL Paul G. Schulstad U.S. Army Reserve Center in Arlington Heights, Illinois, under solicitation number W912EK26BA016. The scope of work encompasses excavation and on-site storage of contaminated spoils, demolition and installation of electrical power distribution systems, directional boring for telecom lines, and the installation and leveling of gravel, all to be performed in accordance with specified plans. The project must be completed within 300 consecutive calendar days, with work scheduled during normal business hours, though limited utility shutdowns may require off-hours or weekend access. A critical constraint is that the USARC site must remain fully operational throughout all construction activities, and all contaminated materials must remain on site due to environmental conditions. This is a pre-solicitation notice issued under the 8(a) competed set-aside program, with responses accepted until July 31, 2026, and no submissions will be evaluated at this stage. The contracting office is located in Rock Island, Illinois, with Jocelyn Rain as the primary point of contact.

W07V Endist Rock Island

POSTED

DEADLINE

WWYK240052 Renovate Hallway, 1AB1-103C, 1AB1-108B, B3001

Solicitation # FA813726R0049

This contract is exclusively for Tinker Air Force Base MAC BOA holders and pertains to the renovation of hallways in B3001 at Tinker AFB, Oklahoma, specifically targeting areas 1AB1-103C, 1AB1-108B, and associated corridor spaces. The project has an estimated value under $25 million and is set aside entirely for small business contractors holding a MAC BOA, with no subcontractor direct participation permitted at the proposal stage. All interested prime contractors must review the project-specific documents, and failure to do so may result in ineligibility. Attendance at the mandatory Initial Site Visit on Wednesday, August 12th at 2:00 PM CST is required for proposal eligibility, and RSVPs must be submitted within five calendar days of the posting. Contractors must confirm in their RSVP whether all attendees have base access; if not, they must submit an Entry Access List for sponsorship. Only prime MAC BOA holders may RSVP; subcontractors must coordinate through a prime contractor, and any base access needs for subcontractors must be sponsored by the prime. The solicitation number is FA813726R0049, with responses due by September 30, 2026, and the NAICS code is 236210 for building construction. Point of contact information is provided for inquiries and document access, with DoD Safe transmission available for secure document exchanges.

POSTED

DEADLINE

JM26 CNIC BLDG 1909 Kitchen Silica Dust Cleaning and Floor Repair

Solicitation # N4008526R0252

The contractor is required to abate silica dust in the kitchen area of Building 1909 by performing all necessary labor, supplying materials and equipment, and providing full supervision to ensure compliance with OSHA regulations governing silica exposure, specifically 29 CFR 1926.1153 for construction or 29 CFR 1910.1053 for general industry, depending on applicable conditions. The scope includes complete removal of existing tile and installation of new porcelain tile with grout to restore the space while eliminating hazardous dust exposure and safeguarding the health of workers and nearby individuals. The project is issued under solicitation number N4008526R0252 by NAVFACSYSCOM Mid-Atlantic, a Department of Defense agency, with a response deadline of August 24, 2026. The work will be performed at a location associated with ZIP code 47522, and inquiries should be directed to Mariah Paulk at the provided contact information. The contract falls under NAICS code 236210, indicating it is for commercial and industrial building construction.

Navfacsyscom Mid-Atlantic

POSTED

DEADLINE

EQUIPMENT STORAGE BUILDING - WMF

Solicitation # 2026-08-05

The City of North Battleford, through the Saskatchewan Public Sector, is soliciting proposals to construct an equipment storage building at the Waste Management Faculty to house operational equipment. Three building sizes—approximately 60x80, 60x100, and 60x120 feet—are under consideration, with the final selection to be made based on the ability to adequately store all required equipment while meeting minimum specifications, including at least 20 feet of vertical internal clearance. Proposals may include alternative designs of similar size and functionality, and contractors are permitted to propose any framing type such as steel or post-frame, with the building required to be metal clad. The RFP seeks vendors with proven experience, the necessary resources, and the capability to deliver the project safely, efficiently, and in full compliance with all applicable building codes and standards. Proposals must be submitted by September 1, 2026, at 10:00 PM local time, with the solicitation issued on August 6, 2026. Interested parties should refer to the official portal for layout examples and additional details, and all inquiries should be directed to Todd Olexson at tends@cityofnb.ca or 306-445-1722. The project is located in Saskatchewan, and while the specific city address is not provided, performance is required on-site at the Waste Management Faculty. The solicitation number is 2026-08-05, and additional information is available through the SaskTenders website.

City of North Battleford

POSTED

DEADLINE

Patch and Repaint of Corridor of Building 6010 (1st, 3rd, & 4th Floor)

Solicitation # W56ZTN-26-Q-1CA4

The contract solicits a firm fixed-price quote for the patching and repainting of corridors and offices across the first, third, and fourth floors of Building 6010 at Aberdeen Proving Ground, Maryland, with a total area of approximately 6,800 square feet spanning about 40 rooms. The work requires precise adherence to specified Sherwin Williams paint colors—Shoji White, Ripe Olive, and Bermuda Blue—in eggshell or eggshell gloss finishes, with strict instructions to avoid painting doors, trim, and ceilings unless explicitly directed, and to preserve existing graphics and signage. All surfaces must be cleaned, prepped, and repaired prior to painting, and the contractor must provide protective coverings, move furniture as needed, and remove all debris using their own disposal methods, not government facilities. The period of performance is 12 months from award, with work required to commence within 30 business days, and must be scheduled to minimize disruption to ongoing operations during normal business hours Monday through Friday, excluding federal holidays. This solicitation is a 100% total small business set-aside under NAICS code 236210 with a size standard of $45 million, and vendors must demonstrate at least five years of proven experience in wall patching and repainting. All quotes must include proof of this experience and a completed copy of the 52.212-3 representations and certifications, or a current active SAM.gov registration. Evaluation will prioritize technical capability and price. Contractors must comply with stringent security protocols including background checks, AT Level I training, ID verification, and restricted movement on the installation, and must adhere to federal environmental, safety, health, and drug-free workplace standards. The government will supply access to electricity and restrooms and certify the area is free of lead and asbestos, but the contractor assumes full responsibility for repairs, warranty of labor for one year, and any damage caused during performance. Quotes are due by 10:00 am EST on August 13, 2026, and must be submitted via email to the designated contract specialist and contracting officer.

W6QK Acc-Apg Director

POSTED

7 days ago

DEADLINE

in about 9 hours

View Details