Y--Bathroom Remodel -Sleeping Bear National Lakeshore

This solicitation, numbered 140P6426Q0087, is a Request for Quote under Standard Form SF-1442 issued by the National Park Service, part of the Department of the Interior, for the renovation of four comfort station showers located within two facilities at Sleeping Bear Dunes National Lakeshore in Empire, Michigan. The procurement is structured as a firm-fixed-price contract with an estimated value between $100,000 and $250,000 and is exclusively set aside for small businesses under NAICS code 236220, which has a size standard of $45 million. Offerors must be actively registered in SAM and possess a valid Unique Entity Identifier, and their quotes must be submitted as a single PDF package via email to the Contracting Officer by the deadline of July 14, 2026, at 12:00 PM local time. The contract requires strict adherence to the project specifications and drawings, which detail the complete demolition and remodeling of the shower areas, including installation of heat, water, ventilation, and drainage systems, with design standards based on prior NPS renovations. Performance must be completed within 120 calendar days from the Notice to Proceed, encompassing all phases including supply lead times, installation, and final commissioning, with no adjustments permitted for weather or delays. Contractors must submit a detailed project schedule with critical path analyses and comply with all safety, health, and operational regulations set forth by the National Park Service and OSHA, including the implementation of an accident prevention program and use of ANSI-compliant personal protective equipment. The procurement mandates a 20% bid guarantee and requires performance and payment bonds under the specified clause with a May 2023 deviation. Award will be made based on best value using simplified acquisition procedures per FAR Parts 13 and 12, considering price, technical capability, and prior experience, though exact weighting is not disclosed. Payment will be processed through the IPP website, requiring contractors to register and submit invoices with full documentation including pricing breakdown, contract number, and invoice letterhead. Final payment is contingent upon submission of comprehensive documentation including as-built drawings, test reports, warranty of construction, release of claims, and all payrolls including subcontractors with corresponding SF-1413 forms. Inspections may occur at any reasonable time and location, and the contractor bears full responsibility for quality control and protection of materials until acceptance. All inquiries must