Broadway Plaza Reconstruction and Roof Repair Project

The Government announces an opportunity for Construction Excellence for the Broadway Plaza Reconstruction and Roof Replacement Project located at the Jacob K. Javits Federal Building, 26 Federal Plaza, in New York, NY. This project is a major Repair and Alteration project which involves immediate repair to the structure in order to fix extensive damage caused by water infiltration, along with the removal and replacement of the existing plaza surfaces to expose and then repair/waterproof the structure below. Furthermore, there will be a new roofing system installation on floors 42, 43 and 44 of the building. The Government is seeking General Contractors to act in the capacity of Construction Manager as Constructor (CMc) who can provide full Construction Services for this project. The Government must ensure that there is adequate capability, experience and competition among the potential pool of responsible contractors. This procurement will be conducted under NAICS Code 236220-Commercial and Institutional Building Construction. The Government anticipates the award of a single contract for CMc Services. The period of performance for the proposed contract will be for an approximate 48 month period. The estimated construction cost range for this project is $45,000,000.00 - $55,000,000.00. Award of this contract shall be subject to the availability of appropriated funds, and the Government shall incur no obligation under the Solicitation in advance of such time as funds are made available to the Contracting Officer for the purpose of contract award. The CMc contractor shall be a member of the project development team during the design and construction phases of the project, working with the selected architect/engineer (A/E) firm and the Government to ensure a quality project, within the mandated schedule and budget. The CMc contractor will perform services including, but not limited to: 1) Design Phase Services (such as reviewing design submissions, preparing cost estimates, controlling schedules, keeping records, reporting on design and construction progress, conducting Value Engineering exercises, and conducting constructability reviews); and 2) Construction Phase Services (such as Constructing the facility at or below the Guaranteed Maximum Price , administering the construction contract and all subcontracts, coordinating construction meetings, Critical Path Method (CPM) scheduling, monitoring construction costs and performing administrative and other services as defined in the scope of work to provide for a completely functional facility). The procurement method that will be implemented for this project will be in accordance with FAR Part 15.1 - Source Selection Processes and Techniques. This project is a competitive acquisition utilizing the Trade-Off process approach under the Best Value Continuum (FAR 15.101). This process permits tradeoffs among cost or price and technical factors, and allows the Government to accept other than the lowest priced proposal. For this procurement, the technical evaluation factors when combined will be approximately equal to cost or price. Details on the submission requirements for the Technical Evaluation Factors will be issued in the solicitation. The solicitation will be posted on the FedBizOpps website at www.fedbizopps.gov on or about June 13, 2018. The closing date for the receipt of proposals will be on or about July 27, 2018. No paper copies will be mailed to prospective offerors. If you have questions regarding this procurement please contact Brad Edwards, Contract Specialist via email at brad.edwards@gsa.gov.