C--CAVHCS AE IDIQ CONTRACT

The Department of Veteran Affairs Network 7 Contracting Office is seeking qualified Architect-Engineering (AE) firms to submit Standard Form 330 (SF 330) Architect/Engineering Statement of Qualifications for Indefinite Delivery-Indefinite Quantity (IDIQ) contracts for Architectural and Mechanical-Electrical-Plumbing services at the Central Alabama Veterans Health Care System facilities in Network 7 (State of Alabama). Firms submitting qualification packages must be fully licensed to perform designs as a registered professional AE firm in the State of Alabama to be considered for this opportunity. Also, see geographic location restriction in paragraph 8.g. of this notice. Network Contracting 7 VA Facilities locations include: Central Alabama Veterans Health Care System West Campus, 215 Perry Hill Rd Montgomery, AL 36109 Central Alabama Veterans Health Care System East Campus, 2400 Hospital Rd Tuskegee, AL 36083 General architectural AE Services to be provided as follows: AE shall be required to furnish services in accordance with current Department of Veterans Affairs Master Specifications (PG-18-1), Barrier Free Design Guide (PG-18-13), Unified Facilities Guide Specifications, International Building Codes, National Fire Protection Association codes, and other agency standards. Department of Veterans Affairs specific documents are located on the Office of Construction and Facilities Management Technical Information Library (http://www.cfm.va.gov/TIL/). AE services required shall be multidisciplinary in nature to include but not limited to: Architectural, Structural, Civil, Interior Design, Landscape Architect, Industrial Hygienist, Surveying, Geotechnical, Surveying, Hazardous Materials / Environmental Services (asbestos, lead survey), Economic Analysis, Project Management, Construction Management, Energy, and Estimating. AE services may include any combination of the below services (but not limited to) to accomplish building designs for new facilities as well as renovation/remodel, cost estimating (using history of similar projects in the region if possible) and upgrade of existing facilities and systems, to include new buildings, building additions and/or building renovations or remodels. Requirements will vary for each individual IDIQ Task Order and will be defined by separate scopes of work. Additional services that may be required include, preparation of designs, plans, drawings, life-cycle cost analysis, construction cost estimates, project specifications; fact-finding studies, surveys, investigations, other professional AE services not necessarily connected with a specific construction project; and inspection of projects under construction. Requirements will vary for each individual IDIQ Task Order and will be defined by separate scopes of work. 1. Concept and scope development. 2. Investigations, Assessments, and Feasibility studies. 3. Space planning. 4. Environmental studies. 5. Program analysis. 6. Schematic design. 7. Pre-construction document technical investigation and studies. 8. Design, drafting, and planning services for renovation, demolition and alterations to existing facilities, interior design, and space planning; 9. Design Development to include deliverables such as designs, plans, drawings, specifications, etc. 10. Design reviews through the Design Development stages of a project. 11. Cost estimates through the Design Development stages of a project (using RS Means, history of similar projects in region, and standard estimating practices). 12. Value engineering reviews. 13. Construction Documents to include deliverables such as designs, plans, drawings, specifications, etc. 14. Construction document and constructability reviews. 15. Cost estimates for Construction Documents (using RS Means, history of similar projects in region, and standard estimating practices). 16. Preparation of schedules, phasing plans, and network analysis. 17. Life-cycle cost analysis. 18. Insuring coordination of various control/life safety/nurse call/IT systems (regardless if new or existing), 19. Fact-finding studies, surveys, investigations and other professional services not necessarily connected with a specific design or construction project. 20. Project Management, Construction Management, and Construction Administration. 21. Construction Quality Assurance and Quality Control. 22. Construction period services including: construction submittal review, request for information investigation and response, change order/modification investigation, design, cost estimating, and issuance. 23. Specialty consulting, investigations, and reports not available through design AE (technical reports, commissioning, etc.). 24. Energy computations, LEED studies/certification 25. As-built preparation 4. AE services are typically known as Study, Schematic, Design Development, Construction Documents, Bid Documents, and Construction Period services, to include reproduction of documents. Potential projects require multi-disciplinary engineering services for various commercial or industrial type facilities, vertical/horizontal construction, pavements and roads, and other hospital related structures. Standard services, in addition to those inherent to the production of construction drawings are (but not limited to): Provide professional engineering services as required for the preparation of working drawings, specifications, cost estimates, and (any) possible impact costs for multi-discipline services for the various projects. Furnish progress reports of their work. Closely coordinate AE s work performed in his/ her office with the related work of the Government staff personnel. Promptly report to the Contracting Officer any ambiguities or discrepancies discovered in the project requirements, criteria, or documents, involving their work or the work of the Government. Assist VA Medical Center in conferring and coordinating with state and local Government agencies, as required. Visit the project sites, hold conferences and discussions with the Government representatives in VA s office, and take such other action as may be necessary for the design development, and to coordinate and complete the required services and documents under each task order. Where relevant for task orders, check and recommend to the Government, approval or rejection of shop drawings, samples, equipment lists, and data applicable to the AE s part of design work, during the construction period. AE shall analyze and verify utility systems and structures as necessary and as part of their proposal. AE shall provide final As-Built drawings utilizing final construction markups ( red-line drawings ) for subsequent submission to the COR for the project or other designated Government representative. The AE shall advise the Contracting Officer and Contracting Officer Representative (COR) as to the recommended construction timeframe for each construction Bid Item and entire project. AE team shall design the project for multiple Bid Alternative Items if requested. The COR shall be included on all correspondence between AE and contractors, subcontractors, vendors, etc. pertaining the request project to ensure VA is in informed of any issues, inquires, questions, etc. regarding the design or project. The Design(s) shall include all (related) work which represents a complete project, including separation of basics, as required for any multiple Bid Items. The AE shall use the most current Veterans Affairs Master Specifications which can be found at: http://www.cfm.va.gov/til/spec.asp and shall edit (accordingly) to ensure best practices and to suit the project. The AE shall document and distribute to the contracting officer and the COR all site visits, meeting minutes, provide a record of all phone messages, and reports monthly. AE shall provide specifications for Phasing and Coordination of utility shutdown(s) with VA COR. Prepay shipping charges on all charts, sketches, drawings, and documents that are sent to the Contracting Officer and/or COR. AE is responsible for physical surveys and investigations (to minimize construction change orders) of existing conditions, which may include sewer surveying, hydrant flow analysis, and accuracy of existing studies and data. Investigative services may require destructive demolition. CRITICAL PATH SCHEDULING: The AE shall develop a critical path schedule demonstrating fulfillment of the contract requirements and shall utilize the plan for scheduling, coordinating and monitoring work under this contract, including all activities of the AE. The precedence diagram method (PDM) shall be utilized to satisfy both time and cost applications. 5. The AE services may be performed in phases, at the option of the Government. These phases will be executed only if the Contracting Officer elects a Government option and issues a separate Task Order or written "Notice to Proceed" to the AE for the particular phase. 6. SET-ASIDE INFORMATION: This procurement is a 50% set-aside for Service Disabled Veteran Owned Small Business (SDVOSB) AE firms under North American Industry Classification System (NAICS) Code 541310, Architectural Services (Small Business Size Standard $7.5 Million) and 50% set aside for Small (SB) AE firms under 541330, Engineering Services (Small Business Size Standard $15.0 Million) The Government intends to award a minimum of two (2) awards to SDVOSB AE firms and a minimum of two(2) awards to other SB AE firms for a total minimum of four (4) awards. The awarded contracts will be firm-fixed price Indefinite Delivery-Indefinite Quantity (IDIQ). The IDIQ contracts will be for one base year from the date of award with options to extend the term of the contracts for four (4) additional one year periods to be exercised at the discretion of the Government, or until the maximum contract amount of $12,000,000.00 awarded across all IDIQs is reached, whichever is earlier. Each contract awarded will have a guaranteed minimum order of $1,500.00 for the total of the base year and all option years. The minimum value of any individual Task Order is $2,500.00 with a maximum Task Order value of $900,000.00. Each specific IDIQ Task Order shall be separately negotiated based on the A/E effort involved. Note: The primary authority for the awarded IDIQ Contracts is Central Alabama Veterans Health Care System Construction Contracting Officers; Other VISN 7 locations within the State of Alabama will be authorized utilization of this IDIQ as a procurement vehicle with prior approval from CAVHCS Contracting Officers. 7. This procurement will be following the procedures established in the Brooks Act, Federal Acquisition Regulation (FAR) 15, FAR 36.6, and Veterans Affairs Acquisition Regulation (VAAR) 836.6. The selection process will be made using a two-stage process. Stage I consists of the initial evaluation of the SF-330 s and determination of the highest rated firms. The highest rated firms will then be short-listed and invited to continue with Stage II of the process. All firms not short-listed will be notified. Stage II consists of Interview/Oral Presentations for the short-listed firms and selection of the top ranked firms to receive the solicitation for pricing and conduct negotiations. Stage I: Firms responding to this notice will be evaluated and ranked using the selection criteria listed below. The factors are listed in descending order of importance. The evaluation will consider how each factor is addressed and how it is formatted to coincide with the selection criteria. The evaluation factors listed below shall be addressed in Part H of the SF-330. Professional qualifications necessary for satisfactory performance of required services - All key personnel for whom resumes are provided shall be shown on the organizational chart in Section D of SF 330, Part 1. Additional staff available for work on this contract shall be indicated on the chart by providing how many staff will be working on the contract in the following key disciplines that are required to be licensed, registered, and/or certified: Two architects Two structural engineers Two civil engineers Two mechanical engineers Two electrical engineers One fire protection engineer One geotechnical engineer One certified industrial hygienist Two project managers One interior designer One cost estimator One landscape architect Specific experience and qualifications of personnel proposed for assignment to the contract and their record of working together as a team - Provide the specific experience and qualifications of the personnel proposed for healthcare facility projects and their record of working together as a team. Specialized Experience of Team Specialized experience and technical competence with healthcare related designs in a hospital setting, in the types of work identified below (in descending order of importance within this category): Rehabilitation of existing structures of various types, sizes, and complexities; Design of new structures of various types, sizes, and complexities; Design of projects at Department of Veterans Affairs (DVA) Healthcare Systems and other healthcare facilities (both private and public); Cost engineering using RS Means and other parametric estimating tools; Sustainable design utilizing Leadership in Energy and Environmental Design (LEED) rating tools; Construction phase services including shop drawing, submittals, and Request for Information reviews. Firm s Capacity Capacity to accomplish the work in the required time, including existing workload that may limit AE s capacity to perform project work expeditiously. Firms must address and demonstrate the capacity to execute several large Task Orders ($150,000 to $900,000 with a performance time of 90-180 calendar days) or multiple small Task Orders ($2,500 to $150,000 with a performance time of 30-90 calendar days) simultaneously. Past performance Past performance on contracts with Government agencies and private industry in terms of cost control, quality of work, and compliance with schedules. Offerors will be evaluated on past performance with Government agencies and private industry in terms of work quality, compliance with schedules, cost control, and stakeholder/customer satisfaction. Evaluating past performance and experience will include information provided in Past Performance Questionnaires (PPQs) or Contractor Performance Assessment Reports System/Architect-Engineer Contract Administration Support System (CPARS/ACASS) for Factor 1 projects and may include other information provided by the firm, customer inquiries, Government databases, and other information available to the Government including contacts with points of contact in other criteria. Failure to provide the requested data, accessible points of contact, or valid phone numbers could result in a firm being rated lower. Management Plan - Reputation and standing of the firm and its principal officials with respect to professional performance, general management, and cooperativeness. Geographic Location- Location in the general geographical area of the project. Must have a working office within 200 miles of the Central Alabama Health Care System (CAVHCS), 215 Perry Hill Road, Montgomery, AL 36109. (As measured drawing a straight line on a map (i.e. Google Maps) from the address to the AE firm s office address). Miscellaneous Experience - Address experiences from the projects listed in the SF 330 in regards to: (1) CADD and other computer applications; (2) value engineering; (3) life cycle cost analyses; (4) environmental; (5) historic preservation; (6) energy conservation; (7) Critical Path Management (CPM) and fast track construction. Also, include any tangible evidence demonstrating superior performance, such as certificates, awards, peer recognitions, etc. Insurance and Litigation - Address the types and amounts of liability insurance carried. Identify all litigation against the firm because of improper or incomplete architectural and engineering services over the last five years and its outcomes. Stage II: The shortlisted firms will be invited to present their qualifications in person to the Evaluation Board. Additional criteria will be provided to these firms, and they will be given approximately ten (10) days to prepare for their Interview Presentations. After the Interview Presentations are concluded the firms will be evaluated and the top-ranked firms will be selected, sent solicitations, and subsequent negotiations to follow. Award selection will be made based on the results of the Interview Presentations only, and not the SF-330 qualifications from Stage I. Firms must be registered in SAM (System for Award Management) database, information on registration requirements can be obtained on the Internet at (http://sam.gov), and submit their complete Annual Representation s and Certifications (ORCA) via online at htpp://orca.bpn.gov. Any firm not CVE verified upon submission of their SF330 s will not be evaluated and not considered for award. Please submit a copy of you CVE verification letter with your SF330 package. The submission must include the SF-330, Architect/Engineer Qualifications (form is available on-line at http://www.cfm.va.gov/contract/ae.asp), and if submitting as a SDVOSB firm a printout of the current VETBIZ registration. The SF-330 including title page, table of contents, and any other relevant information shall not exceed a total of 50 pages in a common font size 12 font, single spaced. Use graphic presentations where such use will contribute relevant data shall be provided in an image area of 7 X 9 inches. The background color of each page of the submission shall be white or ivory stock only. The proposal shall be submitted as a single application-generated (not scanned), searchable PDF document. A page is defined as each face of an 8.5 X 11-inch sheet of paper containing information. THIS ANNOUNCEMENT IS NOT A REQUEST FOR PROPOSAL. THIS IS A PRE-SOLICITATION NOTICE FOR ARCHITECT/ENGINEERING (A/E) DESIGN SERVICES; NO SOLICITATION PACKAGE WILL BE ISSUED UNTIL AFTER AN EVALUATION HAS BEEN MADE ON THE PROVIDED SF-330. ONLY THE A/E FIRMS RESPONDING TO THIS ANNOUNCEMENT BY SUBMITTING AN SF330 PACKAGE ON TIME WILL BE CONSIDERED FOR INITIAL EVALUATION. Offerors shall mail proposal packages to the Department of Veterans Affairs. Mail Delivery Address: Central Alabama Veterans Health Care System Attn: Sherri Mitchell, Contracting Officer Lot S, Trailer 2 Room 9 215 Perry Hill Road Montgomery, AL 36109 Firms shall submit proposals not later than 1:30 PM local time Friday, July 28, 2017. All questions regarding this announcement must be e-mailed to the contracting office at contact@example.gov.