Psst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveCLEATUS Webinar: AI for Government Contracting — Free Webinar — Wednesday, September 30 at 2:00 PM EDT

Register Free →

Search

Top

Back to Contracts

Commercial Flooring

Active

State & Local

Response Deadline10/19/2026, 10:00:00 PM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

This subcontract for commercial flooring is issued by the UNC System Office of Design and Construction for interior improvements at the North Carolina State University Talley Student Union. The selected contractor will be responsible for supplying and installing various flooring materials, including LVT, carpet tiles, polished concrete, and ceramic tile, while also managing all necessary floor preparation to deliver completed surfaces for prime contractors. The solicitation was posted on September 23, 2026, with a response deadline of October 19, 2026. This project falls under NAICS code 238330 and is managed by the state of North Carolina.

General Info

UNC System subcontract for commercial flooring installation at NC State Talley Student Union.

Agency

North Carolina → Unc - System Office Design/construction

NAICS

238330 - Flooring Contractors

Place of Performance

NC, USA

Set-Aside

NONE

Documents

This scope was carved out of 287-26482-PQ.

The full solicitation package (1 document), including the RFP, is on the prime solicitation, not on this scope.

View the prime solicitation

NC State University

AI Contract Breakdown

Uniform Contract Format

No documents to break down

The breakdown needs solicitation documents. None were found from this contract's source.

Timeline

PostedSep 23

subcontract

Response DeadlineOct 19

Submission deadline

Response Deadline

10/19/2026, 10:00:00 PM UTCin 23 days

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more

AgencyNorth Carolina → Unc - System Office Design/construction

ContactsNo contacts available

OfficeN/A

Organization / AgencyNorth Carolina → Unc - System Office Design/construction

Office AddressN/A

ContactsNo contact information available

Full Description

Show more

Supplies and installs flooring materials for prime contractors on NC State University facility projects, here the Talley Student Union interior improvements. Performs installation of LVT, carpet tiles, polished concrete, or ceramic tile, including necessary floor preparation. Delivers completed floor surfaces.

Similar Contracts

Same NAICS industry code

Flooring & PaintingThis subcontract agreement with ONIT Construction involves providing interior finishing services for a residential care facility project located in Hamilton, Ontario. The scope of work includes the application of paint and the installation of multiple flooring types, specifically carpet and tile, to deliver finished interior surfaces according to standard finishing specifications. The solicitation was posted on September 26, 2026, with a response deadline of October 23, 2026. This project falls under NAICS code 238330 and is structured as a subcontract for prime contractors to ensure the completion of all interior surface requirements.

ONIT Construction

POSTED

about 21 hours ago

DEADLINE

Flooring Preparation & Concrete RemediationThis subcontract for Flooring Preparation and Concrete Remediation supports facility projects for the Little Lake City School District in Santa Fe Springs, California. The scope of work involves the removal of existing floor coverings and the preparation of concrete substrates, including moisture and pH testing, the application of moisture sealers, and the installation of cementitious surfacing according to ASTM F710 and ASTM F1869/F2170 standards to deliver a remediated subfloor. The project falls under NAICS code 238330 and was posted on September 26, 2026. Interested parties must submit their responses by the deadline of October 20, 2026.

Little Lake City School District

POSTED

about 23 hours ago

DEADLINE

Resilient Flooring InstallationThis subcontract for the Little Lake City School District involves the installation of resilient plank, tile, and wall base for facility projects located in Santa Fe Springs, California. The contractor is responsible for delivering a complete flooring system, including seaming, installing plastic filler for covered bases, and ensuring all surfaces are flat and crack-free. All work must strictly adhere to ADA Standards as well as ASTM F1700 and ASTM F1861 specifications, and the final delivery must include maintenance attic stock. The project is categorized under NAICS code 238330. The solicitation was posted on September 26, 2026, with a response deadline of October 20, 2026.

Little Lake City School District

POSTED

about 23 hours ago

DEADLINE

Interior Flooring InstallationThis subcontract for Interior Flooring Installation is issued by the Little Lake City School District in California for projects located in Santa Fe Springs. The selected contractor will install new flooring across various educational facility areas, including classrooms, offices, and administration spaces, ensuring all work aligns with the provided Finish Plan. Key requirements include performing field verification of all dimensions and quantities after the demolition of existing ACM flooring and maintaining a valid flooring installation certification. Interested parties must submit their responses by the deadline of October 20, 2026.

Little Lake City School District

POSTED

about 23 hours ago

DEADLINE

SHARP - Flooring Services for Two Properties

Solicitation # SHARP IFQ-2026-087-PS

SHARP LLC is soliciting bids for the removal and replacement of flooring at two residential mid-rise properties in Sacramento: Sierra Vista Apartments at 2300 K Street and Sutterview Apartments at 2526 L Street. The scope of work includes the demolition of existing vinyl plank and carpet tiles, substrate preparation conforming to ASTM F710, and the installation of Mohawk Dealer Solutions III Luxury Vinyl Plank in Caramel with 6-inch brown cove base. Bidders must hold a C-15 Flooring and Floor Coverings license and may submit proposals for one or both properties. All work, including final inspections and invoice submissions, must be completed by December 31, 2026. The contract requires strict adherence to OSHA standards and the use of low-VOC or zero-VOC materials meeting RFCI FloorScore standards. While not subject to prevailing wage requirements, the California Minimum Wage applies to all labor. Financial security requirements include a bid bond of 5% for proposals exceeding 300,000 dollars, and the successful bidder must provide performance and payment bonds totaling 100% of the contract price. Liquidated damages for delays are set at 100 dollars per unit per calendar day. Contractors must also maintain comprehensive insurance coverage as specified in the agency requirements and provide one unopened box of flooring and 25 linear feet of cove base at each site for future maintenance.

Procurement Services Division

POSTED

DEADLINE

CUPCCAA Wood Floor Refinishing

Solicitation # 2026/27-05

The Riverside Unified School District is soliciting bids for wood floor refinishing services across seven school sites, including Chemawa Middle, University Heights Middle, John W North High, Ramona High, Arlington High, Emerson Elementary, and Bryant Elementary. The scope of work involves sanding and recoating two gyms and two elementary stages, as well as top scrubbing and refinishing three gyms. Specific tasks include applying new logos and sport lines, replacing damaged wood sections, polishing aluminum thresholds, and installing walk-off mats. The project must be completed within 60 days, and the district has provided a construction cost estimate of 160,000 dollars. The contract will be awarded to the lowest responsive bidder based on the total cash purchase price. Eligible bidders must be on the district's CUPCCAA list and hold a valid Class C15 Flooring and Floor Covering contractor license. Bids must be hand-delivered to the Purchasing Department by 10:00 AM on October 20, 2026, and must include a 10 percent bid security, a non-collusion declaration, and a list of designated subcontractors. The project is subject to California prevailing wage laws, requires DIR registration, and mandates strict adherence to lead-based paint and asbestos-free material regulations. Performance and payment bonds are required upon award.

Riverside Unified School District

POSTED

DEADLINE

Flooring InstallationAlcorn State University is seeking a subcontractor for flooring installation services to support prime contractors on various facility projects. The scope of work includes the supply and installation of interior flooring materials such as carpet, Luxury Vinyl Tile, VCT, and polished concrete, all of which must adhere to the specific requirements outlined in the Project Manual. Eligible bidders must hold valid Mississippi contractor licenses to qualify for this subcontract. The response deadline for this opportunity is October 29, 2026, and the primary objective is the delivery of fully installed finished flooring under NAICS code 238330.

ALCORN STATE UNIVERSITY

POSTED

DEADLINE

in about 1 month

Buffing the Gym Floor

Solicitation # 203

The Jefferson Parish Government is soliciting bids for the provision of all labor, materials, and equipment required to buff, paint, and apply a urethane coating to the gym floor at the Little Farms Playground Gym located in River Ridge, Louisiana. The scope of work includes buffing the floor using Bona multi plate or an approved equal with 320 or 220 grit paper, touching up existing court lines and logos, adding two new pickleball court lines, and painting a new name on the court using owner-provided fonts and colors. The final step requires the application of two coats of Bona Super Sport or an approved equal water-based urethane. All work must be performed during normal building hours from 8:00 am to 3:00 pm, and the contractor is responsible for removing all materials and debris from the site daily as on-site storage is prohibited. The contract will be awarded to the lowest responsive and responsible bidder. A critical requirement for the apparent low bidder is the submission of final insurance certificates and a notarized worker's compensation insurance declaration affidavit within ten calendar days of the bid opening; failure to comply will result in the rejection of the bid. Contractors must maintain comprehensive insurance coverage, including Worker's Compensation, Commercial General Liability, and Business Automobile Liability, in accordance with Jefferson Parish Resolutions. Bidders are required to conduct a site visit to determine the necessary quantities of materials and equipment before submitting their quotes. For site visit coordination, the point of contact is Ethan Landry.

Jefferson Parish Government

POSTED

DEADLINE

Flooring Supply & Fit

Solicitation # 2026/S 000-091135

Leeds City Council is seeking two subcontractors to supply and install floor coverings for domestic properties under the Housing Responsive Repairs and Voids Contract. The procurement is divided into two geographic areas, with Lot 1 covering regions R1-R5 and Lot 2 covering regions R6-R9. The total estimated value of the contract is 300,000 GBP excluding VAT. The primary period of performance is scheduled from January 2, 2027, to January 1, 2029, with a potential 12-month extension option that could extend the contract through January 1, 2030. The award process follows a two-stage evaluation where bidders must first meet a minimum quality threshold of 60 percent. Once this quality requirement is satisfied, the final award is determined solely based on price, which carries a 100 percent weighting. This opportunity is particularly suitable for small and medium-sized enterprises. Interested parties must submit their responses by the deadline of October 23, 2026, with all inquiries to be directed to Conor Kerins.

Leeds City Council

POSTED

DEADLINE

FA445226R0018_43d AMOG Carpet Repair_Request for Proposal

Solicitation # FA445226R0018

Solicitation FA445226R0018 is a formal Request for Proposal for commercial construction services to perform carpet repairs at Buildings 308 and 430 at Pope Field, North Carolina. The project involves the demolition of existing flooring and cove base and the installation of new 24x24 carpet tiles and approximately 700 linear feet of cove base. The scope covers approximately 864 square feet in Building 430 and 3,647 square feet in Building 308, with the contractor responsible for all labor, materials, equipment, and the movement of furniture. All work must comply with the Whole Building Design Guide, Fort Bragg Installation Design Guide, and various federal and industry standards, including the Corps of Engineers Safety Manual EM 385-1-1. This effort is a 100 percent small business set-aside under NAICS code 238330, with a size standard of 19.0 million dollars. The government intends to award a single firm-fixed-price purchase order based on best value, evaluating technical proposals as superior, acceptable, or unacceptable. Proposals are due by September 28, 2026, and must be submitted in three volumes: Administrative, Technical, and Price. Bonding requirements vary by proposal value, with bid guarantees and performance bonds required for amounts exceeding 150,000 dollars and alternative payment protections for amounts between 35,000 and 150,000 dollars. Labor standards are governed by Davis-Bacon Act wage determination NC20260122, and invoicing must be processed through the Wide Area WorkFlow system.

POSTED

DEADLINE

UNITED STATES COAST GUARD KETCHIKAN ALASKA NEW CARPET INSTALLATION

Solicitation # UNITEDSTATESCOASTGUARDKETCHNEWCARPET

Base KETCHIKAN(00035)

POSTED

DEADLINE

in about 1 month

Flooring Installation SubcontractorThe Cherokee Nation Housing Authority is seeking a flooring installation subcontractor to provide materials and labor for prime contractors on HUD single-family residence projects located in Cherokee County. The selected subcontractor will be responsible for removing existing flooring and installing new materials in accordance with the specific Work Write-Up and all applicable manufacturer installation recommendations throughout the residences. This subcontract opportunity is categorized under NAICS code 238330. Interested parties must submit their responses by the deadline of October 16, 2026. Further details regarding the procurement process can be accessed through the official Cherokee bids portal.

Cherokee Nation Housing Authority

POSTED

DEADLINE

More opportunities from North Carolina → Unc - System Office Design/construction

Same awarding agency

Millwork & CabinetryThis subcontract for millwork and cabinetry involves the supply and installation of custom cabinetry, counters, and architectural woodwork for the Talley Student Union interior improvements at North Carolina State University. The scope of work includes the delivery and installation of reception desks, shelving, and trim work, supporting prime contractors on the facility project. The opportunity is managed by the UNC System Office of Design and Construction for the state of North Carolina under NAICS code 337212. The solicitation was posted on September 23, 2026, with a response deadline of October 19, 2026.

Custom Architectural Woodwork and Millwork Manufacturing

POSTED

DEADLINE

Plumbing & Fixture InstallationThis subcontract for Plumbing and Fixture Installation involves the installation and relocation of plumbing lines and fixtures for interior improvements at the Talley Student Union at NC State University. The scope of work includes pipe routing and the installation of sinks, faucets, and drainage systems specifically for restrooms and breakrooms to ensure the delivery of fully functional plumbing systems. The project is managed under the UNC System Office of Design and Construction with a NAICS code of 238220. The solicitation was posted on September 23, 2026, and the deadline for responses is October 19, 2026.

Plumbing, Heating, and Air-Conditioning Contractors

POSTED

DEADLINE

HVAC & Mechanical ImprovementsThis subcontract for HVAC and Mechanical Improvements involves the modification and installation of heating, ventilation, and air conditioning systems for the Talley Student Union interior improvements at North Carolina State University. The scope of work includes performing ductwork modifications, installing VAV boxes, and updating thermostats to ensure a climate-controlled interior environment. The project is managed under the UNC System Office of Design and Construction and falls under NAICS code 238220. Interested parties must submit their responses by October 19, 2026, following the posting date of September 23, 2026.

Plumbing, Heating, and Air-Conditioning Contractors

POSTED

DEADLINE

Electrical Systems (Interior)This subcontract for Electrical Systems (Interior) involves performing electrical upgrades and lighting installations for the Talley Student Union interior improvements at NC State University. The scope of work includes the installation of LED lighting, power outlets, wiring, and switching systems to ensure a fully functional electrical and lighting infrastructure. The project is managed under the UNC System Office of Design and Construction with a NAICS code of 238210. The solicitation was posted on September 23, 2026, and the deadline for responses is October 19, 2026.

Electrical Contractors and Other Wiring Installation Contractors

POSTED

DEADLINE

Interior Finishes & DrywallThis subcontract for Interior Finishes and Drywall focuses on the interior improvements of the Talley Student Union at NC State University. The selected contractor will be responsible for the installation of gypsum board, taping, finishing, and painting, as well as framing and acoustic ceiling tile installation to deliver completed interior walls and ceilings. The project is managed by the UNC System Office of Design and Construction under NAICS code 238311. The solicitation was posted on September 23, 2026, with a response deadline of October 19, 2026.

Drywall and Insulation Contractors

POSTED

DEADLINE

Electrical Engineering/Testing ServicesThis subcontract for Electrical Engineering/Testing Services involves providing specialized testing and commissioning for prime contractors on Appalachian State University substation projects. The selected provider will be responsible for conducting relay testing, transformer oil analysis, and insulation resistance testing utilizing specialized diagnostic and calibration equipment. A Professional Engineer license is required to perform these services and deliver the necessary certified testing reports and commissioning documentation. The opportunity was posted on September 23, 2026, with a response deadline of October 29, 2026. Managed by the UNC System Office of Design and Construction in North Carolina, the project falls under NAICS code 541330.

Engineering Services

POSTED

DEADLINE

in about 1 month

Security Fencing and Site AccessThis subcontract for Security Fencing and Site Access involves the supply and installation of industrial security fencing and gates for prime contractors working on Appalachian State University substation projects. The scope of work includes installing chain-link fencing and security gates, as well as performing necessary grounding of the fence line to ensure a secure and enclosed substation perimeter. Eligible providers must hold a valid fencing contractor license and operate under NAICS code 238990. The project is managed by the UNC System Office Design/construction for the state of North Carolina. Interested parties must submit their responses by the deadline of October 29, 2026.

All Other Specialty Trade Contractors

POSTED

DEADLINE

in about 1 month

Civil/Site Work & Concrete RepairsThis subcontract for Civil/Site Work and Concrete Repairs involves performing structural and site repairs for prime contractors on Appalachian State University substation projects. The scope of work includes pouring concrete pads for equipment, trenching for conduits, grading, and repairing access roads or perimeter fencing using excavation equipment and concrete mixers. The final deliverables consist of completed concrete foundations, trenches, and site stabilization. The project is managed by the UNC System Office Design/Construction in North Carolina under NAICS code 238110. Qualified bidders must hold a General Contractor or Specialty Civil license. The solicitation was posted on September 23, 2026, with a response deadline of October 29, 2026.

Poured Concrete Foundation and Structure Contractors

POSTED

DEADLINE

in about 1 month

Electrical Substation Construction & RepairThis subcontract for Electrical Substation Construction and Repair involves performing specialized electrical installations and repairs for prime contractors on Appalachian State University substation projects. The scope of work includes the installation and repair of high-voltage electrical components such as transformers, circuit breakers, switchgear, and buswork, utilizing high-voltage testing equipment to ensure a fully operational system. Qualified candidates must hold a Master Electrician license and high-voltage certification. This opportunity was posted by the UNC System Office of Design and Construction on September 23, 2026, with a response deadline of October 29, 2026. The project falls under NAICS code 238210.

Electrical Contractors and Other Wiring Installation Contractors

POSTED

DEADLINE

in about 1 month

NC State University

Solicitation # 287-26482-PQ

NC State University is seeking to prequalify contractors for interior improvements to the One-Earth food service venue located within the Talley Student Union. The project involves a comprehensive renovation of approximately 4,485 square feet, encompassing kitchen, dining, food preparation, storage, refrigeration, freezer, and dishwashing areas. The primary objective of these improvements is to increase the production and throughput of the venue, with construction work anticipated to take place during the summer of 2027. Interested parties must submit a qualification application electronically to Project Manager Bob Cwikla by October 19, 2026, at 5:00 pm. Hard copy submissions will not be accepted. This presolicitation is categorized under NAICS code 236220 and is managed through the UNC System Office of Design and Construction.

Commercial and Institutional Building Construction

POSTED

DEADLINE

Appalachian State University

Solicitation # 29928-CB2

Appalachian State University is soliciting construction bids for the New River Power and Light Oak Grove Substation and Misc. Repairs project in North Carolina. The project, designed by Dewberry Engineers, Inc., involves construction repairs to the specified substation. Interested parties may obtain complete plans and specifications from the design firm, and a plan deposit of 100 dollars is required. A pre-bid meeting is scheduled for October 14, 2026, with the final deadline for bid submissions set for October 29, 2026, at 11:00 am. Bids must be delivered to the Appalachian State University Facilities Annex located at 2458 Hwy 105, Boone, NC 28607. Primary points of contact for the project include Cynthia Strader, Joe Fulk at Dewberry Engineers, and the university campus contact.

Power and Communication Line and Related Structures Construction

POSTED

DEADLINE

in about 1 month

Construction Cost Estimating & BudgetingThis subcontract for Construction Cost Estimating and Budgeting supports the UNC System Office Design/Construction projects, specifically focusing on the Poe Hall Renovation and New Education Building. The selected provider will be responsible for developing detailed cost estimates and budget reports for the demolition of a seven-story, 150,982 GSF concrete-frame structure and the subsequent construction of a replacement building, including costs for hazardous materials mitigation. The project requires the use of professional estimating software and historical cost databases to ensure accuracy. Qualified candidates must hold a valid North Carolina state license and submit an SF-330. The solicitation was posted on September 17, 2026, with a response deadline of October 9, 2026, under NAICS code 541330.

Engineering Services

POSTED

DEADLINE

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Join 750+ contractors already using CLEATUS