Psst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveCLEATUS Webinar: AI for Government Contracting — Free Webinar — Wednesday, November 11 at 2:00 PM ET

Register Free →

Search

Top

Back to Contracts

Conditional Use Permit 25-01: New Telecommunication Mono-Palm

Forecast

25-01State & Local

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

General Info

Agency

California → City of Signal Hill

NAICS

237130 - Power and Communication Line and Related Structures Construction

Place of Performance

Saint Louis Avenue and 28th Street, Signal Hill, CA, 90755

Set-Aside

NONE

Documents

0

No documents available

Documents will appear here when they are available.

AI Contract Breakdown

Uniform Contract Format

Sign up to view the full breakdown with detailed analysis of each section.

Timeline

PhaseForecast

PostedOct 15

forecast

Prepare for this forecast

Research the agency, track this forecast, and prepare your capture plan before the solicitation opens.

Organization & Contact Information

Show more

AgencyCalifornia → City of Signal Hill

Contacts1 person available

OfficeN/A

Organization / Agency

California → City of Signal Hill

Office AddressN/A

Contacts

Susana MartinezAssociate Planner

contact@example.gov

+1 (555) 000-0000

Full Description

Show more

A request for a Conditional Use Permit to allow for the construction of a new telecommunication facility consisting of a 75-foot-tall monopalm with twelve antennas, ground mounted equipment cabinets, and a standby generator within a 522 square foot fenced area on a 12,500 square foot lot. The subject site is located in the Commercial Industrial (CI) zoning district. Wireless telecommunication facilities are permitted in the CI zoning district with the approval of a Conditional Use Permit. The project will fill a significant gap in Verizons cellular phone coverage within the City of Signal Hill.

Similar Contracts

Same NAICS industry code

AAL-1440-01 RCO Relocation Hooper Bay - BNATCS

Solicitation # AAL-1440-01

Solicitation AAL-1440-01, managed by PTSI Managed Services Inc., is for the RCO relocation project located in Hooper Bay, Alaska. The scope of work involves specialized construction activities including foundation work, duct bank installation, and grounding work. This project falls under NAICS code 237130 for Power and Communication Line and Related Structures Construction, with an estimated contract magnitude between 100,000 and 250,000 dollars. The solicitation was posted on November 6, 2026, with a response deadline of November 14, 2026, and a proposed start date of December 10, 2026. This opportunity is set aside for small businesses, including certified Veteran Owned, Service-Disabled Veteran Owned, Women-Owned, and HUBZone small businesses. Interested firms should coordinate with the primary point of contact, Masanori Akers, the Parsons Subcontract Administrator.

PTSI Managed Services Inc.

POSTED

about 3 hours ago

DEADLINE

ACT-1427-00 Construction Cycle 10 (CC10) Concrete Test Pavement Construction at Wm. J. Hughes Technical Center Atlantic City, NJ

Solicitation # act-1427-00-construction-cycle-10-cc10-concrete-test-pavement-construction-wm-j-hughes-technical

Parsons Corporation is soliciting bids for the Construction Cycle 10 project at the William J. Hughes Technical Center in Atlantic City, New Jersey, supporting the FAA Airport Technology Research and Development branch. The scope of work involves the controlled demolition of existing pervious runway test pavement and the construction of new concrete test slabs measuring approximately 310 by 52.5 feet with a thickness of 15.5 inches. The selected subcontractor will be responsible for providing aggregate subbase, updating the asphalt base course to a stabilized drainable base, and performing minor design adjustments to plans and specifications. The project requires the procurement and delivery of all materials, as well as the removal and offsite disposal of all construction waste and debris. Integrated into the construction process are critical material characterization tests, including California Bearing Ratio, Plate Load, Heavy/Falling Weight Deflectometer, and Dynamic Cone Penetrometer tests, necessitating the use of professional testing laboratories and geotechnical engineering services. Work is primarily scheduled for normal business hours, Monday through Friday, though some after-hours and weekend work may be required. This opportunity is set aside for various small business categories, including VOSB, SDVOSB, WOSB, and HUBZone certified firms.

Parsons Corporation

POSTED

about 3 hours ago

DEADLINE

2027 Dalton Telecom Conduit Project

Solicitation # PE-75553-NONST-2027-000000068

The 2027 Dalton Telecom Conduit Project, managed by Dalton Utilities in Georgia, involves the installation of a new telecommunications pathway across several roads, including Industrial South Rd, Callahan Rd, Focus Dr, Brookhollow Ind Blvd, Kraft Dr, South Dalton Bypass, Howell Dr, Enterprise Dr, and Boring Dr. The scope of work requires the contractor to furnish all labor, materials, and equipment to install 11,550 linear feet of two 4-inch underground conduits via directional drilling, 190 linear feet of 12-inch HDPE case bore, and 24 telecommunications vaults (four 60x48 and twenty 48x48). The contractor is responsible for all excavation, vault installation, and site restoration, ensuring that post-construction conditions are equal to or better than pre-construction conditions, including erosion and pollution control. The contract is governed by the laws of the State of Georgia and will be awarded to the lowest responsible and responsive bidder, though the owner reserves the right to select the best overall value based on price, schedule, and experience. Performance is required within 90 calendar days of the Notice to Proceed, with bidders expected to mobilize within three weeks of the bid opening. Financial requirements include a 10% bid bond and 100% performance and payment bonds. Payment terms specify a 30-day window following invoice approval, with a maximum retainage of 10% on progress payments. Final acceptance is contingent upon a final inspection and the submission of precise as-built drawings meeting specific GPS and elevation accuracy standards.

Dalton Utilities

POSTED

about 9 hours ago

DEADLINE

in about 1 month

Energy Generation and Storage InfrastructureThis subcontract for Energy Generation and Storage Infrastructure involves the design, installation, and commissioning of energy generation and industrial-scale battery storage systems at the DOE Hanford Site in Richland. Working under prime contractors, the selected provider will ensure that critical energy supplies are established prior to the activation of other infrastructure, ultimately delivering a fully operational and grid-connected energy facility. The project requires specialized compliance, including NRC licensing for nuclear assets and the establishment of utility interconnection agreements. Interested parties should note the response deadline of January 29, 2027, for this Department of Energy effort categorized under NAICS code 237130.

Em-Environmental Management Con Bus Ctr

POSTED

about 14 hours ago

DEADLINE

Y1AZ--504-21-703 Training and Admin Support Space Construction

Solicitation # 36C25727B0001

The Amarillo VA Medical Center requires the construction of infrastructure and concrete pad space to support mobile EHRM training and administrative facilities at the Amarillo VA Health Care System in Amarillo, Texas. The scope of work includes providing electrical power, domestic water, sanitary sewer, and telecommunications fiber to three utility pad locations, constructing concrete pads according to specifications, and restoring any landscaping, roads, or sidewalks disturbed during construction. This project, identified as Project No. 504-21-703, is anticipated to be awarded as a Firm-Fixed Price Construction contract via an Invitation for Bid (IFB) in accordance with FAR Parts 14 and 36. The estimated contract value ranges between $0 and $1,000,000, with a period of performance of 183 calendar days following the issuance of the Notice to Proceed. This procurement is a set-aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB) under NAICS code 237130, which has a small business size standard of $45.0 million. To be considered responsive, offerors must be certified as an SDVOSB by the U.S. Small Business Administration (SBA) and be listed in the SBA’s Small Business Search (SBS) database prior to submission, adhering to 13 CFR Part 128 and VAAR 819.70. The tentative solicitation period is set for November 30 to December 30, 2026, with a tentative award date of January 20, 2027. Primary points of contact include Contracting Officer Makarim Abdul-Jabbar and Contracting Officer’s Representative Logan Dunn.

257-NETWORK Contract Office 17 (36C257)

POSTED

about 14 hours ago

DEADLINE

Electrical Projects – Use of Progressive Design Build (PDB) with Other Transaction Authority (OTA) - Request for Information

Solicitation # MHMV200009-MHMV120009-MHMV08002

The U.S. Air Force 377th Contracting Division is seeking market intelligence via a Request for Information (RFI) for the demolition and construction of electrical substations at Kirtland Air Force Base, New Mexico. The project involves three primary efforts: the repair of Substation 9 and its feeders, the removal of Substation 23 with load connection to Substation 24A Feeder 5, and the demolition of Substation 3 to facilitate the rebuild of a modern 10,000 KVA consolidated Substation 10. The goal is to modernize the base electrical infrastructure with 12.47 kV distribution systems, eliminate single points of failure, and ensure regulatory compliance. The government is evaluating the feasibility of using a Progressive Design-Build (PDB) delivery method under an Other Transaction (OT) Agreement pursuant to 10 U.S.C. 2808a. The scope of work requires a phased design approach, moving from conceptual design to a final 100% stamped construction document set, with a target completion date of May 2027 or sooner. Technical requirements include compliance with IBC, UFC 3-501-01, NFPA 70, and IEEE C2 standards, as well as strict adherence to Department of Defense cybersecurity protocols for electric meters. Contractors must provide a Critical Path Method schedule and engage an independent testing organization for system calibration. Key administrative requirements include the provision of performance bonds, adherence to Davis-Bacon wage rates, and strict environmental controls regarding hazardous materials and ozone-depleting compounds. Interested firms are requested to provide company profiles, relevant experience, and feedback on the proposed PDB-OTA acquisition strategy.

FA9401 377 Msg Pk

POSTED

about 14 hours ago

DEADLINE

USFK C4I Communication Tower and Facility Maintenance CY27

Solicitation # W91QVN26QXXXX

Solicitation W91QVN27QA007 is a Firm Fixed Price request for quotations to provide non-personnel maintenance and repair services for 21 C4I Communication Tower sites and related facilities supporting the 41st Signal Battalion in South Korea. The scope of work includes structural integrity assessments, physical inspections for rust and damage, bonding and grounding tests, lighting protection maintenance, LED beacon and side marker light replacement, tower painting, and lead abatement. Specific facility repairs are limited to the interior and exterior of the Osan Bucket C4I Communication Shelter. The period of performance is a 12-month base period running from January 1, 2027, to December 31, 2027, across five primary locations: CP Walker, Highpoint, Osan Bucket, Yongsan, and Papyongsan. Award will be made on an all-or-none basis to the responsible offeror submitting the lowest price technically acceptable offer. Technical acceptability is evaluated on a pass/fail basis, requiring a complete technical package and proof of mandatory ROK business licenses, specifically Information and Communication and Electrical Construction licenses. Key personnel requirements include a Contract Manager, a CQCSM/Safety Manager with an associate degree and five years of relevant experience, and a Lead Technical Engineer. All quotes must be submitted in Korean Won via PIEE by November 18, 2026, and must include both a detailed price breakdown and a completed SF 1449 pricing schedule. Performance will be monitored via a Quality Assurance Surveillance Plan and a Performance Requirements Summary to ensure compliance with NETCOM and Army regulations.

0411 Aq Hq Contract Augmented

POSTED

about 14 hours ago

DEADLINE

PSO RF 50112 FK - Dismantling and Safe Relocation of Towers at PSO New Vision Retail Outlets (NVROs), Peshawar Division

Solicitation # RF 50112 FK

The Pakistan State Oil Company Limited, through its Islamabad Divisional Office, is soliciting bids for the dismantling and safe relocation of towers at New Vision Retail Outlets within the Peshawar Division. This procurement is being conducted under PPRA Clause 32 (1)(b), with the solicitation process managed via the SAP Ariba Portal. The submission window opens on November 6, 2026, and closes on November 17, 2026. To be eligible, bidders must be active taxpayers and provide scanned copies of their valid NTN, GST/PST certificates, and the CNIC of the owner or authorized representative. Mandatory eligibility criteria include a clean record of not being blacklisted by PSO or any other firm and a safety record free of fatal accidents during project execution within the last five years. Proposals must be complete and unconditional, as partial or conditional offers, as well as any submissions containing false or incomplete information, will result in immediate rejection.

Pakistan State Oil Company Ltd

POSTED

about 21 hours ago

DEADLINE

Design, Supply, Installation, Testing and Commissioning of a 35-Meter Self-Supporting Steel Tower for Coastal Surveillance and Marine Communications Systems at the Ministry of Ports and BPMPU HQ Bossaso, Puntland State of Somalia George Macharia

Solicitation # EOIUNODC24882

The United Nations Office on Drugs and Crime is seeking Expressions of Interest from qualified companies for the design, supply, installation, testing, and commissioning of a 35-meter self-supporting steel tower in Bossaso, Puntland State of Somalia. This infrastructure will support coastal surveillance and marine communications systems at the Ministry of Ports and BPMPU HQ. The scope of work encompasses engineering design, site verification, foundation and civil works, tower erection, and the installation of equipment platforms, cable management, and aviation safety components. Eligible firms must provide certification of incorporation and be registered to operate within Puntland. This current process is an Expression of Interest intended to identify capable vendors and does not constitute a formal invitation to tender. Final solicitation documents containing complete requirements will be issued to selected interested parties following the closure of the EOI period.

POSTED

DEADLINE

80627Y0173-Neighborhood Internet Installation at HPD Bronx Family Living Center

Solicitation # 80627Y0173

The New York City Department of Housing Preservation and Development is soliciting proposals for the Neighborhood Internet pilot project at the Bronx Family Living Center. The project involves installing a hybrid fiber/fixed wireless internet network, which includes retrofitting two neighboring buildings for hotel-style Wi-Fi service and installing rooftop antennas to establish one building as a wireless hub. The selected vendor must provide 1GB+ fiber backhaul service and ongoing network maintenance for a three-year term. Technical requirements specify that the network must be certified for Wi-Fi 6 (802.11ax) or newer and comply with Citywide Privacy Protection Policies and Protocols. This is a M/WBE Noncompetitive Small Purchase, meaning only New York City-Certified M/WBE firms are eligible to apply. The contract is estimated to be valued at or above $200,000, making Local Law 63 applicable. Proposals are evaluated primarily on experience, qualifications, and capacity (75% weight), specifically regarding residential wireless and hybrid fiber/wireless deployments. Subcontracting is limited to 40% of the total contract amount, with non-M/WBE subcontractors capped at 20%, though fiber backhaul providers are exempt from this limit. All submissions, including cost proposals and required affirmations regarding the Iran Divestment Act, Macbride Principles, and tax status, must be completed through the PASSPort system.

Department Of Housing Preservation And Development

POSTED

DEADLINE

Underground Utility District 38 Overhead-to-Underground Service Conversions

Solicitation # CS 09-26-07

Alameda Municipal Power (AMP) is soliciting bids for the Underground Utility District 38 Overhead-to-Underground Service Conversions project (CS 09-26-07). The primary objective is to safely convert 195 residential electrical services from overhead to underground routing without increasing customer capacity or modernizing existing customer-owned equipment, which will be reused if deemed safe by the City Building Division. The scope includes the installation of approximately 8,389 linear feet of aluminum service conductors across standard and 3-inch lateral locations. The project is expected to start around March 1, 2027, and must be completed within 365 calendar days of the Notice to Proceed. Eligible bidders must possess a valid California C-10 Electrical Contractor license and be registered with the Department of Industrial Relations. A mandatory virtual pre-bid meeting was held on November 5, 2026, and all bids must be submitted via the OpenGov Bid Portal by November 25, 2026. The contract will be awarded to the lowest responsive and responsible bidder based on capacity, experience, and past performance. Required submissions include a 10% bid security, a subcontractor list, and a bid schedule. Once awarded, the contractor must provide performance and payment bonds for 100% of the contract price and adhere to the City of Alameda Project Stabilization Agreement to ensure labor harmony and prevailing wage compliance.

Engineering and Operations

POSTED

DEADLINE

EB - Aerial Power Data Line and Poles

Bureau of Reclamation

POSTED

DEADLINE

Earlier notices in this NAICS code

Posted before this notice, open and closed

Assurance Development

POSTED

about 1 year ago

DEADLINE

American Dark Fiber MEN 101/MEN 20 Broadband

Solicitation # 0179 ADF MEN 20 NOE

Caltrans, District 1 - Eureka

POSTED

about 1 year ago

DEADLINE

Cox Business Internet Service Cable Installation at 2200 Pacific Highway for Solar Turbines, Inc.

Solicitation # 2025-109

San Diego Unified Port District

POSTED

about 1 year ago

DEADLINE

2408 Shark - CO - 1803 Santa Ana Ave

California Public Utilities Commission

POSTED

about 1 year ago

DEADLINE

Remove/Replace SCE Pole in La Habra at PM 21.59

Caltrans, District 12 - Orange

POSTED

about 1 year ago

DEADLINE

California Aqueduct Reaches 5, 6, and 7 Westlands Water District Utility Pole Replacements

California Water Resources, Department of

POSTED

about 1 year ago

DEADLINE

National Electric Vehicle Infrastructure Formula Program

Energy Commission

POSTED

about 1 year ago

DEADLINE

725-6BB-2238 Fiber Optic Installation Project

Caltrans, District 7 - Los Angeles

POSTED

about 1 year ago

DEADLINE

TD2005867 Anaheim Avenue Deteriorated Pole Replacement Project (Notification of Lake or Streambed Alteration, No. EPIMS-SBR-55794-R6)

Solicitation # EPIMS-SBR-55794-R6

Fish and Wildlife, Region 6 - Inland Deserts, Ontario

POSTED

about 1 year ago

DEADLINE

2409 DOLPHIN-A 5701 Hollywood Blvd

California Public Utilities Commission

POSTED

about 1 year ago

DEADLINE

2409 DOLPHIN-A 3421 Huxley St

California Public Utilities Commission

POSTED

about 1 year ago

DEADLINE

T-Mobile Westview High / PRJ - 1102191

Solicitation # 1102191

City of San Diego

POSTED

about 1 year ago

DEADLINE

Prepare for this forecast

Research this forecast and prepare for the solicitation

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Join 750+ contractors already using CLEATUS