This Solicitation opportunity from Florida was posted on March 6, 2025. The submission period has ended. Browse the details below for market research, or find similar active opportunities.

Top

Courthouse Complex Mechanical & Fire Protection Upgrades Phase 1C

Closed

Y25-755State & Local

Submission Closed04/08/2025, 12:00:00 AM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

Active Opportunities Like This One

NAICS: 922160

New

SLED

Fire Alarm Inspection and CertificationThis subcontract for Fire Alarm Inspection and Certification involves providing annual inspections, testing, and certification of fire alarm systems for prime contractors operating on federal facility projects. The selected provider will be responsible for conducting comprehensive certifications, identifying system deficiencies using specialized diagnostic tools and testing equipment, and strictly adhering to the Detailed Scope of Work. The contractor must deliver certified fire alarm inspection reports and detailed deficiency lists, ensuring that the Bidder's Certification Form is validated with a corporate seal. This opportunity is associated with Philadelphia Gas Works in Pennsylvania, with a response deadline set for November 10, 2026.

Philadelphia Gas Works

POSTED

DEADLINE

2026 Volunteer Fire Capacity Grant

Solicitation # 2139681

The New York State Department of Environmental Conservation is administering the 2026 Volunteer Fire Capacity Grant Program, funded by a federal appropriation of 857,629 dollars. This program provides matching grants to eligible rural fire departments for the purchase of wildland firefighting suppression supplies. To be eligible, departments must be comprised of at least 80 percent volunteer personnel and serve a rural area, defined as a town or village with a population of 10,000 or less based on the 2020 Census. Selected departments can receive a maximum award of 3,500 dollars, which must be matched 50/50 by the recipient. Grant funds must be used for items directly related to wildland firefighting that benefit the local rural community, with a restriction that no individual item exceeds 9,999 dollars. Selection is based on the department's funding history over the previous five years, whether it is a newly formed establishment, and the presence of a Native American community within its jurisdiction. The program operates under federal guidelines from the US Forest Service and the Cooperative Forestry Assistance Act of 1978. Applications are accepted through December 30, 2026. This solicitation does not have specific goals for Service-Disabled Veteran-Owned, Minority, Women, or Disadvantaged Business Enterprises. All inquiries and applications are managed by the Volunteer Fire Capacity Grant Coordinator within the Division of Forest Protection.

NYS Department of Environmental Conservation

POSTED

DEADLINE

Supply of Fire Suppression Packing & O-RingsThis subcontract involves the supply of preformed packing and O-rings to prime contractors supporting Department of National Defence HFX Class ship projects. The scope specifically covers parts matching Part Numbers 15-0181-1256 and 130-0060, which are essential components for Halon and Aqueous Film Forming Foam fire suppression systems. All provided materials must adhere to Quality Assurance Code C. The successful provider will be responsible for delivering these components to CFB Halifax and CFB Esquimalt. This procurement is managed under the Government of Canada's Department of National Defence, with a response deadline set for November 4, 2026.

Department of National Defence

POSTED

DEADLINE

Morgantown, WV Fire Service Fee:The Department of Energy, specifically the Office of Fossil Energy, has issued a forecast for a fire service fee contract to be performed in West Virginia. This requirement is categorized under NAICS code 922160 and is currently associated with the City of Morgantown as the incumbent contractor. The forecast was posted on October 18, 2026, and is managed by the Small Business Program Manager, Brian Halstead. While specific solicitation numbers and set-aside details are not provided, the action is listed as a forecast for continued fire service support within the region.

Office of Fossil Energy

POSTED

DEADLINE

Supply of Fire Resistant Protective Clothing (FRC)This subcontract agreement involves the procurement and delivery of fire-resistant protective clothing for prime contractors working on Nashville Electric Service utility projects. The selected provider is responsible for sourcing and delivering FRC garments that strictly adhere to the technical requirements of NES Specification 26-2100ST-FRC, ensuring all fabrics and textiles comply with established electrical utility safety standards. The contract requires the physical delivery of the protective clothing to Nashville, Tennessee. Interested parties must submit their responses by November 5, 2026, in accordance with the solicitation posted on October 16, 2026.

Nashville Electric Service

POSTED

DEADLINE

NOI FDM Fire Department Support and Maintenance

Solicitation # 210-10-26

The City of Burnaby, located in British Columbia, Canada, has issued a pre-solicitation notice for the Fire Department Support and Maintenance contract. This procurement opportunity, identified by solicitation number 210-10-26, falls under NAICS code 922160 and is focused on providing essential support and maintenance services for fire department operations. The notice was posted on October 14, 2026, with a response deadline set for November 4, 2026. Interested parties can find further details and manage their submissions through the BC Bid portal. Performance of the contract will take place within the province of British Columbia.

POSTED

DEADLINE

Emergency Protection Materials SupplyThis subcontract opportunity involves the supply and storage of emergency floodwall protection materials for prime contractors working on New York State OGS Design and Construction projects. The primary objective is to furnish and deliver an on-site inventory of materials necessary to maintain system integrity specifically during Action stage levels of Cayuga Creek. The solicitation is managed by NYS OGS Design and Construction for the state of New York under NAICS code 922160. Interested parties must submit their responses by the deadline of November 18, 2026.

NYS OGS Design & Construction - Construction Contractors

POSTED

DEADLINE

26-013 RFp Fire Protection Services

Solicitation # 234865

Thompson Rivers University, operating under the Province of British Columbia, has issued solicitation 234865 for Fire Protection Services. This procurement opportunity is categorized under NAICS code 922160 and requires the performance of services within British Columbia, Canada. The solicitation was officially posted on October 9, 2026, and interested parties must submit their responses by the deadline of November 6, 2026, at 9:00 PM. Detailed information and submission guidelines can be accessed through the BC Bid portal.

Thompson Rivers University

POSTED

DEADLINE

BPA - Fire fighting Equipment PSC 4210

Solicitation # N0017424SN0017

The Naval Surface Warfare Center Indian Head Division is seeking to establish Blanket Purchase Agreements with small businesses to provide standard commercial fire fighting equipment under NAICS 922160 and PSC/FSC Code 4210. These BPAs are designed for requirements that do not exceed the Simplified Acquisition Threshold, with competition occurring at the call level. Qualified vendors will be issued a Master BPA, allowing them to bid on future requirements through June 2029. To be considered, interested companies must provide a cover sheet with company details, documentation of capabilities and expertise, and a price list. A critical component of the evaluation is past performance, requiring at least three references to be assessed on customer satisfaction, timeliness, technical success, program management, and quality. Applicants must also maintain active accounts in the System for Award Management and the Procurement Integrated Enterprise Environment. While the government previously established a rolling admission cycle with deadlines in April and October, the process is currently paused as the agency explores automation enhancements. Future inquiries should be directed to the designated IHD BPA email inbox.

Nswc Indian Head Division

POSTED

DEADLINE

Fire Alarm System Equipment SupplyThis subcontract, titled Fire Alarm System Equipment Supply, involves the procurement and delivery of specialized hardware and components for prime contractors working on North Carolina Department of Adult Correction projects at the Wake Correctional Center. The scope of work includes providing fire alarm panels, sensors, and notification devices that adhere to project specifications and UL listing standards, with all equipment delivered directly to the project site. The contract is managed by the State of NC Construction Office and falls under NAICS code 922160. It was posted on September 22, 2026, with a response deadline of November 3, 2026.

State of NC - Construction Office

POSTED

DEADLINE

YOSE - 13870 - YOSE Purchase Fire Engine to Replace Engine 23The Department of the Interior is forecasting the procurement of a new fire engine to replace Engine 23 for YOSE. This requirement is currently listed as a forecast with a posted date of September 2, 2026. The project is managed by Raymond P. McPadden, with additional support provided by the Contract Support Center. While the current NAICS code is listed as 922160, there is a noted discrepancy regarding its accuracy.

POSTED

DEADLINE

SAMA - 17181 - Replace and upgrade Fire Alarm panels and other infrastrucure and communications at 6 historic SAMA BuildingsThe Department of the Interior is seeking a contractor to replace and upgrade fire alarm infrastructure across six historic SAMA buildings. The scope of work includes the replacement of five fire alarm panels, one master panel, all associated devices, specific portions of the wiring, and the communications components necessary to ensure required protection for these structures. This project is currently listed as a forecast under NAICS code 922160. Interested parties can coordinate with Jennifer Hardin or the Contract Support Center for further details regarding this requirement.

POSTED

about 2 months ago

DEADLINE

N/A

AI Contract Overview

Orange County, Florida is seeking sealed bids for the Courthouse Complex Mechanical & Fire Protection Upgrades Phase 1C project, with an estimated cost of approximately $3.2 million. The project involves upgrading the mechanical and fire protection systems at the courthouse complex and requires bidders to submit their responses electronically through the OpenGov e-Procurement Platform by 4:00 pm EST on April 8, 2025. Bidders must create a free account on the platform to participate, and all responses must be submitted via this portal, as late or non-compliant submissions will be rejected. The county emphasizes the importance of timely uploads and provides technical support contacts for assistance. Questions regarding the solicitation are to be submitted through the OpenGov question and answer module by March 18, 2025, with no direct contact allowed with the initiating division. Any modifications or clarifications to the solicitation will be issued as written addenda available for download, which will become part of the contract documents. The project is managed by the Orange County Procurement Division, and interested parties can find additional details and updates through the provided online portal link. The contract falls under NAICS code 922160 and is managed by the Florida-based Orange County Administrative Service.

General Info

Agency

Florida → Orange County Administrative Service, Procurement Division

NAICS

922160 - Fire Protection

Place of Performance

FL, USA

Set-Aside

NONE

Documents

Orange County Courthouse Smoke Control Repair - Bid Specifications

specifications

High

Y25-755 Courthouse Complex Mechanical & Fire Protection Upgrades Phase 1C

ifb

High

AI Contract Breakdown

Uniform Contract Format

Timeline

PhaseClosed

PostedMar 6

Solicitation

Response DeadlineApr 8

Deadline has passed

Submission Closed

04/08/2025, 12:00:00 AM UTC

Find active opportunities like this

Get full access to discover similar active contracts, track opportunities, and build proposals with AI assistance.

Organization & Contact Information

AgencyFlorida → Orange County Administrative Service, Procurement Division

Contacts1 person available

OfficeN/A

Organization / AgencyFlorida → Orange County Administrative Service, Procurement Division

Office AddressN/A

Contacts

Gerson Vazquez Gonzalez

contact@example.gov

+1 (555) 000-0000

Full Description

NOTICE IS HEREBY GIVEN that Orange County, Florida, henceforth referred to as the County is accepting sealed bids for Courthouse Complex Mechanical & Fire Protection Upgrades Phase 1C (Y25-755)Sealed offers for furnishing the above will be accepted up to 4:00 pm EST on Tuesday, April 8, 2025.The Estimated Cost for this project is $3,200,000.00NOTE: Respondents are required to submit responses electronically via the OpenGov e-Procurement Platform. Respondents shall not be permitted to hand-deliver, mail, telephone, fax or email offers.Responses received after the submission deadline and/or transmitted outside of the designated OpenGov e-Procurement Platform shall be rejected.Important Instructions for Electronic SubmittalThe County is ONLY accepting electronic bid submissions using the OpenGov e-Procurement Platform. Respondents shall create a FREE account with OpenGov by signing up at https://procurement.opengov.com/login Once you have completed account registration, browse back to this page, click on Submit Response, and follow the instructions to submit the electronic bid.It is the respondent's responsibility to ensure they commence their upload efforts timely to meet the submission deadline. The County shall not be responsible for delays caused by any occurrence, including the respondent's network delays, bandwidth issues, internet outages, or technical difficulties.OpenGov Technical SupportFor Technical Support, respondent's can reach the OpenGov Service Desk:Chat (preferred): Click the button in the lower right hand corner of the portal Email: contact@example.gov: +1 (555) 000-0000 Hours: Mon-Fri 7am - 10pm ESTTimely Questions Regarding this SolicitationThe question and answer module of OpenGov IS being utilized for this solicitation. Timely questions concerning this solicitation shall be submitted in accordance with the deadline for questions: Tuesday, March 18, 2025 at 4:00 pm EST. Respondents are instructed not to contact the initiating division directly.Consideration for modification or alteration of the documents contained in this solicitation shall be requested during the specified question period, before the applicable deadline. No oral interpretation of the meaning of the plans, specifications, or other Contract documents shall be considered binding. The County shall be bound by information and statements only when such statements are written and executed under the authority of the Manager, Procurement Division.Answers for timely questions will be addressed in the OpenGov question and answer module or as an addenda to this solicitation depending on volume, participants are encouraged to subscribe as a follower and monitor all notifications. Beyond questions and answers, any and all modifications, clarifications, interpretations and supplemental instructions will be in the form of a written addendum which, if issued, will be available for download. All addenda and questions/answers so issued shall become part of the Contract Documents and receipt shall be acknowledged as specified herein.This provision exists solely for the convenience and administrative efficiency of Orange County. No respondent or other third party gains any rights by virtue of this provision or the application thereof, nor shall any respondent or third party have any standing to sue or cause of action arising there from.Untimely questions are unable to be submitted in the question and answer module, thereafter respondents raising critical concerns must email contact@example.gov. Critical clarifications may be made via addenda, however, untimely questions may not be considered.