RF Chamber Shielding

Solicitation Number: F2KBAB3031A001 Notice Type: Combined Synopsis/Solicitation Synopsis: This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in FAR Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotes are requested and a written solicitation will not be issued. This requirement is advertised as Full and Open Competition. The NAICS Code for this synopsis/solicitation is __334511__, Search, Detection, Navigation, Guidance, Aeronautical, and Nautical System and Instrument Manufacturing, Size Standard 750 employees. Solicitation/Purchase Requisition Number F2KBAB3031A001 is issued as a Request for Quote (RFQ). This document incorporates provisions and clauses that are in effect through Federal Acquisition Circular 2005-68 effective 26 June 2013. This solicitation is to purchase items for AFRL/6TRDHE to upgrade the High Energy Laboratory Radio Frequency Chamber. See upload of all items needed. This acquisition shall be procured as brand name or equal in accordance with FAR 52.211-6. NOTE: please provide a BRAND NAME OR EQUIVALENT quote for the item(s) below. If an "or EQUIVALENT" quote is submitted, the proposal will be sent to the technical advisor for compatibility and verification. Any offeror providing an "or equal" product shall describe thoroughly how their product meets all the required characteristics listed below in the statement of objectives. Failure to do so will render that offeror non-responsive and will not be considered for award. The Government intends to award one (1) contract with five (5) contract line item number: Award shall be made to the offeror that can provide the requirement that represents the best value and meets all the minimum requirements of the government. (CLIN 0001) Product: Anechoic absorbers - various sizes QTY: 1 Unit of Issue: LT Desired Delivery Date: 8 weeks ARO FOB: Destination Inspection and Acceptance: Destination (CLIN 0002) Product: 2 ft. Pyramidal cones QTY: 1 Unit of Issue: LT Desired Delivery Date: 8 weeks ARO FOB: Destination Inspection and Acceptance: Destination (CLIN 0003) Product: 4 by 4 walkway absorbers QTY: 35 Unit of Issue: EA Desired Delivery Date: 8 weeks ARO FOB: Destination Inspection and Acceptance: Destination (CLIN 0004) Product: Flexsorb or equivalent RAM material QTY: 1 Unit of Issue: LT Desired Delivery Date: 8 weeks ARO FOB: Destination Inspection and Acceptance: Destination (CLIN 0005) Product: Manufacture, Design & Installation QTY: 1 Unit of Issue: LT Desired Delivery Date: 8 weeks ARO See attached statement of work. In accordance with Subpart 12.6, as supplemented with additional information included in this notice. Offerors are notified that award will be made on the basis of best value. Failure to furnish supporting documentation expressly requested and necessary for the agency to perform, price, cost and/or cost realism analysis is grounds to reject the quote All offers are due no later than 15 July 2013 (Mountain Standard Time) 1600. Offers may be mailed to AFNWC/PZIB, ATTN: Susan Myers, 8500 Gibson Blvd., SE, Bldg. 20202, Office 224, Kirtland AFB, NM 87117, emailed to Susan.Myers@Kirtland.af.mil, or faxed to (505) 853-3476 ATTN Susan Myers. Be advised that all interested parties must be registered in the System for Award Management database in order to receive an award. If you are not registered you may request an application at (888) 227-2423 or through the SAM website at http://www.sam.gov. All payments are to be paid via the Internet through the Wide Area Work Flow (WAWF) system. WAWF may be accessed at https://wawf.eb.mil. WAWF training may be accessed online at http://www.wawftraining.com. Payment information may be accessed using the DFAS website at https:www.dfas.mil. Your purchase order/contract number or invoice will be required to inquire status of your payment The following provisions and clauses apply to FedBizOps RFQ: F2KBAB3031A001 procurement: FAR 52.211-6 -- Brand Name or Equal 52.202-1 DEFINITIONS (JAN 2012) (IAW FAR 2.201) 52.203-3 GRATUITIES (APR 1984) (IAW FAR 3.202) 52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (JAN 1997) (IAW FAR 3.104-9(b)) 52.203-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (APR 2010) (IAW FAR 3.1004(a)) 52.203-16 PREVENTING PERSONAL CONFLICTS OF INTEREST (DEC 2011) (IAW FAR 3.1106) 252.203-7000 REQUIREMENTS RELATING TO COMPENSATION OF FORMER DOD OFFICIALS (SEP 2011) (IAW DFARS 203.171-4) 252.203-7002 REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS (JAN 2009) (IAW DFARS 203.970) 52.204-1 APPROVAL OF CONTRACT (DEC 1989) (IAW FAR 4.103) This contract is subject to the written approval of (designated agency official) and shall not be binding until so approved. This clause is applicable at various dollar levels for specific activities. If this contract requires approval at a level above the Contracting Officer in accordance with agency procedures, such approval will be shown on the cover page of the contract at the time of contract issuance. 52.204-2 SECURITY REQUIREMENTS (AUG 1996) (IAW FAR 4.404(a)) 52.204-2 SECURITY REQUIREMENTS -- ALTERNATE I (APR 1984) (IAW FAR 4.404(b)) 52.204-2 SECURITY REQUIREMENTS -- ALTERNATE II (APR 1984) (IAW FAR 4.404(c)) 52.204-7 CENTRAL CONTRACTOR REGISTRATION (FEB 2012) (IAW FAR 4.1105) 52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS (FEB 2012) (IAW FAR 4.1403(a)) 252.204-7003 CONTROL OF GOVERNMENT PERSONNEL WORK PRODUCT (APR 1992) (IAW DFARS 204.404-70(b)) 252.204-7004 ALTERNATE A, CENTRAL CONTRACTOR REGISTRATION (SEP 2007) (IAW DFARS 204.1104) 252.204-7008 EXPORT-CONTROLLED ITEMS (APR 2010) (IAW DFARS 204.7304) 52.209-1 QUALIFICATION REQUIREMENTS (FEB 1995) (IAW FAR 9.206-2) (a) Definition: "Qualification Requirement," as used in this clause, means a Government requirement for testing or other quality assurance demonstration that must be completed before award. (b) One or more qualification requirements apply to the supplies or services covered by this contract. For those supplies or services requiring qualification, whether the covered product or service is an end item, the product, manufacturer, or source must have demonstrated that it meets the standards prescribed for qualification before award of this contract. The product, manufacturer, or source must be qualified at the time of award whether or not the name of the product, manufacturer, or source is actually included on a qualified products list, qualified manufacturers list, or qualified bidders list. Offerors should contact the agency activity designated below to obtain all requirements that they or their products or services, or their subcontractors or their products or services, must satisfy to become qualified and to arrange for an opportunity to demonstrate their abilities to meet the standards specified for qualification. Item No Agency Name/Address (c) If an offeror, manufacturer, source, product or service covered by a qualification requirement has already met the standards specified, the relevant information noted below should be provided. Offeror's Name ______________________________ Manufacturer's Name _________________________ Source's Name ______________________________ Item Name _________________________________ Service Identification _________________________ Test Number _______________________________ (to the extent known) (d) Even though a product or service subject to a qualification requirement is not itself an end item under this contract, the product, manufacturer, or source must nevertheless be qualified at the time of award of this contract. This is necessary whether the Contractor or a subcontractor will ultimately provide the product or service in question. If, after award, the Contracting Officer discovers that an applicable qualification requirement was not in fact met at the time of award, the Contracting Officer may either terminate this contract for default or allow performance to continue if adequate consideration is offered and the action is determined to be otherwise in the Government's best interests. (e) If an offeror, manufacturer, source, product, or service has met the qualification requirement but is not yet on a qualified products list, qualified manufacturers list, or qualified bidders list, the offeror must submit evidence of qualification prior to award of this contract. Unless determined to be in the Government's interest, award of this contract shall not be delayed to permit an offeror to submit evidence of qualification. (f) Any change in location or ownership of the plant where a previously qualified product or service was manufactured or performed requires reevaluation of the qualification. Similarly, any change in location or ownership of a previously qualified manufacturer or source requires reevaluation of the qualification. The reevaluation must be accomplished before the date of award. 52.209-3 FIRST ARTICLE APPROVAL--CONTRACTOR TESTING (SEP 1989) (IAW FAR 9.308-1(a)(1), FAR 9.308-1(b)(1)) a) The Contractor shall test ** unit(s) of Lot/Item * as specified in this contract. At least *** calendar days before the beginning of first article tests, the Contractor shall notify the Contracting Officer, in writing, of the time and location of the testing so that the Government may witness the tests. *Lot/Item ***Calendar Days Before Test **Quantity (b) The Contractor shall submit the first article test report within ___**___ calendar days from the date of this contract to ___***___ marked "FIRST ARTICLE TEST REPORT: Contract No. Lot/Item No. ___*___" Within ___****___ calendar days after the Government receives the test report, the Contracting Officer shall notify the Contractor, in writing, of the conditional approval, approval, or disapproval of the first article. The notice of conditional approval or approval shall not relieve the Contractor from complying with all requirements of the specifications and all other terms and conditions of this contract. A notice of conditional approval shall state any further action required of the Contractor. A notice of disapproval shall cite reasons for the disapproval. *Lot/Item ****Approval Days ELIN No. FA Test Report Item ***Type/Location **Calendar Days 52.209-3 FIRST ARTICLE APPROVAL--CONTRACTOR TESTING -- ALTERNATE I (JAN 1997) (IAW FAR 9.308-1(a)(2), FAR 9.308-1(b)(2)) 52.209-3 FIRST ARTICLE APPROVAL--CONTRACTOR TESTING -- ALTERNATE II (SEP 1989) (IAW FAR 9.308-1(a)(3), FAR 9.308-1(b)(3)) 52.209-4 FIRST ARTICLE APPROVAL--GOVERNMENT TESTING (SEP 1989) (IAW FAR 9.308-2(a)(1), FAR 9.308-2(b)(1)) (a) The Contractor shall deliver ** units(s) of Lot/Item * within *** calendar days from the date of this contract to the Government at **** for first article tests. First Article Item **Quantity ***Calendar Days ****Type/Location (b) Within ** calendar days after the Government receives the first article, the Contracting Officer shall notify the Contractor, in writing, of the conditional approval, approval, or disapproval of the first article. *Lot/Item **Approval Days ELIN No. (c) If the first article is disapproved, the Contractor, upon Government request, shall submit an additional first article for testing. After each request, the Contractor shall make any necessary changes, modifications, or repairs to the first article or select another first article for testing. All costs related to these tests are to be borne by the Contractor, including any and all costs for additional tests following a disapproval. The Contractor shall furnish any additional first article to the Government under the terms and conditions and within the time specified by the Government. The Government shall act on this first article within the time limit specified in paragraph (b) above. The Government reserves the right to require an equitable adjustment of the contract price for any extension of the delivery schedule or for any additional costs to the Government related to these tests. 52.209-4 FIRST ARTICLE APPROVAL--GOVERNMENT TESTING -- ALTERNATE I (JAN 1997) (IAW FAR 9.308-2(a)(2), FAR 9.308-2(b)(2)) 52.209-4 FIRST ARTICLE APPROVAL--GOVERNMENT TESTING -- ALTERNATE II (SEP 1989) (IAW FAR 9.308-2(a)(3), FAR 9.308-2(b)(3)) 52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (DEC 2010) (IAW FAR 9.409) 52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS (MAY 2012) (IAW FAR 9.108-5(b)) 52.211-8 TIME OF DELIVERY (JUN 1997) (IAW FAR 11.404(a)(2)) (a) The Government requires delivery to be made according to the following schedule: DELIVERY FOR EACH ITEM IS ANNOTATED IN THE SCHEDULE (PART I SECTION B) UNDER EACH LINE ITEM. The Government will evaluate equally, as regards time of delivery, offers that propose delivery of each quantity within the applicable delivery period specified above. Offers that propose delivery that will not clearly fall within the applicable required delivery period specified above, will be considered nonresponsive and rejected. The Government reserves the right to award under either the required delivery schedule or the proposed delivery schedule, when an offeror offers an earlier delivery schedule than required above. If the offeror proposes no other delivery schedule, the required delivery schedule above will apply. ANNOTATE YOUR PROPOSED DELIVERY, IF ANY, UNDER THE GOVERNMENT'S DELIVERY SET FORTH UNDER EACH ITEM IN THE SCHEDULE. (b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed, or otherwise furnished to the successful offeror, results in a binding contract. The Government will mail or otherwise furnish to the offeror an award or notice of award not later than the day award is dated. Therefore, the offeror should compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the Contractor's date of receipt of the contract or notice of award by adding (1) five calendar days for delivery of the award through the ordinary mails, or (2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term "working day" excludes weekends and U.S. Federal holidays.) If, as so computed, the offered delivery date is later than the required delivery date, the offer will be considered nonresponsive and rejected. 52.211-8 TIME OF DELIVERY -- ALTERNATE I (APR 1984) (IAW FAR 11.404(a)(2)) If the delivery schedule is expressed in terms of specific calendar dates or specific periods and is based on an assumed date of award, the contracting officer may substitute the following paragraph (b) for paragraph (b) of the basic clause. The time may be expressed by substituting "on or before"; "during the months ..."; or "not sooner than ... or later than ..." as headings for the third column of paragraph (a) the basic clause. (b) The delivery dates or specific periods above are based on the assumption that the Government will make award by . Each delivery date in the delivery schedule above will be extended by the number of calendar days after the above date that the contract is in fact awarded. Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed or otherwise furnished to the successful offeror results in a binding contract. Therefore, the offeror should compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. 52.211-8 TIME OF DELIVERY -- ALTERNATE I (APR 1984) (IAW FAR 11.404(a)(2)) If the delivery schedule is expressed in terms of specific calendar dates or specific periods and is based on an assumed date of award, the contracting officer may substitute the following paragraph (b) for paragraph (b) of the basic clause. The time may be expressed by substituting "on or before"; "during the months ..."; or "not sooner than ... or later than ..." as headings for the third column of paragraph (a) the basic clause. (b) The delivery dates or specific periods above are based on the assumption that the Government will make award by [Contracting Officer insert date]. Each delivery date in the delivery schedule above will be extended by the number of calendar days after the above date that the contract is in fact awarded. Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed or otherwise furnished to the successful offeror results in a binding contract. Therefore, the offeror should compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. 52.211-8 TIME OF DELIVERY -- ALTERNATE II (APR 1984) (IAW FAR 11.404(a)(2)) If the delivery schedule is expressed in terms of specific calendar dates or specific periods and is based on an assumed date the contractor will receive notice of award, the contracting officer may substitute the following paragraph (b) for paragraph (b) of the basic clause. The time may be expressed by substituting "within days after the date of receipt of a written notice of award" as the heading for the third column of paragraph (a) of the basic clause. (b) The delivery dates or specific periods above are based on the assumption that the successful offeror will receive notice of award by . Each delivery date in the delivery schedule above will be extended by the number of calendar days after the above date that the Contractor receives notice of award; provided, that the Contractor promptly acknowledges receipt of notice of award. 52.211-8 TIME OF DELIVERY -- ALTERNATE III (APR 1984) (IAW FAR 11.404(a)(2)) If the delivery schedule is to be based on the actual date the contractor receives a written notice of award, the contracting officer may be delete paragraph (b) of the basic clause. The time may be expressed by substituting "within days after the date of receipt of a written notice of award" as the heading for the third column of paragraph (a) of the basic clause. 52.211-9 DESIRED AND REQUIRED TIME OF DELIVERY (JUN 1997) (IAW FAR 11.404(a)(3)) (a) The Government desires delivery to be made according to the following schedule: DELIVERY FOR EACH LINE ITEM IS ANNOTATED IN THE SCHEDULE (PART I SECTION B) UNDER EACH LINE ITEM. If the offeror is unable to meet the desired delivery schedule, it may, without prejudicing evaluation of its offer, propose a delivery schedule below. However, the offeror's proposed delivery schedule must not extend the delivery period beyond the time for delivery in the Government's required delivery schedule as follows: DELIVERY FOR EACH ITEM IS ANNOTATED IN THE SCHEDULE (PART I SECTION B) UNDER EACH LINE ITEM. Offers that propose delivery of a quantity under such terms or conditions that delivery will not clearly fall within the applicable required delivery period specified above, will be considered nonresponsive and rejected. If the offeror proposes no other delivery schedule, the desired delivery schedule above will apply. ANNOTATE YOUR PROPOSED DELIVERY, IF ANY, UNDER THE GOVERNMENT'S DELIVERY SET FORTH UNDER EACH ITEM IN THE SCHEDULE. (b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed, or otherwise furnished to the successful offeror, results in a binding contract. The Government will mail or otherwise furnish to the offeror an award or notice of award not later than the day award is dated. Therefore, the offeror shall compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the Contractor's date of receipt of the contract or notice of award by adding (1) five calendar days for delivery of the award through the ordinary mails, or (2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term "working day" excludes weekends and U.S. Federal holidays.) If, as so computed, the offered delivery date is later than the required delivery date, the offer will be considered nonresponsive and rejected. 52.211-9 DESIRED AND REQUIRED TIME OF DELIVERY -- ALTERNATE I (APR 1984) (IAW FAR 11.404(a)(3)) If the delivery schedule is expressed in terms of specific calendar dates or specific periods and is based on an assumed date of award, the contracting officer may substitute the following paragraph (b) for paragraph (b) of the basic clause. The time may be expressed by substituting "on or before"; "during the months __ "; or "not sooner than __ , or later than __ " as headings for the third column of paragraph (a) of the basic clause. (b) The delivery dates or specific periods above are based on the assumption that the Government will make award by ___*___. Each delivery date in the delivery schedule above will be extended by the number of calendar days after the above date that the contract is in fact awarded. Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed or otherwise furnished to the successful offeror results in a binding contract. Therefore, the offeror shall compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. *Item No *Government will make award by 52.211-9 DESIRED AND REQUIRED TIME OF DELIVERY -- ALTERNATE II (APR 1984) (IAW FAR 11.404(a)(3)) If the delivery schedule is expressed in terms of specific calendar dates or specific periods and is based on an assumed date the contractor receives notice of award, the contracting officer may substitute the following paragraph (b) for paragraph (b) of the basic clause. The time may be expressed by substituting "within days after the date of receipt of a written notice of award" as the heading of the third column of paragraph (a) of the basic clause. (b) The delivery dates or specific periods above are based on the assumption that the successful offeror will receive notice of award by * . Each delivery date in the delivery schedule above will be extended by the number of calendar days after the above date that the Contractor receives notice of award; provided, that the Contractor promptly acknowledges receipt of notice of award. *Item No *Delivery Number *Government will make award by 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) (IAW FAR 11.404(b)) The Contractor shall be required to (a) commence work under this contract within * calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than ** . The time stated for completion shall include final cleanup of the premises. Item No *Commence Work Within **Complete No Later Than 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK -- ALTERNATE I (APR 1984) (IAW FAR 11.404(b)) The completion date is based on the assumption that the successful offeror will receive the notice to proceed by ** . Item No *Date 52.211-11 LIQUIDATED DAMAGES--SUPPLIES, SERVICES OR RESEARCH AND DEVELOPMENT (SEP 2000) (IAW FAR 11.503(a)) (a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $ per calendar day of delay. 52.211-13 TIME EXTENSIONS (SEP 2000) (IAW FAR 11.503(b), FAR 11.503(c)) 52.211-16 VARIATION IN QUANTITY (APR 1984) (IAW FAR 11.703(a)) (b) The permissible variation shall be limited to: Percent increase (See individual line item(s)) Percent decrease (See individual line item(s)) This increase or decrease shall apply to (See individual line item(s)). 52.212-4 CONTRACT TERMS AND CONDITIONS--COMMERCIAL ITEMS (FEB 2012) (IAW FAR 12.301(b)(3)) 52.212-4 CONTRACT TERMS AND CONDITIONS--COMMERCIAL ITEMS -- ALTERNATE I (OCT 2008) (IAW FAR 12.301(b)(3)) 52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS--COMMERCIAL ITEMS (MAY 2012) (IAW FAR 12.301(b)(4)) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.222-50, Combating Trafficking in Persons (Feb 2009) (22 U.S.C. 7104(g)). __X __ Alternate I (Aug 2007) of 52.222-50 (22 U.S.C. 7104(g)). (2) 52.233-3, Protest After Award (Aug 1996)(31 U.S.C 3553). (3) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004)(Pub. L. 108-77, 108-78). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] __X __ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sep 2006), with Alternate I (Oct 1995)(41 U.S.C. 253g and 10 U.S.C. 2402). __X __ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)). __ __ (3) 52.203-15, Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.) __X __ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Feb 2012) (Pub. L. 109-282) (31 U.S.C. 6101 note). __ __ (5) 52.204-11, American Recovery and Reinvestment Act-Reporting Requirements (Jul 2010) (Pub. L. 111-15). __X __ (6) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Dec 2010) (31 U.S.C. 6101 note). __X __ (7) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Feb 2012) (41 U.S.C. 2313). __ __ (8) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (May 2012) (section 738 of Division C of Pub. L. 112-74, section 740 of Division C of Pub. L. 111-117, section 743 of Division D of Pub. L. 111-8, and section 745 of Division D of Pub. L. 110-161). __X __ (9) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011)(15 U.S.C. 657a). __X __ (10) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Jan 2011) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a). (11) [Reserved] __X __ (12) (i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011)(15 U.S.C. 644). __ __ (12) (ii) Alternate I (Nov 2011). __X __ (12) (iii) Alternate II (Nov 2011). __X __ (13) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003)(15 U.S.C. 644). __ __ (13) (ii) Alternate I (Oct 1995) of 52.219-7. __ __ (13) (iii) Alternate II (Mar 2004) of 52.219-7. __X __ (14) 52.219-8, Utilization of Small Business Concerns (Jan 2011) (15 U.S.C. 637(d)(2) and (3)). __X __ (15) (i) 52.219-9, Small Business Subcontracting Plan (Jan 2011)(15 U.S.C. 637(d)(4)). __X __ (15) (ii) Alternate I (Oct 2001) of 52.219-9. __X __ (15) (iii) Alternate II (Oct 2001) of 52.219-9. __X __ (15) (iv) Alternate III (Jul 2010) of 52.219-9. __X (16) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)). __X (17) 52.219-14, Limitations on Subcontracting (Nov 2011)(15 U.S.C. 637(a)(14)). __X __ (18) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). __ __ (19) (i) 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns (Oct 2008)(10 U.S.C. 2323) (if the offeror elects to waive the adjustment, it shall so indicate in its offer). (In accordance with DDP Memo dated 12 Mar 2010, DAR Tracking Number 2010-O0006, Immediate Cessation of the Use of Price Evaluation Adjustment for Small Disadvantaged Businesses, this clause is suspended in DoD. Effective until incorporated into the FAR or DFARS or until rescinded.) __ __ (19) (ii) Alternate I (June 2003) of 52.219-23. (In accordance with DDP Memo dated 12 Mar 2010, DAR Tracking Number 2010-O0006, Immediate Cessation of the Use of Price Evaluation Adjustment for Small Disadvantaged Businesses, this clause is suspended in DoD. Effective until incorporated into the FAR or DFARS or until rescinded.) __ __ (20) 52.219-25, Small Disadvantaged Business Participation Program-Disadvantaged Status and Reporting (Dec 2010)(Pub. L. 103-355, section 7102, and 10 U.S.C. 2323). __ __ (21) 52.219-26, Small Disadvantaged Business Participation Program-Incentive Subcontracting (Oct 2000) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323). __X __ (22) 52.219-27, Notice of Total Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011)(15 U.S.C. 657 f). __X __ (23) 52.219-28, Post Award Small Business Program Rerepresentation (Apr 2012) (15 U.S.C. 632(a)(2)). __X __ (24) 52.219-29, Notice of Set-Aside for Economically Disadvantaged Women-Owned Small Business (EDWOSB) Concerns (Apr 2012) (1 U.S.C. 637(m)). __X __ (25) 52.219-30, Notice of Set-Aside for Women-Owned Small Business (WOSB) Concerns Eligible Under the WOSB Program (Apr 2012) (15 U.S.C. 637(m)). __X __ (26) 52.222-3, Convict Labor (June 2003)(E.O. 11755). __X __ (27) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Mar 2012)(E.O. 13126). __X __ (28) 52.222-21, Prohibition of Segregated Facilities (Feb 1999). __X __ (29) 52.222-26, Equal Opportunity (Mar 2007)(E.O. 11246). __X __ (30) 52.222-35, Equal Opportunity for Veterans (Sep 2010)(38 U.S.C. 4212). __X __ (31) 52.222-36, Affirmative Action For Workers with Disabilities (Oct 2010)(29 U.S.C. 793). __X __ (32) 52.222-37, Employment Reports on Veterans (Sep 2010)(38 U.S.C. 4212). __X __ (33) 52.222-40, Notification of Employee Rights Under the National Labor relations Act (Dec 2010) E.O. 13496). __ __ (34) 52.222-54, Employment Eligibility Verification (Jan 2009). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) __X __ (35) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008)(42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) __ _ (35) (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) __X __ (36) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42.U.S.C. 8259b). __X __ (37) (i) 52.223-16, IEEE 1680 Standard for the Environmental Assessment of Personal Computer Products (Dec 2007) (E.O. 13423). __ _ (37) (ii) Alternate I, (Dec 2007) of 52.223-16. __X __ (38) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011). __X __ (39) 52.225-1, Buy American Act--Supplies (Feb 2009)(41 U.S.C. 10a-10d). __X __ (40) (i) 52.225-3,...