Skip to main contentPsst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveFree Webinar — Wednesday, October 28 at 2:00 PM ET

Register Free →

Roof Replacement at Gunston Elementary School

Active
MMB-022-27State & Local

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

Fairfax County Public Schools has issued Invitation for Bid MMB-022-27 for the Roofing Replacement Project at Gunston Elementary School in Lorton, Virginia. The project requires a contractor to provide all labor, materials, equipment, permits, and related services necessary to complete the roof replacement in accordance with provided specifications and drawings. The work must be completed by September 30, 2027, and the contract includes a liquidated damages penalty of 1,000 dollars per calendar day for any delays beyond this completion date. Participation is restricted to prequalified bidders, who must attend a mandatory pre-bid meeting on October 27, 2026, at 10:00 a.m. at the school site to remain eligible for award. Sealed bids must be submitted by November 12, 2026, at 3:00 p.m., with a public bid opening scheduled for 10:00 a.m. that same day via Google Meet. Bids must be comprehensive, including all applicable sales or use taxes and costs required to finish the work in its entirety.

General Info

Roof replacement at Gunston Elementary School due September 30, 2027, for prequalified bidders.

Place of Performance

VA, USA

Set-Aside

NONE

Documents

1

IFB No. MMB-022-27 Roofing Replacement Project at Gunston ES

PDF, High priority: read this firstifb
High

AI Contract Breakdown

Uniform Contract Format

Sign up to view the full breakdown with detailed analysis of each section.

Timeline

PhaseSolicitation
Posted

Solicitation

Response Deadline

Submission deadline

Response Deadline

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more
AgencyVirginia → Fairfax County Public Schools
ContactsNo contacts available
OfficeVA, USA
Office AddressVA, USA
ContactsNo contact information available

Full Description

Show more
Bidders: You are invited to submit a sealed bid for the following: Furnish all labor, materials, and related services required for the Roofing Replacement Project at Gunston Elementary School in accordance with the contract specifications and drawings. Bid documents will be available for download from the Bonfire website one week prior to the mandatory pre-bid meeting and will also be available for pickup at the meeting.
A mandatory pre-bid meeting will be held October 27, 2026*, at 10:00 a.m. at Gunston Elementary School, 10100 Gunston Road, Lorton, Virginia 22079. Contractors shall meet in the Lobby of the building’s front entrance to sign the meeting roster. NO ONE WILL BE ADMITTED AFTER 10:05 A.M. Bidders who do not attend the pre-bid meeting will not be permitted to submit a Bid. A Bid submitted by a Bidder who did not attend the mandatory pre-bid meeting will not be eligible for award. Only prequalified Bidders may attend.
- PLEASE NOTE: SPECIFICATIONS WILL BE POSTED TO BONFIRE ON OCTOBER 20, 2026.

Similar Contracts

Same NAICS industry code

NAICS: 238160
New
Inland Empire Job Corps-Request for Quote Roof Design & Build
Solicitation # inland-empire-job-corps-request-quote-roof-design-build
Management & Training Corporation is seeking quotes for a fixed-price design-build subcontract to construct an over-build enclosure for the lower roof of Building G at the Inland Empire Job Corps Center in San Bernardino, California. The project involves designing and installing a roof covering approximately 800 gross square feet, featuring a 3% sloped roof with a single ply, EPDM 60 mil roofing system over wood or metal decking. The scope includes structural framing that extends existing bearing walls or utilizes a new post-beam system, the installation of three LED strip light fixtures with one emergency backup, and strict adherence to OSHA safety standards and the Architectural Barriers Act Accessibility Standard of 2007. The total period of performance is 240 days, with a requirement to complete the work within 100 consecutive business days following the Notice to Proceed. Bids are due by November 2, 2026, and will be evaluated based on overall best value. This is a small business set-aside opportunity open to various SBA certifications. For bids equal to or greater than $25,000, a bid bond of 20% of the base bid is required, and the awarded contractor must provide performance and payment bonds from a surety with at least an A- rating. Bidders must conduct a physical site visit and sign an attendance roster to be eligible. The project is subject to Construction Wage Rate Requirements, necessitating compliance with California prevailing wages and the submission of weekly certified payroll reports. Additionally, all inspections and testing must be conducted by an independent, third-party agency registered in California. Required insurance minimums include 1 million dollars per occurrence for general liability, 1 million dollars for auto, and 500,000 dollars for workers compensation.
Inland Empire Job Corps

POSTED

about 6 hours ago

DEADLINE

in 5 days
View Details
NAICS: 238160
New
SLED
REPLACE THE GUTTERS AT THE DEFUNIAK COURTHOUSE
Solicitation # 05-27
Walton County is soliciting competitive quotations for the complete removal and replacement of the internal and concealed gutter system at the three-story DeFuniak Springs Courthouse in Florida. The selected contractor must provide all labor, supervision, equipment, and materials necessary to install a durable, watertight drainage system, including the removal of deteriorated flashing, sealants, and liners. Key requirements include performing a preconstruction assessment to verify dimensions, conducting a controlled water test upon completion, and ensuring all restoration materials are compatible with the existing building. The project requires a final walkthrough with the owner and a comprehensive site cleanup to return the area to its preconstruction condition. Qualified respondents must hold a valid Florida contractor license, such as a Certified General, Building, Roofing, or Sheet Metal Contractor license. Submissions must include a total lump-sum base quotation with an itemized breakdown, a proposed project schedule detailing mobilization and duration, warranty information for both workmanship and materials, and two professional references. The deadline for responses is November 19, 2026, at 12:00 pm, with all submissions and clarifications handled through the OpenGov Procurement portal. Award consideration will be based on price and the ability to meet technical and administrative requirements.
Facility Maintenance

POSTED

about 17 hours ago

DEADLINE

in 22 days
View Details

More opportunities from Virginia → Fairfax County Public Schools

Same awarding agency

NAICS: 524114
SLED
Group Medicare Advantage Plan
Solicitation # 2000004432
Fairfax County Public Schools is soliciting sealed proposals under solicitation 2000004432 to establish a contract for a fully insured Medicare Advantage plan providing medical and vision benefits for eligible retirees and their dependents. Effective January 1, 2028, the plan will operate alongside a self-insured Employer Group Waiver Plan with a Wrap prescription drug program administered by SilverScript. The contract will be awarded to the offeror providing the best proposal based on a combined evaluation by a Selection Advisory Committee and an IT Committee. Qualified offerors must manage at least 100,000 covered lives within their Medicare Advantage book of business and comply with all Centers for Medicare and Medicaid Services requirements. The pricing structure is based on a per-member-per-month basis, requiring guaranteed premium quotes for 2028 through 2030, as well as allowances for implementation, renewal support, audits, and communications. A gain-sharing agreement based on a defined Loss Ratio will also be implemented. Key administrative requirements include the assignment of a dedicated account executive, adherence to strict cybersecurity and data privacy standards, and compliance with accessibility mandates such as the ADA and Section 508. Proposals must be submitted electronically via the Euna Procurement portal by November 6, 2026, and must include a separate cost proposal and a signed non-disclosure agreement to access specific attachments.
Direct Health and Medical Insurance Carriers

POSTED

16 days ago

DEADLINE

in 9 days
View Details
NAICS: 238210
SLED
Electrical Installation Services for Portable Classroom Trailers
Solicitation # RFP #27-002
Fairfax County Public Schools is soliciting proposals under RFP 27-002 for qualified electrical contractors to provide on-demand electrical and low-voltage installation services for portable classroom trailers in Virginia. The scope of work includes the installation of new electrical services, temporary wooden utility poles, power sheds, ground grids, and meter cabinets, as well as comprehensive low-voltage cabling for data, telephone, security, and CATV. All work must comply with the National Electrical Code and project-specific specifications, with the contractor responsible for obtaining all necessary trade permits and scheduling inspections through the Fairfax County Department of Public Works and Environmental Services. Proposals must be submitted electronically via the Bonfire Interactive portal by 2:00 PM on November 3, 2026. Award decisions will be based on a competitive negotiation process evaluating the offeror's capability, size, organizational experience, bonding capacity, and location. Selected contractors must provide performance and payment bonds equal to 100 percent of the contract sum and maintain comprehensive insurance naming the school system as an additional insured. Additionally, offerors must certify authorization to do business in Virginia and provide a child safety certification confirming no history of felonies or child abuse for employees having direct contact with students.
Electrical Contractors and Other Wiring Installation Contractors

POSTED

26 days ago

DEADLINE

in 6 days
View Details

Earlier notices in this NAICS code

Posted before this notice, open and closed

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Miguel
Hillary
Keith Deutsch
Christine

Join 750+ contractors already using CLEATUS