Skip to main contentPsst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveFree Webinar — Wednesday, September 16 at 2:00 PM EDT

Register Free →

Award Notice

Awarded
W912HN26BA009Federal

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

The Brunswick Harbor Modifications Project in Brunswick, Georgia, is a U.S. Army Corps of Engineers contract awarded under solicitation number W912HN26BA009, issued by the Department of Defense’s W074 Endist Savannah office. The contract is classified under NAICS code 237990 for other heavy and civil engineering construction, and while no estimated contract value is provided, the project requires specialized civil engineering work involving dredging, material placement, and landform creation to modify harbor infrastructure. The contractor must demonstrate the ability to access the placement site via river systems without impacting adjacent wetlands, maintain strict environmental controls to prevent pumped material from entering surrounding marshes and tidal creeks during all tide cycles, and employ on-site personnel with expertise to monitor and mitigate sediment-related hydraulic and engineering issues. The award notice indicates that the contract includes the mandatory FAR clause 52.240-93 for safeguarding covered contractor information systems, which supersedes the older 52.204-21 clause, and explicitly removes the 52.249-13 Excusable Delays clause, altering the risk allocation for scheduling issues. The solicitation required submission of a comprehensive capability statement addressing technical, environmental, and operational requirements, alongside verification of SBA certifications such as HUBZone, 8(a), and Small Disadvantaged Business status via SAM.gov, along with bonding capability documentation for both single and aggregated bonds. The contractor must also provide their UEI and CAGE codes, company details, and designate primary and secondary points of contact. The place of performance is listed as Brunswick, Georgia, though exact site coordinates are not detailed in the provided documentation. The primary point of contact for contract matters is Rohan Bryan, Contract Specialist, with Chad Arnett, Contracting Officer, serving as the secondary contact. While key sections of the contract—such as pricing, delivery schedules, inspection criteria, and detailed technical specifications—are not included in the source materials, the procurement emphasizes environmental stewardship, technical precision, and regulatory compliance over traditional cost-based evaluation.

General Info

USACE seeks bids for dredging, expanding Brunswick Harbor bends, fixed-price $10-$25M, environmental controls required.

Agency

Department Of Defense → W074 Endist SavannahView Agency

Contract Value

$19,138,783

NAICS

237990 - Other Heavy and Civil Engineering ConstructionView NAICS

Place of Performance

Brunswick Harbor, GA

Set-Aside

NONE

Awardee

MARINEX CONSTRUCTION INCView Profile

Award Issued Date

Documents

(2)

POC Contact Information for NAIC 237990 Construction Services

PDF2 pagesother

W912HN26BA009 Abstract of Bids – FY26 Brunswick Inner Harbor Modifications

PDF1 pageother

AI Contract Breakdown

Uniform Contract Format

Sign up to view the full breakdown with detailed analysis of each section.

Timeline

2 updates
PhaseAwarded
Posted

Sources Sought

Type Changed

Sources Sought → Presolicitation

Type Changed

Presolicitation → Solicitation

Amendment 1

Contract was updated

Amendment 2

Contract was updated

Awarded

Contract was awarded

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more
AgencyDepartment Of Defense → W074 Endist Savannah
Contacts1 person available
OfficeSAVANNAH, GA, 31401-3604, USA
Organization / Agency
Department Of Defense → W074 Endist Savannah
View Agency Profile
Office AddressSAVANNAH, GA, 31401-3604, USA

Full Description

Show more
Brunswick Harbor Modifications Project, Brunswick.

Similar Contracts

Same NAICS industry code

NAICS: 237990
New
Haleiwa Small Boat Harbor Maintenance Dredging and Revetted Mole Repair
Solicitation # W9128A26BA002
Solicitation W9128A26BA002 is a firm-fixed-price contract issued by the U.S. Army Corps of Engineers Honolulu District for maintenance dredging and revetted mole repair at the Haleiwa Small Boat Harbor in Oahu, Hawaii. The project scope includes mobilization and demobilization, the dredging and ocean disposal of approximately 4,260 cubic yards of material to an approved offshore site south of Oahu, and comprehensive revetment repairs involving clearing, grubbing, stone rework, and vegetation removal. The estimated contract value ranges between 1,000,000 and 5,000,000 dollars, with a performance period of 200 calendar days from the receipt of the Notice to Proceed. This opportunity is set aside for HUBZone Small Businesses, who are eligible for a 10 percent price evaluation preference. Bidders must submit sealed physical bids by September 30, 2026, as electronic submissions are not permitted. Key requirements include the provision of performance and payment bonds, adherence to the Davis-Bacon Act, and the appointment of key personnel, including a Project Manager, Project Superintendent, Quality Control System Manager, and Site Safety and Health Officer. The contract stipulates liquidated damages of 2,297 dollars per calendar day of delay and requires a third-party qualified surveyor for pre- and post-dredge multi-beam hydrographic surveys to verify final quantities.
Healy Tibbitts Builders, Inc.

POSTED

about 3 hours ago

DEADLINE

in 18 days
View Details
NAICS: 237990
New
Federal
Station Umpqua River Floating Dock Repair
Solicitation # 70Z03326QSEAT0015
The Department of Homeland Security, through the U.S. Coast Guard Base Seattle, is soliciting bids for a firm-fixed-price contract to repair the floating pier at Station Umpqua River in Winchester Bay, Oregon. The project involves providing all personnel, equipment, and tools to remove deteriorated wooden whalers and hardware and install three layers of 4 by 12 inch wooden whalers, through rods, roller hoops, and an egress ladder, while reinstalling ten existing cleats. The estimated period of performance is from September 21, 2026, to October 22, 2026, with a required completion date of October 14, 2026. This is a total small business set-aside under NAICS code 237990. A mandatory site visit is scheduled for August 27, 2026, at 10:00 AM, and interested offerors must submit their attendee lists by August 26, 2026. Proposals are due by September 14, 2026, at 3:00 PM PST and must be submitted via email to the contracting officer. Submissions are limited to six pages and must include a completed SF 1442, a detailed price breakdown covering mobilization, materials, and labor, and a technical proposal detailing the approach and project schedule. Evaluation will be based on technical capability, past performance, and price, with technical capability being the most significant factor. Awardees must be registered in the System for Award Management and comply with Davis-Bacon Act wage determinations for Douglas County, Oregon.
Base SEATTLE(00033)

POSTED

about 20 hours ago

DEADLINE

in 5 days
View Details
NAICS: 237990
New
Federal
KB Dock Piers Ladder Replacement
Solicitation # N0025326Q0009
The Naval Undersea Warfare Center Division Keyport is soliciting a firm-fixed-price construction contract, designated as RFQ N0025326Q0009, for the replacement of emergency pier ladders at KB Dock in Bangor, Washington, and the Keyport Main Pier in Keyport, Washington. The scope of work involves removing thirteen 20-foot ladder extensions and two upper ladder sections, and installing twelve new 20-foot aluminum ladders and two new upper ladder sections. All new hardware must be constructed from 6061 marine-grade aluminum with nonslip rungs. The estimated magnitude of the requirement is between $100,000 and $250,000, and the project is 100% set aside for small business concerns under NAICS code 237990. Award will be based on the Lowest Price Technically Acceptable (LPTA) method, evaluating technical capability, past performance, and safety records. Offerors must demonstrate at least three years of experience in commercial or industrial applications and provide a stable safety rating based on DART and TCR rates over the last five years. Key requirements include the provision of a Site Safety and Health Officer with a 30-hour OSHA construction safety certification and adherence to EM-385-1-1 safety standards, including the presence of a rescue boat during working hours. Bid bonds are required for proposals of $150,000 or more, and performance and payment bonds must be submitted within ten days of award. All proposals must be submitted digitally, and the contractor must maintain active registration in the System for Award Management.
Naval Undersea Warfare Center

POSTED

about 20 hours ago

DEADLINE

in 10 days
View Details

More opportunities from Department Of Defense → W074 Endist Savannah

Same awarding agency

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Miguel
Hillary
Keith Deutsch
Christine

Join 650+ contractors already using CLEATUS