Denton County — CSJ 6492-44-001 — July 2026 Letting — Local-Let Maintenance

The contract pertains to a Local-Let Maintenance project in Denton County, Texas, solicited by the Texas Department of Transportation under solicitation number 6492-44-001, with a letting date of July 1, 2026. The scope centers on temporary traffic control measures including installation of barricades, signage, truck-mounted attenuators, and traffic delineation devices along FM0156 and IH35E, with work restricted to weekday hours between 9:00 AM and 3:30 PM and lane closures limited to two miles. The project also includes tree and brush removal, with specific pricing for removal by tree diameter, and requires hazardous material handling compliant with OSHA standards, including proper labeling, Safety Data Sheets, and restrictions on lead and asbestos content. Materials must conform to TxDOT specifications such as DMS-8300 for retroreflective sheeting, DMS-8240 for pavement markings, and DMS-8242 for temporary flexible markers, which must pass field testing for retention under traffic. Performance is subject to monitoring through Project Recovery Plans and Corrective Action Plans, with penalties outlined in a Schedule of Liquidated Damages for noncompliance or delays. The contract requires strict adherence to compliance certifications, including mandatory E-Verify participation for all workforce tiers, submission of a Disadvantaged Business Enterprise commitment, and adherence to federal and state nondiscrimination laws. Contractors must certify they are not affiliated with foreign adversaries under Section 889 of the NDAA, comply with prohibitions against boycotting Israel or energy companies, and report changes in interested parties if the contract value reaches $1 million. Security protocols mandate safeguarding TxDOT data, reporting cybersecurity incidents via official portals, and flowing down security obligations to subcontractors. All proposals must use the Department’s official bid form, with no alterations allowed, and must be submitted in person at the designated letting event after completing a pre-submission questionnaire ten days in advance. Work must commence within seven calendar days of the work order, and performance is governed by state transportation codes and TxDOT special provisions rather than standardized FAR clauses. The estimated contract value is approximately $946,613 based on listed line items, excluding a negative unit price for flex base that may denote a rebate. Despite the absence of explicit award methodology or evaluation factors, the structure suggests a Lowest Price Technically Acceptable approach. No formal contracting officer or point of contact details