UNR - Replace Roof at Artemisia Building

This contract involves the complete removal and replacement of the existing asphalt shingle roof at the Artemisia Building, University of Nevada, Reno (UNR), scheduled to begin on August 10, 2026, with completion required by October 2, 2026. It is a prevailing wage project with an estimated value between $200,000 and $300,000, and includes a liquidated damages clause imposing $500 per day for delays beyond the completion date. The scope of work requires strict adherence to prevailing wage laws and compliance with the TEMPLATE-Owner-Contractor Construction Agreement, which outlines insurance requirements such as Commercial General Liability, Business Automobile Liability, Workers’ Compensation, Pollution Liability, Contractors Equipment coverage, Installation Floater, Rigger's Liability, and Builder’s Risk insurance. The contract mandates electronic submissions exclusively through the Nevada Government Marketplace (NGEM) platform, disallowing any physical document submissions and encouraging early and saved drafts to avoid last-minute technical issues. Inspection and acceptance of the work will occur at the UNR Artemisia Building under the oversight of university project managers, with the contractor responsible for performing the work to institutional standards and prevailing construction practices. While no detailed pricing breakdown, FAR clauses, or formal evaluation criteria are provided, the solicitation is identified as an Invitation to Bid (ITB 9105 Addendum 1) with a submission deadline of June 25, 2026. No contract options, security clearances, special personnel requirements, or organizational conflict of interest provisions are specified. The contract administration is managed internally by UNR personnel, though no contracting officer contact information is listed. Overall, this procurement focuses on timely, skilled roofing replacement under prevailing wage regulations with mandatory insurance coverage, conducted via a fully electronic bidding process.