Skip to main contentPsst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveFree Webinar — Wednesday, October 28 at 2:00 PM ET

Register Free →

This Sources Sought opportunity from Department Of Defense was posted on May 22, 2019. The submission period has ended. Browse the details below for market research, or find similar active opportunities.

XUMU 09-1700B, Replace Exterior Windows and Doors

Closed
XUMU09_1700BFederal

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

Active Opportunities Like This One

NAICS: 236220
New
Federal
PN 110205 - SOS Hangar Renovation - Progressive-Design-Build OT
Solicitation # W912PM279A001
The U.S. Army Corps of Engineers is issuing a draft program solicitation for the renovation of Hangar 750 at Pope Army Airfield, Fort Bragg, North Carolina. This project supports an Air Force Special Operations Command squadron mission and involves the comprehensive architectural and MEP build-out of ground floor aircraft maintenance bays, the integration of exterior hangar doors, and the construction of second-floor administrative and high-security operational spaces. The scope includes the installation of Level 2 wet-pipe fire suppression, intrusion detection systems, electronic access control, and full furniture, fixtures, and equipment packages. This procurement is conducted as an Other Transaction Agreement under 10 USC 2808a, meaning it is not subject to the Federal Acquisition Regulation. The project follows a Progressive Design-Build approach divided into two stages: Phase 1 focuses on design and pre-construction services, while Phase 2 covers final design and construction via a Fixed Price model based on a negotiated Guaranteed Maximum Price. The government has established an affordability cap of 35 million dollars as a material requirement, and the selected firm must be capable of providing performance and payment bonds of at least 35 million dollars. Selection is based on a qualifications-based methodology involving a two-step process: an initial evaluation of White Papers followed by Pitch Presentations for a target of three highly qualified teams. All team members must be registered in the System for Award Management with a valid Unique Entity Identifier. Additionally, the successful Design-Builder must comply with Cybersecurity Maturity Model Certification (CMMC) requirements as codified in 32 CFR Part 170, including a positive self-assessment and signed attestation of security controls. Submissions must be made through the PIEE Solicitation Module.
W074 Endist Wilmington

POSTED

about 5 hours ago

DEADLINE

in 17 days
NAICS: 236220
New
Federal
Z1DA-- 460-26-004 | Wilmington VAMC Roof Replacement | NCO 4 Construction East (VA-26-00029152)
Solicitation # 36C24426B0015
Solicitation 36C24426B0015 is a firm-fixed price construction contract issued by the Department of Veterans Affairs Network Contracting Office 4 for the removal and replacement of Roof 3D, the Physical Therapy Roof, Roof 10, and Roof 11 at the Wilmington VA Healthcare System in Delaware. The project has an estimated magnitude between $250,000 and $500,000 and is set aside 100% for Service-Disabled Veteran-Owned Small Businesses (SDVOSB). The scope of work includes demolition of existing roofing and insulation, installation of 60 Mil Elevate RubberGard EPDM LS-FR white low-slope fire retardant roofing material or equivalent, and the repair of roof drains. The completed installation must meet high wind zone design requirements and include a minimum 20-year warranty against leaks. Award will be granted to the responsive and responsible bidder offering the lowest price. Eligible bidders must be registered in SAM, VETCERT, and the VETS-4212 database. The contractor is required to provide performance and payment bonds and adhere to Davis-Bacon Act Wage Determination DE20260008. Strict safety standards are mandated, including the presence of an OSHA-certified competent person on-site and 10-hour OSHA certification for all employees. Performance must begin within 10 calendar days of award and be completed within 30 calendar days, with work performed Monday through Friday from 7:00 AM to 5:00 PM. Following multiple amendments, the final bid opening was rescheduled for October 21, 2026.
244-NETWORK Contract Office 4 (36C244)

POSTED

about 5 hours ago

DEADLINE

in 15 days
NAICS: 236220
New
Federal
Source Sought 36C25627Q0020_564-610 NIPMHB Nurses Call, Boilers, and Rigid Vinyl Sheet
Solicitation # 36C25627Q0020
The Department of Veterans Affairs, through Network Contract Office 16, is conducting market research via a Request for Information to identify qualified Service-Disabled Veteran-Owned Small Businesses (SDVOSB) and Veteran-Owned Small Businesses (VOSB) for a construction project at the Veterans Health Care System of the Ozarks in Fayetteville, Arkansas. The project, identified as Project 564-610, involves repairs and installations at the New Inpatient Mental Health Building (Building 49). The scope of work includes the installation of two electric backup boilers with associated piping, pumps, and electrical work, the application of Inpro Palladium Rigid Vinyl Sheet, and the installation of 3/8 inch interior tempered safety glazing for nurse station partitions. The government anticipates awarding a single, firm-fixed-price contract with an estimated magnitude between 250,000 and 500,000 dollars. The period of performance is 210 calendar days from the Notice to Proceed. All work must be performed without disrupting medical center operations and must adhere to the latest NEC, NFPA, and OSHA standards, including the development of an Infection Control Risk Assessment. Personnel are required to have a negative TB test within 90 days of starting work and a minimum OSHA 10 certification. Interested firms under NAICS code 236220 must provide a capability statement, proof of ability to obtain performance and payment bonds up to 500,000 dollars, and details of three relevant recent projects. Responses must be submitted to the Contracting Officer by November 3, 2026.
256-NETWORK Contract Office 16 (36C256)

POSTED

about 5 hours ago

DEADLINE

in 14 days
NAICS: 236220
New
Construction of the Recharge Master Plan Update Basin Improvements Project Montclair Basin Improvements
Solicitation # construction-recharge-master-plan-update-basin-improvements-project-montclair-basin-improvements-2
The Construction of the Recharge Master Plan Update Basin Improvements Project Montclair Basin Improvements is a solicitation issued by RT Contractor Corp for a project under the Inland Empire Utilities Agency in California. This opportunity is specifically set aside for Disadvantaged Business Enterprises (DBE) under the Department of Transportation, with a response deadline of November 4, 2026. The project falls under NAICS code 236220 and focuses on basin improvements within the Riverside or Los Angeles project areas. A critical component of this solicitation is strict adherence to six Good Faith Effort (GFE) requirements designed to ensure DBE participation and secure project financing. Bidders must provide proof of GFE #2, which requires posting solicitations in an online publication for 30 consecutive calendar days and in a print newspaper for one day, as well as proof of GFE #5, involving the utilization of the Small Business Administration (SBA) and the Minority Business Development Agency (MBDA). Failure to submit documentation for these two specific efforts within the bid package will result in the proposal being deemed non-responsive. Additionally, outreach documentation for GFE #1 may be submitted up to three business days after the bid closing date.
RT CONTRACTOR CORP

POSTED

about 11 hours ago

DEADLINE

in 14 days
NAICS: 236220
New
P084 NEXT GENERATION TORPEDO INTEGRATION LAB & P1016 Consolidated RDT&E Systems Facility – Newport, RI
Solicitation # p084-next-generation-torpedo-integration-lab-p1016-consolidated-rdte-systems-facility-newport-ri
J&J Contractors, Inc. is soliciting bids for the construction of the Next Generation Torpedo Integration Lab and the P1016 Consolidated RDT&E Systems Facility in Newport, Rhode Island. The project involves the development of a 12,920 square foot multi-story steel frame laboratory and office facility, as well as an optional 17,978 square foot laboratory facility. Construction features include shallow foundations, metal standing seam roofs, and exterior walls composed of masonry and metal panels. The scope of work encompasses comprehensive site preparations, including landscaping, parking, exterior lighting, and the installation of underground stormwater retention and utility systems. Additionally, the project requires the demolition of Building 1272T, a 548 square meter engineering facility. Pricing is requested across a wide array of trades, including demolition, abatement, concrete, masonry, structural and miscellaneous metals, millwork, roofing, drywall, flooring, painting, elevator installation, fire protection, plumbing, mechanical, electrical, sitework, and crane services. This is a small business set-aside solicitation subject to Davis Bacon Wage Rates and is exempt from sales tax. Interested parties must contact the primary point of contact to receive bid invitations and documents via Building Connected. The response deadline for this solicitation is November 30, 2026.
J&J CONTRACTORS, INC.

POSTED

about 11 hours ago

DEADLINE

in about 1 month

General Info

Agency

Department Of Defense → FA4610 30 Cons Pk

NAICS

236220 - Commercial and Institutional Building Construction

Place of Performance

Vandenberg AFB, CA, 93437, USA

Set-Aside

NONE

Documents

1

09-1700B_SOW_Draft.pdf

PDF

AI Contract Breakdown

Uniform Contract Format

Contract not broken down yet

CLEATUS splits the solicitation into Uniform Contract Format (UCF) sections: scope, pricing, deliverables, and evaluation criteria.

Timeline

1 update
PhaseClosed
Posted

Sources Sought

Notice updated

Notice details unchanged. Attachments may have changed.

Response Deadline

Deadline has passed

Submission Closed

Find active opportunities like this

Start your free trial to discover similar active contracts, track opportunities, and build proposals with AI assistance.

Organization & Contact Information

Show more
AgencyDepartment Of Defense → FA4610 30 Cons Pk
Contacts2 people available
OfficeVANDENBERG SFB, CA, 93437-5212, USA
Organization / Agency
Department Of Defense → FA4610 30 Cons Pk
Office AddressVANDENBERG SFB, CA, 93437-5212, USA
Contacts
Meghann E. ApplebayContract Specialist
Albert Thompson JrContracting Officer

Full Description

Show more
The 30th Contracting Squadron is publicizing this SOURCES SOUGHT NOTICE to gather industry information with respect to the removal, disposal and replacement of exterior doors and windows at (Building Location to be Identified at Solicitation), Vandenberg AFB, CA. No solicitation is being issued at this time. This is not a Request for Proposal (RFP), Request for Quotation (RFQ) nor Invitation for Bid (IFB), and shall not be construed as a commitment by the Government to issue a solicitation or ultimately award a contract. Responses will not be considered as proposals, nor will any award be made as a result. The Air Force will not be responsible for any costs incurred by interested parties in responding to this notice. Any future solicitation, including specifications and/or drawings, will be made available only on the Federal Business Opportunities website (https://www.fbo.gov/). Interested Parties are solely responsible for monitoring the aforementioned website for the release of a solicitation package and/or any updates and/or amendments. The government is seeking to identify qualified, experienced, and interested small businesses capable of performing the type of work as described herein in order to help determine which small business set-aside to use. The following North American Industry Classification System (NAICS) code applies to this request of information: 236220 Commercial and Institutional Building Construction and the size standard is $36.5 Million. The purpose of the project is to provide the government with a complete engineering design, construction, and warranty for the removal, disposal and replacement of exterior doors and windows at (Building Location to be Identified at Solicitation), Vandenberg AFB, CA. See the attached Draft Statement of Work for more details. The estimated magnitude of the project is between $250,000 and $500,000. The proposed contract would be a firm-fixed-priced contract. All interested parties are invited to respond and must be currently registered in the System for Award Management (SAM) (http://www.sam.gov/). The information requested will be used within the Air Force to facilitate decision making and will not be disclosed outside the agency. If your firm has interest in proposing on this requirement, please prepare and email your company name, address, point of contact (POC), telephone number, CAGE Code and DUNS Number, applicable NAICS codes, and Business size (i.e. Large Business, Small Business, SBA Certified 8(a) Program Participant, SBA Certified HUB Zone Firm, Service Disabled Veteran Owned Business, Woman Owned Business) to the Contracting Officer, Mr. Albert Thompson, albert.thompson.2@us.af.mil and Contract Specialist, Ms. Meghann Applebay, meghann.applebay@us.af.mil, no later than 4:30 PM PDT, 29 May 2019.

Find Active Opportunities Like This

Get AI-powered intelligence on the opportunities still open

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Miguel
Hillary
Keith Deutsch
Christine

Join 750+ contractors already using CLEATUS