26-33-1

Solicitation 26-33-1 is issued by the St. Tammany Parish Government for the Wildwood Farms Subdivision Drainage project in Pearl River, Louisiana. The contractor is required to provide all labor, equipment, and materials to improve drainage by removing and replacing driveway pipes, catch basins, and drain pipes along Max Mercer Rd (R06I026) and Cecil Fleming Rd (R06I009). Specific work items include full depth asphalt patching, installation of 18-inch HP storm drain pipes, cleaning and grading of existing ditches, and the placement of 55LB rip rap. The project must be completed within 45 calendar days from the issuance of the Notice to Proceed, with liquidated damages set at 1% per day for delays. The contract will be awarded to the lowest compliant monetary quote. Eligible respondents must hold a Highway, Street, and Bridge Construction classification, and those bidding on work estimated at $50,000 or more must be licensed by the State of Louisiana under Chapter 24 of Title 37. Submission requirements include a detailed pricing sheet, affidavits, corporate resolutions, and insurance certificates, with a deadline of November 12, 2026. Payment is structured through monthly certificates for 90% of work performed and materials stored, with the final 10% released 45 days after filing acceptance and securing a Clear Liens and Privilege Certificate. Contractors are also required to provide a performance and payment bond and adhere to strict safety, traffic control, and civil rights compliance standards.