Psst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveCLEATUS Webinar: AI for Government Contracting — Free Webinar — Wednesday, October 28 at 2:00 PM ET

Register Free →

Search

Top

Back to Contracts

AN 085-175-018/4210 Doe Avenue, Homewood, CA 96141. Transfer of land coverage rights for an addition to an existing single-family home.

Active

State & Local

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

General Info

Agency

California → Tahoe Conservancy

NAICS

236118 - Residential Remodelers

Place of Performance

Rubicon Avenue, CA, 96141

Set-Aside

NONE

Documents

0

No documents available

Documents will appear here when they are available.

AI Contract Breakdown

Uniform Contract Format

Sign up to view the full breakdown with detailed analysis of each section.

Timeline

PostedJan 21

forecast

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more

AgencyCalifornia → Tahoe Conservancy

Contacts2 people available

OfficeN/A

Organization / Agency

California → Tahoe Conservancy

Office AddressN/A

Contacts

Daniel HuertaAssociate Environmental Planner

contact@example.gov

+1 (555) 000-0000

Naraya Hockaday

contact@example.gov

+1 (555) 000-0000

Full Description

Show more

The project consists of the transfer of 564 square feet of potential land coverage rights from Conservancy-owned land to the receiving parcel, identified above, to facilitate a 1,126-square-foot addition to an existing single-family home. The addition includes a new bedroom, bathroom, stairway, attached garage, and deck. The transfer enables the receiving landowner to construct the additions to the home without a net increase in the amount of existing land coverage in the Lake Tahoe Basin

Similar Contracts

Same NAICS industry code

FEMA Elevation Project - 2705 Church Street {4491-22} - REBID #3

Solicitation # 2027-IFB-031

Wicomico County is soliciting bids under solicitation 2027-IFB-031 for a FEMA/MEMA funded structural elevation project located at 2705 Church Street in Quantico, Maryland. The project requires a qualified vendor to elevate a residential structure and its kitchen to at least two feet above the base flood elevation. The scope of work includes the demolition of the existing foundation, construction of a new foundation using concrete piers, columns, and steel beams, and the subsequent lowering of the building onto the new structure. Additional requirements include obtaining necessary plumbing, electrical, and mechanical permits, disconnecting and reconnecting utilities, installing three new exterior stair systems, and ensuring all exterior siding and paint match original conditions per Historic District guidelines. Bids must be submitted electronically via the OpenGov e-Procurement Portal by November 3, 2026, at 2:30 p.m. The contract will be awarded to the lowest responsive and responsible vendor. The project must be completed by May 31, 2027, with a performance duration of 90 days following contract execution, weather permitting. Vendors are required to provide a Certificate of Good Standing from the Maryland Department of Assessments and Taxation and must adhere to strict insurance and bonding requirements, including performance and payment bonds if the contract exceeds 100,000 dollars. Payment for approved work will be issued within 30 days of receiving a proper invoice.

Planning and Zoning

POSTED

about 12 hours ago

DEADLINE

City Of Encinitas CUPCCAA Qualified Contractors' List Renewal

Solicitation # 20261027007

City of Encinitas

POSTED

about 12 hours ago

DEADLINE

RFP 26-24-CW_Re-Advertisement for the Elevation of Flood Prone Homes

Solicitation # RFP-26-24-CW

The City of Port Orange is soliciting proposals under RFP-26-24-CW for turnkey services to elevate up to 11 single-family residential structures to mitigate flood risk. Funded by the FEMA Hazard Mitigation Grant Program, the project requires elevating homes on new open foundations using concrete piers or pilings to achieve a 9-foot clearance above existing ground, ensuring protection against 100-year storm events. The scope of work includes permitting, utility disconnection and reconnection with underground electrical services, and the installation of medically necessary lift platforms for two of the residences. All work must strictly comply with the Florida Building Code, ASCE 24-14, and local floodplain ordinances. Proposals are due by November 13, 2026, with a final performance deadline of March 1, 2028. The City will rank respondents using a 10-point weighted scoring system based on responsiveness, technical capability, past performance, and professional licensure. Awardees must provide performance and payment bonds for 100 percent of the contract price and adhere to extensive federal and state compliance requirements, including E-Verify, anti-collusion, and non-discrimination standards. While the project involves construction, the Davis-Bacon Act does not apply; however, contractors must comply with the Copeland Anti-Kickback Act and the Contract Work Hours and Safety Standards Act for contracts exceeding $100,000.

Community Development

POSTED

about 13 hours ago

DEADLINE

RTOIL Office rehab

Solicitation # N6893627Q0001

The Naval Air Warfare Center is soliciting quotes for the PM36 RTOIL Office Rehab project located at Naval Base Ventura County Point Mugu. This firm-fixed-price contract is a 100 percent small business set-aside with an estimated project magnitude between 250,000 and 500,000 dollars. The scope of work includes the demolition of approximately 2,455 square feet of carpet, 974 square feet of vinyl flooring, and 1,150 linear feet of base board, as well as the removal of all window blinds. Improvements involve installing 53 dimmable LED troffer light fixtures with associated switches, patching and painting 9,000 square feet of walls in light French Grey, painting 20 door frames, installing cushioned back carpet tiles and vinyl plank flooring, and mounting 16 new whiteboards. The performance period is 120 calendar days, with work beginning within 14 days of the Notice to Proceed. The closing date for quotes has been extended to October 30, 2026, at 4 PM PDT. Award will be granted to the responsible offeror determined to be most advantageous based on price, delivery schedule, technical compliance, and Supplier Performance Risk System assessments. Offerors must provide sufficient technical information to demonstrate project understanding to be considered. Key requirements include the submission of a Quality Control Plan managed by a NAVFAC Contractor Quality Management certified manager, adherence to Davis-Bacon prevailing wage rates for Ventura County, and the provision of required payment bonds. Invoicing will be processed via Wide Area WorkFlow with net 30 payment terms.

Naval Air Warfare Center

POSTED

about 16 hours ago

DEADLINE

Carpentry Repair ServicesThis subcontract for Carpentry Repair Services involves performing maintenance and repair work for prime contractors on Texas Parks and Wildlife Department projects located at Goliad State Park. The scope of work focuses on repairing and stabilizing wooden structural elements, including framing, trim, and fascia, to ensure the integrity of the roof and general workshop structure. Qualified providers must hold dual CTCD/CTCM certification to be eligible for the contract. The solicitation was posted on October 26, 2026, with a response deadline of December 8, 2026. The project falls under NAICS code 236118 and requires the delivery of fully repaired and stabilized wooden structural components.

Parks and Wildlife Department

POSTED

DEADLINE

in about 1 month

Housing Rehabilitation Program- 1137 Bel Air Ct, Modesto, CA 95350

Solicitation # HUD-INF-IFB-00132

Solicitation HUD-INF-IFB-00132 is an invitation for bids for residential repairs and rehabilitation at 1137 Bel Air Ct, Modesto, CA 95350. Funded by the U.S. Department of Housing and Urban Development (HUD), the project is administered by the City of Modesto's Community and Economic Development Department. The selected contractor must provide all labor, materials, and supervision to complete the work in accordance with California Building Code standards and the Community Development Division's Housing Rehabilitation Program. Key requirements include holding a valid California Class B General Building Contractor license and maintaining approved insurance coverage for general liability, workers' compensation, and automobile liability through the City's Public Improvement Notification System (PINS). Bids must be submitted electronically via the OpenGov Procurement Portal by November 2, 2026, at 4:00 pm. Proposals must include a Work Write-Up with itemized costs, and the City reserves the right to reject bids that exceed the Housing Rehabilitation Specialist's cost estimate by more than 15%. While the project is not subject to prevailing wage requirements, the City strongly encourages participation from Section 3 businesses. The awarded contractor is required to provide a COVID-19 Health and Safety Plan and an operation and maintenance manual upon completion. Performance is subject to liquidated damages of 65 dollars per day for delays, and final payment is contingent upon a signed Certificate of Completion and necessary termite and lead-based paint clearances.

Community and Economic Development

POSTED

DEADLINE

Housing Rehabilitation Program-1017 Crippen Ave, Modesto, CA 95351

Solicitation # HUD-INF-IFB-00130

The City of Modesto Community and Economic Development Department is soliciting bids for a housing rehabilitation project located at 1017 Crippen Ave, Modesto, CA 95351. Funded through the U.S. Department of Housing and Urban Development, the project emphasizes economic opportunities for low-income individuals via Section 3 requirements. The scope of work involves providing all supervision, labor, materials, and equipment necessary to perform repairs as detailed in the Work Write-Up. Bidders must hold a valid California General Contractor Class B license and maintain compliant insurance coverage, including General Liability, Workers Compensation, and Automobile Liability, approved through the City's Public Improvement Notification System. Bids must be submitted electronically via the OpenGov Procurement Portal by November 2, 2026, at 4:00 pm. To be validated, bids must include a completed Work Write-Up/Submittal sheet with itemized costs and fall within 15 percent of the Housing Rehabilitation Specialist's cost estimate. The project is not subject to prevailing wage requirements, but contractors must comply with strict safety standards, including OSHA Asbestos Standards, lead-based paint compliance under 24 CFR Part 35 Subpart J, and the submission of a COVID-19 Health and Safety Plan. The approximate contract award date is January 2027. Performance is subject to a liquidated damages penalty of 65 dollars per calendar day for delays. Final payment is contingent upon inspection and approval by the homeowner and the City of Modesto, and requires the delivery of an Operation and Maintenance manual for all new installations. Invoices must be signed by the contractor, homeowner, and relevant City specialists, with reimbursement typically processed within 30 days.

Community and Economic Development

POSTED

DEADLINE

Housing Rehabilitation Program- 103 Chabot Ct, Modesto, CA 95354

Solicitation # HUD-INF-IFB-00131

The City of Modesto Community and Economic Development Department is soliciting bids for a housing rehabilitation project located at 103 Chabot Ct, Modesto, CA 95354, under solicitation number HUD-INF-IFB-00131. Funded by the U.S. Department of Housing and Urban Development, the project emphasizes Section 3 requirements to expand economic opportunities for low-income individuals. Bidders must hold a valid California Class B General Building Contractor license and maintain compliant insurance coverage, including General Liability, Workers Compensation, and Automobile Liability, approved through the City's Public Improvement Notification System. All bids must be submitted electronically via the OpenGov Procurement Portal by November 3, 2026. The scope of work requires adherence to the California Building Code, California Green Building Standards Code, and specific lead-safe work practices for homes built before 1978. Awarded contractors must provide a COVID-19 Health and Safety Plan and are subject to a one-year warranty period to remedy any defects. Bids must be within 15 percent of the Housing Rehabilitation Specialist's cost estimate to be considered reasonable. While the project is not subject to prevailing wage requirements, it does include liquidated damages of 65 dollars per day for delays. Payment is processed upon the submission of detailed invoices signed by the contractor, homeowner, and city specialists, with final payment issued upon total completion and the signing of a Certificate of Completion.

Community and Economic Development

POSTED

DEADLINE

General Building Maintenance/Handyman ServicesThis subcontract for General Building Maintenance and Handyman Services involves performing miscellaneous small-scale repairs and general maintenance for prime contractors at Middle Georgia State University residence halls. The scope of work includes replacing door hardware, repairing windows, replacing ceiling tiles, and addressing general wear-and-tear using standard carpentry tools. While the focus is on minor fixes, a General Contractor License is required for larger tasks to ensure facility conditions are properly maintained and repair tickets are completed. The opportunity is categorized under NAICS code 236118 and was posted on October 26, 2026, with a response deadline of November 30, 2026. Interested parties can find further details through the Georgia Department of Administrative Services portal.

Middle Georgia State University

POSTED

DEADLINE

in about 1 month

FRA Remedial Works - North West (Lot 3)This subcontract involves performing general fire risk assessment remedial works for prime contractors on residential projects managed by the London & Quadrant Housing Trust within the North West region. The scope of work focuses on executing general construction and repair tasks to resolve fire safety deficiencies identified in official FRA reports, utilizing standard construction materials while adhering strictly to UK fire safety regulations and construction standards. The project, titled FRA Remedial Works - North West (Lot 3), is categorized under NAICS code 236118. Interested parties must submit their responses by the deadline of November 23, 2026, to ensure the delivery of completed remedial works as specified in the governing safety reports.

London & Quadrant Housing Trust

POSTED

DEADLINE

FRA Remedial Works - North London (Lot 2A)This subcontract agreement involves the execution of general fire risk assessment remedial works for residential projects managed by the London & Quadrant Housing Trust in North London. The selected provider will work under prime contractors to address fire safety deficiencies identified in official FRA reports, utilizing standard construction materials to perform necessary repairs and general construction tasks. All activities must strictly adhere to UK fire safety regulations and established construction standards to ensure the safety and compliance of the residential properties. The project, identified as FRA Remedial Works - North London (Lot 2A), is categorized under NAICS code 236118. Interested parties must submit their responses by the deadline of November 23, 2026. The primary objective of the contract is the successful delivery of all remedial works as specified in the provided fire risk assessment documentation to mitigate identified hazards across the trust's housing portfolio.

London & Quadrant Housing Trust

POSTED

DEADLINE

FRA Remedial Works - South London (Lot 1A)This subcontract involves performing general fire risk assessment remedial works for prime contractors on residential projects managed by the London & Quadrant Housing Trust in South London. The scope of work focuses on executing general construction and repair tasks to resolve fire safety deficiencies identified in official FRA reports, utilizing standard construction materials while ensuring full compliance with UK fire safety regulations and construction standards. The project, titled FRA Remedial Works - South London (Lot 1A), was posted on October 26, 2026, with a response deadline of November 23, 2026. The primary objective is the delivery of completed remedial works as specified in the assessment reports to enhance the safety of the residential properties within the designated region.

London & Quadrant Housing Trust

POSTED

DEADLINE

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Join 750+ contractors already using CLEATUS