Psst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveCLEATUS Webinar: AI for Government Contracting — Free Webinar — Wednesday, October 28 at 2:00 PM ET

Register Free →

Search

Top

Back to Contracts

City Of Encinitas CUPCCAA Qualified Contractors' List Renewal

Active

20261027007State & Local

Response Deadline10/01/2027, 12:00:00 AM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

General Info

Agency

California → City of Encinitas

NAICS

236118 - Residential Remodelers

Place of Performance

Encinitas, CA, 92024, USA

Set-Aside

NONE

Documents

4

City of Encinitas CUPCCAA Renewal Notice 2026-2027

presolicitation

Low

City of Encinitas CUPCCAA Renewal Notice 2026-2027

presolicitation

Low

Proof of Publication_Document view.pdf

Proof of Publication_Overview.pdf

AI Contract Breakdown

Uniform Contract Format

Contract not broken down yet

CLEATUS splits the solicitation into Uniform Contract Format (UCF) sections: scope, pricing, deliverables, and evaluation criteria.

Timeline

PhaseSolicitation

PostedOct 27

Solicitation

Response DeadlineOct 1

Submission deadline

Response Deadline

10/01/2027, 12:00:00 AM UTCin 11 months

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more

AgencyCalifornia → City of Encinitas

Contacts1 person available

OfficeN/A

Organization / AgencyCalifornia → City of Encinitas

Office AddressN/A

Contacts

contact@example.gov

Full Description

Show more

Bid #BA-20261022034: This notice is for the annual renewal of the City of Encinitas's qualified contractors' list under the California Uniform Public Construction Cost Accounting Act (CUPCCAA) for the period of October 1, 2026, through September 30, 2027. All licensed contractors are invited to submit their firm's name for inclusion on this list. The City utilizes the PlanetBids online bid management system for vendor registration and prequalification. Contractors on this list will receive notices inviting informal bids for projects relevant to their classification. New and returning contractors must complete the Prequalification section of their vendor profile and are responsible for keeping their classification and license information current. Submissions for inclusion on the list are accepted at any time throughout the year.

Similar Contracts

Same NAICS industry code

FEMA Elevation Project - 2705 Church Street {4491-22} - REBID #3

Solicitation # 2027-IFB-031

Wicomico County is soliciting bids under solicitation 2027-IFB-031 for a FEMA/MEMA funded structural elevation project located at 2705 Church Street in Quantico, Maryland. The project requires a qualified vendor to elevate a residential structure and its kitchen to at least two feet above the base flood elevation. The scope of work includes the demolition of the existing foundation, construction of a new foundation using concrete piers, columns, and steel beams, and the subsequent lowering of the building onto the new structure. Additional requirements include obtaining necessary plumbing, electrical, and mechanical permits, disconnecting and reconnecting utilities, installing three new exterior stair systems, and ensuring all exterior siding and paint match original conditions per Historic District guidelines. Bids must be submitted electronically via the OpenGov e-Procurement Portal by November 3, 2026, at 2:30 p.m. The contract will be awarded to the lowest responsive and responsible vendor. The project must be completed by May 31, 2027, with a performance duration of 90 days following contract execution, weather permitting. Vendors are required to provide a Certificate of Good Standing from the Maryland Department of Assessments and Taxation and must adhere to strict insurance and bonding requirements, including performance and payment bonds if the contract exceeds 100,000 dollars. Payment for approved work will be issued within 30 days of receiving a proper invoice.

Planning and Zoning

POSTED

about 6 hours ago

DEADLINE

RFP 26-24-CW_Re-Advertisement for the Elevation of Flood Prone Homes

Solicitation # RFP-26-24-CW

The City of Port Orange is soliciting proposals under RFP-26-24-CW for turnkey services to elevate up to 11 single-family residential structures to mitigate flood risk. Funded by the FEMA Hazard Mitigation Grant Program, the project requires elevating homes on new open foundations using concrete piers or pilings to achieve a 9-foot clearance above existing ground, ensuring protection against 100-year storm events. The scope of work includes permitting, utility disconnection and reconnection with underground electrical services, and the installation of medically necessary lift platforms for two of the residences. All work must strictly comply with the Florida Building Code, ASCE 24-14, and local floodplain ordinances. Proposals are due by November 13, 2026, with a final performance deadline of March 1, 2028. The City will rank respondents using a 10-point weighted scoring system based on responsiveness, technical capability, past performance, and professional licensure. Awardees must provide performance and payment bonds for 100 percent of the contract price and adhere to extensive federal and state compliance requirements, including E-Verify, anti-collusion, and non-discrimination standards. While the project involves construction, the Davis-Bacon Act does not apply; however, contractors must comply with the Copeland Anti-Kickback Act and the Contract Work Hours and Safety Standards Act for contracts exceeding $100,000.

Community Development

POSTED

about 7 hours ago

DEADLINE

RTOIL Office rehab

Solicitation # N6893627Q0001

The Naval Air Warfare Center Weapons Division is soliciting quotes for the PM36 RTOIL Office Rehabilitation project located at Naval Base Ventura County, Point Mugu, California. This is a 100% small business set-aside under NAICS code 236118, utilizing a firm-fixed-price contract with an estimated magnitude between $250,000 and $500,000. The scope of work involves rehabilitating an office facility, including wall repair, painting, carpeting with specific Mohawk-Elite-Azure-Edge-Blue-Commercial flooring, lighting installation, and the installation of 16 new white boards. Performance must begin within 14 calendar days of award and be completed within 120 calendar days, with a scheduled delivery period from October 29, 2026, to February 26, 2027. Award will be granted to the responsible offeror determined to be most advantageous based on price, delivery schedule, technical compliance, and Supplier Performance Risk System assessments. Offerors must provide sufficient technical information to demonstrate project understanding to be considered. The contract requires adherence to the Davis-Bacon Act for prevailing wages, the presence of an on-site Site Safety and Health Officer, and the submission of a comprehensive Quality Control Plan. Invoicing will be processed electronically through Wide Area Workflow with net 30 payment terms. All quotes must be submitted by October 22, 2026, at 3:00 PM PST, and offerors must maintain active registration in the System for Award Management.

Naval Air Warfare Center

POSTED

about 10 hours ago

DEADLINE

Carpentry Repair ServicesThis subcontract for Carpentry Repair Services involves performing maintenance and repair work for prime contractors on Texas Parks and Wildlife Department projects located at Goliad State Park. The scope of work focuses on repairing and stabilizing wooden structural elements, including framing, trim, and fascia, to ensure the integrity of the roof and general workshop structure. Qualified providers must hold dual CTCD/CTCM certification to be eligible for the contract. The solicitation was posted on October 26, 2026, with a response deadline of December 8, 2026. The project falls under NAICS code 236118 and requires the delivery of fully repaired and stabilized wooden structural components.

Parks and Wildlife Department

POSTED

DEADLINE

in about 1 month

Housing Rehabilitation Program- 1137 Bel Air Ct, Modesto, CA 95350

Solicitation # HUD-INF-IFB-00132

Solicitation HUD-INF-IFB-00132 is an invitation for bids for residential repairs and rehabilitation at 1137 Bel Air Ct, Modesto, CA 95350. Funded by the U.S. Department of Housing and Urban Development (HUD), the project is administered by the City of Modesto's Community and Economic Development Department. The selected contractor must provide all labor, materials, and supervision to complete the work in accordance with California Building Code standards and the Community Development Division's Housing Rehabilitation Program. Key requirements include holding a valid California Class B General Building Contractor license and maintaining approved insurance coverage for general liability, workers' compensation, and automobile liability through the City's Public Improvement Notification System (PINS). Bids must be submitted electronically via the OpenGov Procurement Portal by November 2, 2026, at 4:00 pm. Proposals must include a Work Write-Up with itemized costs, and the City reserves the right to reject bids that exceed the Housing Rehabilitation Specialist's cost estimate by more than 15%. While the project is not subject to prevailing wage requirements, the City strongly encourages participation from Section 3 businesses. The awarded contractor is required to provide a COVID-19 Health and Safety Plan and an operation and maintenance manual upon completion. Performance is subject to liquidated damages of 65 dollars per day for delays, and final payment is contingent upon a signed Certificate of Completion and necessary termite and lead-based paint clearances.

Community and Economic Development

POSTED

DEADLINE

Housing Rehabilitation Program-1017 Crippen Ave, Modesto, CA 95351

Solicitation # HUD-INF-IFB-00130

The City of Modesto Community and Economic Development Department is soliciting bids for a housing rehabilitation project located at 1017 Crippen Ave, Modesto, CA 95351. Funded through the U.S. Department of Housing and Urban Development, the project emphasizes economic opportunities for low-income individuals via Section 3 requirements. The scope of work involves providing all supervision, labor, materials, and equipment necessary to perform repairs as detailed in the Work Write-Up. Bidders must hold a valid California General Contractor Class B license and maintain compliant insurance coverage, including General Liability, Workers Compensation, and Automobile Liability, approved through the City's Public Improvement Notification System. Bids must be submitted electronically via the OpenGov Procurement Portal by November 2, 2026, at 4:00 pm. To be validated, bids must include a completed Work Write-Up/Submittal sheet with itemized costs and fall within 15 percent of the Housing Rehabilitation Specialist's cost estimate. The project is not subject to prevailing wage requirements, but contractors must comply with strict safety standards, including OSHA Asbestos Standards, lead-based paint compliance under 24 CFR Part 35 Subpart J, and the submission of a COVID-19 Health and Safety Plan. The approximate contract award date is January 2027. Performance is subject to a liquidated damages penalty of 65 dollars per calendar day for delays. Final payment is contingent upon inspection and approval by the homeowner and the City of Modesto, and requires the delivery of an Operation and Maintenance manual for all new installations. Invoices must be signed by the contractor, homeowner, and relevant City specialists, with reimbursement typically processed within 30 days.

Community and Economic Development

POSTED

DEADLINE

Housing Rehabilitation Program- 103 Chabot Ct, Modesto, CA 95354

Solicitation # HUD-INF-IFB-00131

The City of Modesto Community and Economic Development Department is soliciting bids for a housing rehabilitation project located at 103 Chabot Ct, Modesto, CA 95354, under solicitation number HUD-INF-IFB-00131. Funded by the U.S. Department of Housing and Urban Development, the project emphasizes Section 3 requirements to expand economic opportunities for low-income individuals. Bidders must hold a valid California Class B General Building Contractor license and maintain compliant insurance coverage, including General Liability, Workers Compensation, and Automobile Liability, approved through the City's Public Improvement Notification System. All bids must be submitted electronically via the OpenGov Procurement Portal by November 3, 2026. The scope of work requires adherence to the California Building Code, California Green Building Standards Code, and specific lead-safe work practices for homes built before 1978. Awarded contractors must provide a COVID-19 Health and Safety Plan and are subject to a one-year warranty period to remedy any defects. Bids must be within 15 percent of the Housing Rehabilitation Specialist's cost estimate to be considered reasonable. While the project is not subject to prevailing wage requirements, it does include liquidated damages of 65 dollars per day for delays. Payment is processed upon the submission of detailed invoices signed by the contractor, homeowner, and city specialists, with final payment issued upon total completion and the signing of a Certificate of Completion.

Community and Economic Development

POSTED

DEADLINE

General Building Maintenance/Handyman ServicesThis subcontract for General Building Maintenance and Handyman Services involves performing miscellaneous small-scale repairs and general maintenance for prime contractors at Middle Georgia State University residence halls. The scope of work includes replacing door hardware, repairing windows, replacing ceiling tiles, and addressing general wear-and-tear using standard carpentry tools. While the focus is on minor fixes, a General Contractor License is required for larger tasks to ensure facility conditions are properly maintained and repair tickets are completed. The opportunity is categorized under NAICS code 236118 and was posted on October 26, 2026, with a response deadline of November 30, 2026. Interested parties can find further details through the Georgia Department of Administrative Services portal.

Middle Georgia State University

POSTED

DEADLINE

in about 1 month

FRA Remedial Works - North West (Lot 3)This subcontract involves performing general fire risk assessment remedial works for prime contractors on residential projects managed by the London & Quadrant Housing Trust within the North West region. The scope of work focuses on executing general construction and repair tasks to resolve fire safety deficiencies identified in official FRA reports, utilizing standard construction materials while adhering strictly to UK fire safety regulations and construction standards. The project, titled FRA Remedial Works - North West (Lot 3), is categorized under NAICS code 236118. Interested parties must submit their responses by the deadline of November 23, 2026, to ensure the delivery of completed remedial works as specified in the governing safety reports.

London & Quadrant Housing Trust

POSTED

DEADLINE

FRA Remedial Works - North London (Lot 2A)This subcontract agreement involves the execution of general fire risk assessment remedial works for residential projects managed by the London & Quadrant Housing Trust in North London. The selected provider will work under prime contractors to address fire safety deficiencies identified in official FRA reports, utilizing standard construction materials to perform necessary repairs and general construction tasks. All activities must strictly adhere to UK fire safety regulations and established construction standards to ensure the safety and compliance of the residential properties. The project, identified as FRA Remedial Works - North London (Lot 2A), is categorized under NAICS code 236118. Interested parties must submit their responses by the deadline of November 23, 2026. The primary objective of the contract is the successful delivery of all remedial works as specified in the provided fire risk assessment documentation to mitigate identified hazards across the trust's housing portfolio.

London & Quadrant Housing Trust

POSTED

DEADLINE

FRA Remedial Works - South London (Lot 1A)This subcontract involves performing general fire risk assessment remedial works for prime contractors on residential projects managed by the London & Quadrant Housing Trust in South London. The scope of work focuses on executing general construction and repair tasks to resolve fire safety deficiencies identified in official FRA reports, utilizing standard construction materials while ensuring full compliance with UK fire safety regulations and construction standards. The project, titled FRA Remedial Works - South London (Lot 1A), was posted on October 26, 2026, with a response deadline of November 23, 2026. The primary objective is the delivery of completed remedial works as specified in the assessment reports to enhance the safety of the residential properties within the designated region.

London & Quadrant Housing Trust

POSTED

DEADLINE

rehab both unit 107 Lacey Lane and 113 Lacey Lane

Solicitation # 168634

The Choctaw Nation Housing Authority is soliciting bids for the comprehensive rehabilitation of two residential units, 107 and 113 Lacey Lane, located in Poteau, Oklahoma. The objective is to make both homes move-in ready, with all work meeting or exceeding 2019 IRC standards. The scope of work includes extensive interior and exterior renovations, such as replacing ridge caps, gutters, and windows, as well as repairing and painting all drywall. Flooring updates involve installing 12x12 VCT tile with a waterproofing membrane across units 107, 113, and 109. Plumbing and electrical upgrades are required for both units, including the installation of new fixtures, Delta plumbing components, and updated electrical panels and lighting. Unit 107 requires a full HVAC replacement with a minimum 14.3 SEER2-rated electric heat pump and new hardwood cabinetry with granite countertops. Special emphasis is placed on ADA compliance, particularly for unit 113, which requires ADA-compliant door thresholds, comfort-height commodes, and a master bathroom equipped with grab bars and a wall-mount shower seat. The contractor is responsible for all permits, line locates, waste removal, and final yard restoration. Prospective bidders must visit the site before submitting quotes, as change orders for conditions identifiable during a site visit will not be approved. Key administrative requirements include providing an AHRI certificate for HVAC equipment to receive payment and obtaining color approvals from John Cook or Kash Clemons. Bids are due by November 2, 2026.

Choctaw Nation Housing Authority

POSTED

DEADLINE

More opportunities from California → City of Encinitas

Same awarding agency

Park Equipment Replacement at Wiro and Orpheus Parks

Solicitation # ENG-BID 26-05

The City of Encinitas is soliciting bids for solicitation number ENG-BID 26-05 to replace playground equipment at Wiro and Orpheus Parks. The project at Wiro Park focuses on the removal of existing equipment and surfacing, followed by the installation of new playground structures and poured-in-place rubber surfacing. At Orpheus Park, the scope includes removing old equipment and surfacing to install new playground structures, drain inlets, and engineered mulch media, as well as the construction of an ADA-compliant concrete ramp from the adjacent sidewalk. Additionally, the Orpheus Park portion of the contract includes two additive alternates for the replacement of the existing picnic shade shelter and the construction of an adult fitness area. Interested parties must submit their responses by November 11, 2026, at 2:00 PM PT. All project activities will be performed within Encinitas, California.

All Other Specialty Trade Contractors

POSTED

DEADLINE

Clearing, Grubbing, and Demolition (Wiro and Orpheus Parks)This subcontract involves site clearing, grubbing, and demolition services for the Wiro and Orpheus Parks projects within the City of Encinitas, California. The selected contractor will work under prime contractors to remove vegetation and demolish existing structures and equipment using heavy machinery for demolition and hauling. Additionally, the contractor is responsible for implementing all necessary erosion control measures to ensure the sites are fully prepared for subsequent construction activities. The opportunity is categorized under NAICS code 238910 and is located in Encinitas, zip code 92024. Interested parties must submit their responses by the deadline of November 12, 2026. This project is specifically focused on delivering construction-ready sites for city park improvements.

Site Preparation Contractors

POSTED

DEADLINE

Traffic Control Services (Wiro and Orpheus Parks)This subcontract for Traffic Control Services supports prime contractors on City of Encinitas park projects, specifically focusing on Wiro and Orpheus Parks. The selected provider is responsible for ensuring safe traffic flow and site perimeter security through the preparation of traffic control plans and the deployment of essential safety equipment, including cones, signs, electronic message boards, flashing arrow signs, flaggers, detours, and barricades in accordance with Section 601-2.2. The scope of work also includes the utilization of K-rail and delineators to maintain safety during construction. The opportunity is managed by the City of Encinitas in California, with performance taking place in Encinitas, zip code 92024. The solicitation was posted on October 20, 2026, and requires a response by the deadline of November 12, 2026. This project falls under NAICS code 561990.

All Other Support Services

POSTED

DEADLINE

ADA Concrete Ramp and Hardscape (Orpheus Park)This subcontract agreement covers the installation of ADA-compliant concrete ramps, hardscape, and play area curbs at Orpheus Park for the City of Encinitas. The scope of work involves utilizing Portland Cement Concrete and crushed aggregate base to deliver high-quality paving and curbing. The contractor is responsible for providing all necessary mix designs and conducting compressive strength testing in accordance with Section 201 and Subsection 201-1.1.4. The project is categorized under NAICS code 238110 and is located in Encinitas, California. Interested parties must submit their responses by the deadline of November 12, 2026. The contract ensures that all completed concrete work meets strict ADA compliance standards for public park accessibility.

Poured Concrete Foundation and Structure Contractors

POSTED

DEADLINE

PVC Storm Drain Installation (Wiro Park)This subcontract for the PVC Storm Drain Installation at Wiro Park involves the excavation and installation of 6-inch PVC storm drain pipe systems for prime contractors on City of Encinitas park projects. The scope of work requires the use of specialized trenching equipment to deliver a fully functional system installed in accordance with Section 315.1.5. The project is located in Encinitas, California, under NAICS code 238910. The solicitation was posted on October 20, 2026, with a response deadline set for November 12, 2026.

Site Preparation Contractors

POSTED

DEADLINE

Rubberized Play Surfacing Installation (Wiro Park)This subcontract involves the installation of rubberized safety surfacing for the City of Encinitas park projects, specifically at Wiro Park. The selected contractor will work under a prime contractor to perform essential tasks including surface and subgrade preparation, form work, and the pouring of rubberized materials. All work must be completed in accordance with project plans and Section 303-9.7, utilizing specialized pouring equipment and materials to deliver a finished play surface. The project is located in Encinitas, California, within the 92024 zip code. Interested parties must submit their responses by the deadline of November 12, 2026. This opportunity falls under NAICS code 238990 and is focused on the delivery of a high-quality, installed rubberized safety area for public use.

All Other Specialty Trade Contractors

POSTED

DEADLINE

Playground Equipment Installation (Wiro Park)This subcontract for the Wiro Park project in Encinitas, California, involves the installation of playground equipment for prime contractors working on City of Encinitas park projects. The scope of work includes footing excavation, subgrade preparation, and full equipment installation according to project plans, as well as the provision of necessary structural plans and calculations. The contractor must ensure all work adheres to ASTM F 1487, ASTM F 1292, and U.S. CPSC standards. A critical requirement is that the final delivery must be safety-certified by a National Playground Safety Institute certified inspector. The response deadline for this opportunity is November 12, 2026.

All Other Specialty Trade Contractors

POSTED

DEADLINE

Park Equipment Replacement Project At Wiro And Orpheus Parks

Solicitation # ENG-BID 26-05

The City of Encinitas is soliciting bids for the Park Equipment Replacement Project at Wiro and Orpheus Parks, identified as solicitation ENG-BID 26-05 and project CP23D. The scope of work includes the installation of playground equipment, rubberized play surfacing, and a 6-inch PVC drain pipe at Wiro Park, as well as mobilization, traffic control, and the installation of an ADA-compliant concrete ramp at Orpheus Park. All work must adhere to ASTM F 1487, ASTM F 1292, and U.S. Consumer Product Safety Commission standards, with final certification required from a National Playground Safety Institute Certified Playground Inspector. The project is a prevailing wage contract under determination 2026-2 and requires bidders to provide bid, performance, and payment bonds. The contract will be awarded to the lowest responsive and responsible bidder based on the sum total of the base bid, with the City reserving the right to award additive alternates. The total performance period is 150 working days, divided into a 70-day procurement phase and an 80-day construction phase, though this may extend to 90 days if all additive alternates are awarded. To minimize public disruption, neither park playground area may be closed for more than 40 working days. Payment will be made via monthly progress payments at 95 percent of the work value, with the final 5 percent retained until 60 days after the recordation of the Notice of Completion. Bids are due by November 12, 2026, and must include comprehensive documentation, including a 50 percent own forces requirement and various legal certifications.

All Other Specialty Trade Contractors

POSTED

DEADLINE

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Join 750+ contractors already using CLEATUS