Psst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveCLEATUS Webinar: AI for Government Contracting — Free Webinar — Wednesday, September 30 at 2:00 PM EDT

Register Free →

Search

Top

Back to Contracts

DR 2026-0024, CDP 2026-0025, and Variance 2026-0026 Krishna Residence

Active

State & Local

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

The Krishna Residence project in Laguna Beach, California, involves the demolition of existing structures to facilitate the construction of a new single-family dwelling and a two-car garage. Located in an R-1 Residential Low Density zone, the development is situated in an environmentally sensitive oceanfront area and includes extensive site improvements such as new vehicular access, elevator height adjustments, grading, retaining walls, and elevated decks. Additional amenities for the property include a pool, spa, fencing, and landscaping. The project is managed through various regulatory filings, including DR 2026-0024, CDP 2026-0025, and Variance 2026-0026. A Notice of Exemption was filed in September 2026, certifying that the project is categorically exempt from the California Environmental Quality Act (CEQA) under State Guidelines Section 15303. Key points of contact for the project include the Principal Planner for the City of Laguna Beach and the project architect.

General Info

Demolition and construction of a single-family home and garage in Laguna Beach, California.

Agency

California → City of Laguna Beach

NAICS

236115 - New Single-Family Housing Construction (except For-Sale Builders)

Place of Performance

Coast Highway & 10th Avenue, Laguna Beach, CA, 92651

Set-Aside

NONE

Documents

(0)

No documents available

AI Contract Breakdown

Uniform Contract Format

No documents to break down

The breakdown needs solicitation documents. None were found from this contract's source.

Timeline

PostedSep 25

forecast

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more

AgencyCalifornia → City of Laguna Beach

Contacts2 people available

OfficeN/A

Organization / Agency

California → City of Laguna Beach

Office AddressN/A

Contacts

Wendy JungPrincipal Planner

contact@example.gov

+1 (555) 000-0000

Morris SkenderianArchitect

contact@example.gov

+1 (555) 000-0000

Full Description

Show more

Demolish existing structures and construct a new single-family dwelling, two-car garage with new vehicular access, elevator height, grading, retaining walls, elevated decks, pool, spa, fencing, landscaping, and construction in an environmentally sensitive area (oceanfront) in the R-1 (Residential Low Density) zone.

Similar Contracts

Same NAICS industry code

Residential Home Construction (General/Shell)This subcontract for Residential Home Construction involves the delivery of turn-key 3 and 4-bedroom homes for prime contractors working on Housing Authority of the Cherokee Nation residential projects. The scope of work includes framing and roofing with Gable or Hip configurations, as well as the implementation of ADA handicap modifications for designated units. All work must be performed in compliance with Davis-Bacon labor standards to ensure the delivery of completed residential structures. The project is managed by the Cherokee Nation Housing Authority under NAICS code 236115. The solicitation was posted on September 25, 2026, with a response deadline of October 23, 2026.

Cherokee Nation Housing Authority

POSTED

DEADLINE

Solicitation 2026-001-055- New Construction-Cherokee, Delaware, Mayes, Rogers, and Sequoyah Co.

Solicitation # 2026-001-055

The Housing Authority of the Cherokee Nation is soliciting bids for the turn-key construction of eight 3- and 4-bedroom homes located within the Cherokee Nation Reservation across Cherokee, Delaware, Mayes, Rogers, and Sequoyah Counties. The project requires the contractor to provide all labor, materials, equipment, permits, and supervision, including comprehensive site preparation such as tree removal, driveway installation, and the construction of well and septic systems. Specific technical requirements include the use of gable or hip roof designs, with at least one unit requiring full ADA handicap accessibility. The project must be completed within 120 working days from the Notice to Proceed, with a penalty of 1,000 dollars per working day for delays beyond the contract end date. The contract will be awarded to the lowest responsive and responsible bidder, with a strong preference given to Indian-owned economic enterprises. Bidders must comply with Davis-Bacon prevailing wage rates and provide certifications regarding Indian preference in employment and subcontracting. Mandatory submission documents include a non-collusive affidavit, trade licenses, insurance certificates for general liability, auto, and workers compensation, and a core crew listing. Final payment is contingent upon the delivery of closing documents, including as-built drawings, final DEQ paperwork, and lien releases from all subcontractors. Performance and payment bonds totaling 100 percent of the contract price are required.

Cherokee Nation Housing Authority

POSTED

DEADLINE

Cutting, Patching & DrywallThis subcontract for the Village of Southampton in New York focuses on cutting, patching, and drywall services for local government projects. The selected provider will perform structural modifications and surface restoration, including the installation of gypsum board assemblies and the sealing of cavities to prevent pest infiltration. The primary objective is to ensure that all patched and sealed walls and ceilings are restored to their original condition. Qualified candidates must possess expertise in general construction or carpentry to execute these tasks for prime contractors. The solicitation was posted on September 24, 2026, with a response deadline of October 22, 2026. This opportunity falls under NAICS code 236115.

Village of Southampton

POSTED

DEADLINE

Residential General Construction (Home Building)The Town Administrator's Office for Massachusetts is seeking a subcontractor for Residential General Construction to build residential homes, including affordable housing units, on Providence Road in Grafton. The selected contractor will be responsible for the structural assembly of these dwellings, specifically performing framing, roofing, and siding to deliver completed homes ready for sale. This subcontract opportunity is listed under NAICS code 236115 and was posted on September 23, 2026. Interested parties must submit their responses by the deadline of November 12, 2026, at 6:00 PM.

TAOFF - Town Administrator's Office

POSTED

DEADLINE

in about 2 months

Solicitation A10-09-26-9618- Housing Rehab- Tulsa County

Solicitation # A10-09-26-9618

The Housing Authority of the Cherokee Nation is soliciting bids for the demolition of an existing residential structure and the turnkey construction of one 2-bedroom, 2-bathroom ADA-compliant replacement home located at 1402 E 69th St North in Tulsa County, Oklahoma. The project requires the contractor to provide all necessary labor, materials, equipment, permits, and supervision. Key technical specifications include a 1,099 square foot floor plan featuring a 36-inch entry doorway, high-rise toilets, and an ADA shower with transfer. The contractor is responsible for all utility connections and must adhere to all local, city, and state building codes. The project must be fully completed within 180 work days, with a penalty of $1,000 per working day for delays beyond the contract end date. Bids are due by October 14, 2026, at 5:00 p.m. and will be awarded based on the lowest responsive bid, with specific preferences given to TERO-certified Indian-owned enterprises. Compliance with Davis-Bacon prevailing wage rates is mandatory, and contractors must submit comprehensive documentation, including HUD Form 5369-A, insurance certificates, and trade licenses. Payment is structured around a three-phase milestone schedule, requiring the submission of lien waivers and final payrolls before the final draw is released.

Cherokee Nation Housing Authority

POSTED

DEADLINE

Residential General Carpentry & FramingThis subcontract for Residential General Carpentry and Framing involves performing structural framing and exterior shell construction for prime contractors on residential projects within the City of Florence, South Carolina. The scope of work includes framing walls, installing roof trusses, and installing sheathing to deliver completed structural frames for four single-family residences. The project is categorized under NAICS code 236115 and requires strict compliance with Davis-Bacon Wage Decisions SC20260066. Interested parties must submit their responses by the deadline of October 2, 2026, at 6:15 PM.

City Of Florence

POSTED

DEADLINE

General Residential ConstructionThis subcontract for General Residential Construction involves the full-scale construction of six new single-family residential homes as part of the City of Statesboro affordable housing projects. The selected contractor will be responsible for managing all site work and specialty trades to deliver six completed homes that are ready for certificates of occupancy, ensuring all dwellings adhere to local building codes and energy-efficient standards. The project requires strict compliance with Section 3 hiring regulations and MBE/WBE participation goals. Interested parties must submit their responses by the deadline of November 5, 2026. This opportunity falls under NAICS code 236115 and is managed through the state of Georgia for the City of Statesboro.

City of Statesboro

POSTED

DEADLINE

in about 1 month

THE GEORGIA DEPARTMENT OF COMMUNITY AFFAIRS (DCA) CHIP - FUNDED HOUSING DEVELOPMENT PROGRAM

Solicitation # PE-61650-NONST-2027-000000066

The City of Statesboro Planning and Development Department is seeking a qualified development partner to implement six new construction single-family homeownership units for low-income households. This initiative is funded through the Georgia Department of Community Affairs Community HOME Investment Program and requires the selected partner to manage the full development lifecycle, including site coordination, construction oversight, and administrative compliance. The project emphasizes the creation of high-quality, energy-efficient housing and requires strict adherence to the HOME Investment Partnerships Program Final Rule, HUD regulations, Fair Housing, Equal Opportunity, and Section 3 requirements. Qualified firms must submit their qualifications package by November 5, 2026, consisting of three paper copies and one USB copy delivered to Darren Prather. Evaluation is based on a 70-point scale across seven categories: affordable housing and new construction experience, organizational capacity, financial stability, development approach, partnership experience with income-qualified homebuyers, past performance references from the last five years, and overall responsiveness. Applicants must provide professional credentials, financial evidence, and documentation of Community Housing Development Organization certification if applicable. The City reserves the right to conduct interviews and negotiate final terms with the selected respondent.

City of Statesboro

POSTED

DEADLINE

in about 1 month

Earley Variance

Solicitation # PLN26-00133

The Earley Variance project, identified as solicitation PLN26-00133, is a request submitted to the Placer County Community Development Resource Agency for the construction of a 1,750 square-foot detached garage at 5937 Del Oro Road in California. The applicant is seeking a variance to allow the structure to be placed 12 feet from both the west side and north rear property lines, which deviates from the standard 30-foot setback requirement. The primary purpose of the garage is to provide storage for various vehicles, including a recreational vehicle, trailers, a boat, a quad, and two buggies. The project is managed by technician Claudia Garcia and was posted as a forecast on September 22, 2026. According to the Notice of Exemption filed on September 17, 2026, the construction is categorically exempt from the California Environmental Quality Act environmental review under Sections 15303 and 15305.

Placer County Community Development Resource Agency

POSTED

DEADLINE

Piasente Side Setback Variance

Solicitation # PLN26-00229

The Piasente Side Setback Variance, identified as project PLN26-00229, is a request submitted to the Placer County Community Development Resource Agency for the construction of a 720 square-foot shop with an attached 360 square-foot carport. The project, located at 2422 Topside Drive in Auburn, California, seeks a variance to allow the structure to be positioned six feet from the side property line, whereas a setback of 30 feet is typically required. The project was posted on September 22, 2026, and is managed by technician Claudia Garcia. According to the Notice of Exemption dated September 17, 2026, the project is categorically exempt from the California Environmental Quality Act review under Sections 15303 and 15305.

Placer County Community Development Resource Agency

POSTED

DEADLINE

Framing & Building EnvelopeThis subcontract for Framing and Building Envelope involves the structural framing and exterior cladding for 102 townhouse units as part of CIVIDA affordable housing projects. The scope of work includes the installation of wall framing, floor joists, and building envelope materials to ensure proper weatherproofing and structural integrity, ultimately delivering the completed building shell. The project is managed by Civida under NAICS code 236115. The solicitation was posted on September 21, 2026, with a response deadline of October 19, 2026.

POSTED

DEADLINE

Affordable Housing ConstructionThis subcontract for the Town of Yarmouth involves the physical construction of new affordable housing units along the Route 28 corridor. The selected contractor will be responsible for the full build process, including site preparation, framing, roofing, utility installation, and interior finishing, to deliver residential buildings that are ready for certificates of occupancy. Eligible bidders must possess a General Contractor's License and provide necessary bonding and insurance. This opportunity, categorized under NAICS code 236115, was posted on September 21, 2026, with a response deadline of December 4, 2026. Performance will take place within the 02664 zip code area.

01YAR - TOWN HALL

POSTED

DEADLINE

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Join 750+ contractors already using CLEATUS