Psst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveCLEATUS Webinar: AI for Government Contracting — Free Webinar — Wednesday, October 28 at 2:00 PM ET

Register Free →

Search

Top

Back to Contracts

Infrastructure - Invitation to Bid - Duct Cleaning and Hazardous Materials Abatement

Active

AB-2026-06964International

Response Deadline11/03/2026, 09:01:00 PM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

BGIS, acting on behalf of Alberta Infrastructure, is seeking bids for duct cleaning and hazardous materials abatement at the Devon Research Centre and Alberta Research Centre. Testing has confirmed the presence of lead and asbestos within the ductwork, although air monitoring suggests these materials are not airborne during typical HVAC operations. The selected contractor must perform cleaning services in strict accordance with National Air Duct Cleaning Association standards and low risk asbestos cleanup requirements. Interested parties must submit their responses by November 3, 2026, for this Alberta based project.

General Info

Bids for duct cleaning and hazardous materials abatement in Alberta due November 3, 2026.

Agency

NAICS

562910 - Remediation Services

Place of Performance

AB, CAN

Set-Aside

NONE

Documents

0

No documents available

Documents will appear here when they are available.

AI Contract Breakdown

Uniform Contract Format

No documents to break down

The breakdown needs solicitation documents. None were found from this contract's source.

Timeline

PhaseSolicitation

PostedOct 19

Solicitation

Response DeadlineNov 3

Submission deadline

Response Deadline

11/03/2026, 09:01:00 PM UTCin 12 days

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more

AgencyInfrastructure

Contacts1 person available

OfficeN/A

Organization / AgencyInfrastructure

Office AddressN/A

Contacts

Mike McMasterFacility Manager III

contact@example.gov

+1 (555) 000-0000

Full Description

Show more

BGIS on behalf of Alberta Infrastructure The Devon Research Centre and Alberta Research Centre ductwork has been tested for lead and asbestos, and has been found to contain both. Air monitoring has indicated that the lead and asbestos is not airborne under typical HVAC operating conditions. The ductwork is required to be cleaned in accordance with the National Air Duct Cleaning Association (NADCA) standards, and low risk asbestos clean up requirements.

Similar Contracts

Same NAICS industry code

Asbestos and Lead AbatementThis subcontract, managed by the Bristol Alliance of Companies through its Temecula office, involves providing specialized asbestos and lead abatement services for VA Health Care System facility projects located in Loma Linda, California. The selected contractor will be responsible for the removal of asbestos-containing materials and lead-based paint in accordance with 2022 re-inspection reports, ensuring that all work areas are delivered certified asbestos and lead-free. Compliance is a critical component of this agreement, requiring strict adherence to EPA Region 9 standards and Cal-OSHA Title 8, Section 1532.1. Additionally, the performing party must hold valid CDPH Lead Inspector/Assessor certifications to meet the technical requirements of the project. The opportunity is categorized under NAICS code 562910.

Bristol Alliance of Companies

POSTED

about 5 hours ago

DEADLINE

CCENV27004 - MOLD REMEDIATION AND DEEP CLEANING RA

Solicitation # WMATA-0000010955

The Washington Metropolitan Area Transit Authority is seeking solicitations for contract CCENV27004, which focuses on mold remediation and deep cleaning services. This project falls under NAICS code 562910 and is managed through the agency's Virginia operations. The solicitation, identified by number WMATA-0000010955, was posted on October 22, 2026. Interested parties must submit their responses by the deadline of October 23, 2026.

Washington Metropolitan Area Transit Authority

POSTED

about 5 hours ago

DEADLINE

Theatre Mold Remediation Scope of Work

Solicitation # AT25-0006

Solicitation AT25-0006 is a subcontracting opportunity with Adams and Associates, Inc. for comprehensive mold remediation at Theatre Building 1086 of the Atterbury Job Corps Center in Edinburgh, Indiana. The project, necessitated by a sprinkler system failure, requires the remediation of mold throughout the entire building and the cleaning or replacement of damaged theater seating cushions. All work must be performed in accordance with ANSI/IICRC S520 standards, EPA guidelines, OSHA regulations, and the findings of the Micro Air Inc. Mold Testing report dated April 11, 2024. A key requirement is the provision of a Certified Industrial Hygienist to conduct daily site visits and a final clearance walkthrough. The contract is a single lump sum award based on best value, with evaluation weights assigned to price (60), quality (20), past performance (10), and schedule (10). Bidders must attend a mandatory site visit on October 27, 2026, and submit typed proposals on company letterhead by November 10, 2026. Required documentation includes a detailed cost breakdown, a timeline for substantial completion, proof of a valid Indiana Contractor's License, and certification of compliance with Davis Bacon Act wage rates. The selected contractor must provide specific automobile and workers compensation insurance, naming Adams and Associates, Inc. as an additional insured, and must commence work within 14 days of the Notice to Proceed. Payment terms are Net 30.

Atterbury Job Corps Center

POSTED

about 5 hours ago

DEADLINE

Maui JCC Mold Remediation and Removal of Water-Damaged Materials

Solicitation # maui-jcc-mold-remediation-removal-water-damaged-materials

Management & Training Corporation is soliciting bids for a fixed-price, single lump sum contract for mold remediation and removal of water-damaged materials at the Maui Job Corps Center in Makawao, Hawaii. The project focuses on Building 11, specifically the cafeteria, food service areas, restrooms, and adjoining spaces, which sustained significant water intrusion during a windstorm on August 15, 2026. The scope of work includes the removal of mold-affected porous materials such as drywall and ceiling tiles, the establishment of containment using HEPA-filtered negative air pressure to protect adjacent areas, and the remediation of structural surfaces. The estimated price range for this effort is between $25,000 and $100,000. Bids are evaluated based on overall best value, and a physical site visit is mandatory prior to submission. For bids of $25,000 or more, contractors must provide a bid bond guarantee equal to 20 percent of the base bid, and the awarded contractor will be required to provide performance and payment bonds from a surety company with at least an A- rating. Compliance with Davis-Bacon Act minimum wage rates and EPA guidance for mold remediation is required. The solicitation is set aside for small businesses, including VOSB, SDVOSB, WOSB, and HUBZone certifications. Required submission documents include a detailed cost breakout, three comparable references, proof of insurance, and a completed supplier self-certification packet.

Management & Training Corporation/Hawaii/Maui Job Corps Center

POSTED

about 5 hours ago

DEADLINE

Paint and Chemical Waste Recovery

Department of Transportation

POSTED

about 13 hours ago

DEADLINE

Hazardous Materials Emergency Response and Cleanup

Department of Transportation

POSTED

about 13 hours ago

DEADLINE

OFFICIAL NOTICE 84-1-2026

Solicitation # 49311

Solicitation 49311, issued by the City of Milwaukee, seeks a contractor to dismantle processing equipment from the tip floor and processing floor of a fire-damaged building. The scope of work includes the removal and disposal of all furniture and the clearing of debris from the entire space. Contractors are responsible for ensuring that all hazardous materials are removed and disposed of in strict accordance with state and federal regulations. The response deadline for this solicitation is October 30, 2026. To be considered responsive, bidders must submit a Small Business Enterprise Contractor Compliance Plan, as failure to do so may result in the bid being rejected. SBE firms must hold an active, unexpired City of Milwaukee certification and perform a Commercially Useful Function. Additionally, bidders may qualify for a Socially-Responsible Contractor bid incentive by submitting a notarized affidavit demonstrating the implementation of at least three programs designed to reduce employment barriers. All required documentation should be submitted to the Department of Administration-Purchasing Division at 841 N Broadway, Room 506, Milwaukee, Wisconsin.

City of Milwaukee

POSTED

about 14 hours ago

DEADLINE

Hazardous Material Testing and Source RemovalThis subcontract opportunity with the Cambridge Housing Authority involves providing hazardous material testing and source removal services for residential renovation projects. The selected contractor will be responsible for coordinating testing efforts, identifying hazardous materials, and executing full source removal in strict accordance with all applicable state and municipal regulations. The final deliverables include detailed testing reports and a certified clean site that is fully prepared for renovation activities. The project is located in Cambridge, Massachusetts, under NAICS code 562910. Interested parties must submit their responses by the deadline of November 5, 2026. This role functions as a subcontractor supporting prime contractors to ensure environmental safety and regulatory compliance across the authority's residential portfolio.

CHA01 - Cambridge Housing Authority

POSTED

about 14 hours ago

DEADLINE

Asbestos Abatement - HVAC Vibration DampenersThis subcontract involves the removal of asbestos-containing flexible HVAC vibration dampener cloth connectors for the City of Jackson Building Department. The scope of work requires the disconnection and removal of 16 connectors from apartment mechanical systems using specialized HVAC containment and abatement tools. Qualified bidders must hold a Licensed Environmental Abatement Contractor designation and possess HVAC-specific asbestos safety certifications. The project is categorized under NAICS code 562910, with a response deadline set for November 10, 2026.

City of Jackson

POSTED

about 15 hours ago

DEADLINE

Asbestos Abatement - Kitchen Sinks and Floor TilesThis subcontract involves the removal and legal disposal of asbestos-containing materials for the City of Jackson Building Department. The scope of work includes removing kitchen sink assemblies with sound-deadening black mastic from 16 units and floor tiles with black mastic from 8 ground-level apartments. To ensure safety and compliance, the contractor must utilize HEPA vacuums, containment barriers, and hazardous waste containers. Eligible bidders must hold a Licensed Environmental Abatement Contractor certification. The project falls under NAICS code 562910, with a response deadline of November 10, 2026. The selected contractor will be responsible for delivering certified removal and documented legal disposal of all hazardous materials.

City of Jackson

POSTED

about 15 hours ago

DEADLINE

Environmental Abatement ServicesThis subcontract for Environmental Abatement Services involves the identification and removal of hazardous materials, specifically asbestos and lead-based paint, for prime contractors working on Georgia Department of Transportation Right of Way projects. The scope of work requires the use of specialized equipment, including containment barriers and HEPA vacuums, along with appropriate personal protective equipment to ensure safe abatement and disposal. To qualify, contractors must hold all necessary state and federal abatement certifications and provide a notarized Georgia Security and Immigration Compliance Act Affidavit. The successful provider is responsible for delivering certified abatement and disposal manifests. This opportunity is categorized under NAICS code 562910, with a response deadline of October 28, 2026.

Department of Transportation

POSTED

about 18 hours ago

DEADLINE

Solicitation # 49621

The City of Columbus Department of Finance and Management in Ohio is seeking proposals for the remediation of public safety facilities located at 2077 Parkwood and 743 E Woodrow. This solicitation, identified as RFQ033899 under solicitation number 49621, falls under NAICS code 562910 for remediation services. The opportunity was posted on October 21, 2026, and requires all responses to be submitted by the deadline of November 4, 2026, at 6:00 PM. Interested parties can find further details and submission guidelines through the Bid Express portal.

City of Columbus – Department of Finance and Management

POSTED

about 18 hours ago

DEADLINE

More opportunities from Infrastructure

Same awarding agency

Infrastructure - Request for Quotes - Furniture (Lounge Seating Bufalo Jump)

Solicitation # AB-2026-07006

The Government of Alberta, through the Infrastructure agency, is seeking quotes for the supply of office furniture, specifically lounge seating for Bufalo Jump. This solicitation, identified by number AB-2026-07006, was posted on October 20, 2026, with a response deadline of November 2, 2026. The project will be performed within the province of Alberta, Canada. Interested parties should note that budget information is not provided and any listed project estimates may not reflect actual government projections. Additionally, the delivery date mentioned is an estimate only, and bidders are advised to consult the RFQ document for specific delivery details. All inquiries regarding this opportunity should be directed to Senior Procurement Officer Saheed Lasisi.

Office Furniture (except Wood) Manufacturing

POSTED

DEADLINE

Infrastructure - Request for Proposal - RFP FOR ELECTRICAL (PRIME) CONSULTANT SERVICES FOR EDMONTON – LAW COURTS: Courthouse Security Implementation Project (CSIP) and Holding Cell Lock Upgrades

Solicitation # AB-2026-06966

The Infrastructure agency is seeking proposals for a prime electrical consultant to support the Courthouse Security Implementation Project and Holding Cell Lock Upgrades at the Edmonton Law Courts in Alberta. This solicitation, identified as AB-2026-06966, focuses on enhancing security infrastructure and upgrading lock systems within the facility to ensure operational safety and efficiency. Interested parties must submit their responses by the deadline of November 16, 2026. The procurement process is being managed by Project Procurement Specialist Nkechi Nzewi, who serves as the primary point of contact for this solicitation.

Engineering Services

POSTED

DEADLINE

Infrastructure - Invitation to Bid - Calgary Court of Appeal Redevelopment

Solicitation # AB-2026-06938

CANA Management Ltd., acting on behalf of Alberta Infrastructure, is soliciting bids for the Calgary Court of Appeal Redevelopment. The project involves the construction of a five-storey building featuring an underground parkade and a +45 bridge that will connect the new structure to the existing Calgary Court Centre in Alberta. Interested parties must request access to the tender via BuildingConnected by emailing the estimating team at cana.estimating@cana.ca. The solicitation, identified by number AB-2026-06938, was posted on October 17, 2026, and requires all responses to be submitted by the deadline of October 30, 2026, at 8:00 PM.

Commercial and Institutional Building Construction

POSTED

DEADLINE

Infrastructure - Request for Quotes - Outdoor Camping Equipment and Accessories

Solicitation # AB-2026-06835

The Government of Alberta, through the Infrastructure agency, is seeking quotes to establish a Supply Arrangement for outdoor camping equipment and accessories under solicitation number AB-2026-06835. Interested parties must submit their responses by the deadline of November 6, 2026. The performance of this contract will take place within the province of Alberta. It is important to note that any values and delivery dates provided in the solicitation are estimates and do not represent final project figures or firm deadlines. All inquiries regarding this opportunity should be directed to Senior Procurement Officer Henry Seggumba via the provided corporate tendering email address.

Sporting and Recreational Goods and Supplies Merchant Wholesalers

POSTED

DEADLINE

Infrastructure - Invitation to Bid - CALGARY – ALBERTA RESEARCH COUNCIL BUILDING - CHILLER REPLACEMENT

Solicitation # AB-2026-06918

The Infrastructure agency is seeking bids for the replacement of the existing chiller and cooling pumps at the Alberta Research Council building, located at 3608 33 St NW in Calgary, Alberta. This solicitation, identified by number AB-2026-06918, focuses on critical infrastructure upgrades to the facility's cooling systems. The invitation to bid was posted on October 16, 2026, with a response deadline set for November 10, 2026, at 9:00 PM. Interested parties may coordinate with the primary point of contact, Project Procurement Specialist Rauf Ramooz, to facilitate the bidding process.

Plumbing, Heating, and Air-Conditioning Contractors

POSTED

DEADLINE

Infrastructure - Request for Proposal - TRANSACTION AND FAIRNESS CONSULTANT SERVICES - Modified Design-Build APD10

Solicitation # AB-2026-06898

Alberta Infrastructure is seeking a Transaction and Fairness Consultant to provide specialized services for a Modified Design-Build project involving the construction of six schools in Edmonton and the surrounding area. This solicitation, identified as AB-2026-06898, focuses on ensuring the integrity and transparency of the alternative project delivery process. Interested parties must submit their responses by the deadline of November 9, 2026. The project is managed by the Infrastructure agency in Alberta, with Aaron Rose serving as the primary point of contact for procurement inquiries.

Administrative Management and General Management Consulting Services

POSTED

DEADLINE

Infrastructure - Invitation to Bid - VULCAN - PARKS WORKSHOP - Roof Replacement

Solicitation # AB-2026-06875

This infrastructure project involves a comprehensive roof replacement for the Parks Workshop located in Vulcan, Alberta. The scope of work requires the complete removal and disposal of the existing asphalt and felt BUR membrane system, including gravel protection, gypsum board, vapour retarders, insulation, and associated metal flashings. Additionally, the contractor must remove roof-mounted antenna towers and their related components, while carefully storing and reinstalling any exterior instruments or devices displaced during the process. The installation phase includes the placement of new gypsum board on the steel deck, an air barrier, vapour retarder membrane, insulation, composite coverboard, and a new 2-ply SBS membrane system. Key structural and safety additions include new metal flashings, roof drain assemblies, two overflow scuppers, a non-penetrating safety zone warning line, and a grab handle for the roof hatch. The project also requires the fabrication and installation of an engineered fixed roof access ladder connecting lower Roof Area 2 to upper Roof Area 4. Bids for solicitation AB-2026-06875 are due by November 5, 2026.

Roofing Contractors

POSTED

DEADLINE

Infrastructure - Notice of Planned Procurement - Infrastructure’s Procurement Pipeline Edition # 7

Solicitation # AB-2026-06880

Alberta Infrastructure has issued a notice of planned procurement under solicitation number AB-2026-06880, detailing its procurement pipeline for upcoming construction projects. This notice focuses on projects delivered by Alberta Infrastructure that have secured construction funding and carry a budget exceeding 5 million dollars. The solicitation was posted on October 14, 2026, with a response deadline set for February 26, 2027. All work associated with these procurements will be performed within the province of Alberta. Max Amodio, the Executive Director of Procurement, serves as the primary point of contact for this initiative.

Commercial and Institutional Building Construction

POSTED

DEADLINE

Infrastructure - Notice of Planned Procurement - Infrastructure’s Procurement Pipeline Edition # 7

Solicitation # AB-2026-06876

Alberta Infrastructure has issued a notice of planned procurement under solicitation number AB-2026-06876, detailing its procurement pipeline for upcoming construction projects. This initiative focuses on projects delivered by Alberta Infrastructure that have secured construction funding and carry a budget exceeding 5 million dollars. The solicitation was posted on October 14, 2026, with a response deadline set for February 26, 2027. These projects will be performed within the province of Alberta. Max Amodio, the Executive Director of Procurement, serves as the primary point of contact for this procurement process.

Commercial and Institutional Building Construction

POSTED

DEADLINE

Infrastructure - Request for Proposal - REQUEST FOR PROPOSALS (RFP) FOR PRIME ARCHITECTURAL CONSULTANT SERVICES FOR PADDLE PRAIRIE- K-12 PADDLE PRAIRE SCHOOL REPLACEMENT

Solicitation # AB-2026-06869

The Infrastructure agency is seeking proposals for prime architectural consultant services to facilitate the replacement of the Paddle Prairie K-12 school located in Alberta. This solicitation, identified by number AB-2026-06869, focuses on securing professional architectural expertise to lead the design and planning phases of the school replacement project. Interested parties must submit their responses by the deadline of October 29, 2026, at 10:00 PM. The procurement process is being managed by Project Procurement Specialist Shosama Chowdhury, who serves as the primary point of contact for this infrastructure initiative.

Architectural Services

POSTED

DEADLINE

Infrastructure - Request for Qualification - REQUEST FOR QUALIFICATION - CLAIRMONT-PEACE WAPITI ACADEMY REPLACEMENT

Solicitation # AB-2026-06862

This project involves the construction of a Grade 9-12 school for the Peace Wapiti School Division located in Clairmont, Grande Prairie County No. 1, Alberta. The facility is designed with an initial capacity for 1,225 students and a programmed gross floor area of 11,395 square meters, with the potential to expand to 1,425 students through permanent or modular additions. The procurement process is being managed by Infrastructure Alberta under solicitation number AB-2026-06862. The project utilizes a Design-Build delivery method guided by Bridging Documents, which include schematic designs and performance requirements developed by a Bridging Consultant. These documents establish the minimum technical and functional standards while encouraging proponents to offer innovative and cost-effective solutions. Interested parties must respond to the Request for Qualification by the deadline of November 10, 2026.

Commercial and Institutional Building Construction

POSTED

DEADLINE

Infrastructure - Request for Proposal - EDMONTON - LEGISLATURE BUILDING Rotunda Renewal

Solicitation # AB-2026-06856

The Infrastructure agency is seeking formal offers through an Adjusted Price bid call for the Rotunda Renewal project located at the Legislature Building in Edmonton, Alberta. This solicitation, identified by number AB-2026-06856, focuses on infrastructure improvements and renewal work within the specified historic site. Interested parties must submit their responses by the deadline of November 5, 2026, at 9:00 PM. The procurement process is being managed by Project Procurement Specialist Austin Speers, who serves as the primary point of contact for this request for proposal.

Commercial and Institutional Building Construction

POSTED

DEADLINE

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Join 750+ contractors already using CLEATUS