Psst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveCLEATUS Webinar: AI for Government Contracting — Free Webinar — Wednesday, September 16 at 2:00 PM EDT

Register Free →

Search

Top

Back to Contracts

Minimum of 18,884 BUSF not to exceed 20,000 BUSF

Awarded

CSOSA-L-26-0001a2Federal

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

The contract requires the provision of between 18,884 and 20,000 Business Unit Square Feet of office space in Washington D.C., specifically for the Court Services and Offender Supervision Agency. The space must be capable of replication and relocation if the winning bidder is not the current lessor, ensuring continuity of operations regardless of vendor change. The solicitation number is CSOSA-L-26-0001a2, posted on July 21, 2026, with no set-aside designation applied, meaning all eligible contractors may compete. The NAICS code 531120 identifies the contract as related to real estate lessors of nonresidential buildings. Performance will take place within the District of Columbia, with a zip code of 20018, and all communications and inquiries should be directed to Tiffany de Lisio or Elijah Anderson at the provided contact details. The agency is located in Washington D.C. with a zip code of 20004, and the full procurement details are accessible through the SAM.gov portal.

General Info

Provide 18,884–20,000 sq ft office space in D.C. for CSOSA, relocatable, no set-aside, NAICS 531120, SAM.gov portal.

Agency

Court Services And Offender Supervision Agency → Court Services Offender Supv AgcyView Agency

Contract Value

$15,186,415

NAICS

531120 - Lessors of Nonresidential Buildings (except Miniwarehouses)View NAICS

Place of Performance

DC, 20018, USA

Set-Aside

NONE

Awardee

BOUNDARY 900 RI AVE LLCView Profile

Award Issued Date

06/30/2026, 12:00:00 AM UTC

Documents

(0)

No documents available

AI Contract Breakdown

Uniform Contract Format

No contract breakdown available.

Cannot generate Contract Breakdown because no documents were found from this contract's source.

Timeline

PhaseAwarded

PostedJul 21

Award Notice

AwardedJun 30

Contract was awarded

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more

AgencyCourt Services And Offender Supervision Agency → Court Services Offender Supv Agcy

Contacts2 people available

OfficeWASHINGTON, DC, 20004, USA

Organization / Agency

Court Services And Offender Supervision Agency → Court Services Offender Supv Agcy

View Agency Profile

Office AddressWASHINGTON, DC, 20004, USA

Contacts

Tiffany de Lisio

contact@example.gov

+1 (555) 000-0000

Elijah Anderson

contact@example.gov

+1 (555) 000-0000

Full Description

Show more

18,884 BUSF Office Space Field Office requiring replication and relocation if LPTA was other than incumbent lessor.

Similar Contracts

Same NAICS industry code

WAREHOUSE SPACE NEEDED IMMEDIATELY

Solicitation # 27734

The Chickasaw Nation is seeking immediate lease of a warehouse facility located within Pontotoc County for the storage of fiber optic materials. The required space must be at least 10,000 square feet and fully accessible for forklift operations. The lease is intended to be a short-term arrangement for less than one year, operating on a month-to-month basis. Interested parties must submit their monthly leasing fees to the designated point of contact by the response deadline of September 15, 2026.

Chickasaw Nation

POSTED

about 19 hours ago

DEADLINE

Conference Facility / Venue Provider

TCOCP - Trial Court Commissioner of Probation

POSTED

about 21 hours ago

DEADLINE

OFFICE SPACE WANTED TO LEASE BY THE STATE OF CALIFORIA in Palmdale

Solicitation # 17250

The California Department of General Services, acting on behalf of the Department of Social Services, is soliciting proposals for approximately 5,653 nusf of office space in Palmdale, Los Angeles County. The required space must include 25 parking spaces, consisting of 5 exclusive fleet spaces and 20 non-exclusive spaces. The search area is bounded by W Ave O to the north, Pearblossom Hwy to the south, 55th St E to the east, and 25th St W to the west. Eligible properties must be asbestos hazard-free upon occupancy, close to public transportation, and compliant with Disabled Veteran Business Enterprise requirements. Facilities must also adhere to the California Building Code, Title 24, seismic safety standards, and the Americans with Disabilities Act. Preference will be given to cost-effective buildings that demonstrate LEED or Energy Star compliance. Property owners or authorized agents must submit the property address, a map, and project number 17250 to Boyce Whitlock via email or in writing by September 28, 2026.

California Department of General Services

POSTED

about 22 hours ago

DEADLINE

U.S. GOVERNMENT SEEKS TO LEASE SPACE IN TOPEKA, KS

Solicitation # 2KS0140

The General Services Administration is seeking to lease approximately 5,239 to 5,500 square feet of contiguous office space within the city limits of Topeka, Kansas, under a long-term lease spanning 180 months with a firm term of 60 months and a one-time option to extend for an additional five years. The space must be fully serviced, accessible 24 hours a day, seven days a week, 365 days a year, and capable of supporting a high-density file system through adequate floor load capacity. The property must include 25 total surface parking spaces, with 10 reserved, secured, and fenced for government use, and allow for truck and trailer maneuverability within the parking area. The building cannot be located in an area classified as high crime by local law enforcement and must be outside the 1-percent-annual chance floodplain. It must comply with all federal standards for fire safety, accessibility, seismic resilience, and sustainability. The space must meet ANSI/BOMA office area (ABOA) measurements, with rental rates broken down into shell and operating expense components, and must include all utilities, maintenance, and services necessary for full operation. Respondents must provide building ownership details, energy efficiency metrics including Energy Star certification if applicable, a detailed list of building services, and a one-eighth inch scale floor plan or marketing brochure. Parking costs must be clearly stated and included in the rental rate. Expressions of interest must be submitted by July 23, 2026, to Bruce Keyes at bruce.keyes@gsa.gov, and must include Solicitation #2KS0140, along with documentation proving authorized representation if applicable. Entities must also comply with Section 889 of the NDAA regarding prohibited telecommunications equipment. The estimated occupancy date is August 31, 2028, following a market survey scheduled for August 20, 2026.

Pbs R00 Center For Broker Services

POSTED

DEADLINE

X1AA--HAWAII - HILO VET CENTER - RELOCATION

Solicitation # 36C24W23R0031

The Department of Veterans Affairs, through RPO West, is soliciting proposals for a fully serviced lease of contiguous clinical space for a Vet Center in Hilo, Hawaii. The government is seeking a maximum of 3,844 ABOA square feet with a total lease term of 20 years, including a 10-year firm period. The lease is a total small business set-aside and will be awarded based on a best value tradeoff, where technical factors—including facility design, site attributes, and offeror experience—are significantly more important than price. The lessor is responsible for providing all materials, labor, and services, including utilities, janitorial services, and security. Specific technical requirements include the installation of a 50 AMP exterior outlet for a Mobile Vet Center, a 20-foot illuminated flagpole, and adherence to Facility Security Level II standards. The facility must meet strict acoustic standards (STC 45 for specific rooms), ADA accessibility requirements, and seismic safety certifications. The design team must consist of licensed professionals across multiple engineering and architectural disciplines, with low-voltage designers requiring BICSI certification. Proposals must be submitted in separate technical and price volumes, with the technical offer limited to 300 pages. The contract incorporates various FAR and GSAR clauses covering labor standards, including union prevailing wage rates, and strict guidelines for the handling of Controlled Unclassified Information. Final acceptance of the space is contingent upon the government's inspection of tenant improvements, the provision of a valid Certificate of Occupancy, and compliance with ASHRAE air quality and OSHA/EPA hazardous materials standards.

Rpo West (36C24W)

POSTED

DEADLINE

in about 2 months

X1DB--Canton OH Outpatient Clinic 62,784 ANSI/BOMA Replace Appendix A_2 LDN_ Pre-bid Conference Presentation Slide Deck_Transcript_ Questions and Responses

Solicitation # 36C10F26R0052

The Department of Veterans Affairs, Office of Construction and Facilities Management, is soliciting proposals under RLP No. 36C10F26R0052 for the lease and construction of an outpatient clinic in Canton, Ohio. The project requires a facility of approximately 62,784 ANSI/BOMA square feet to support various medical services, including imaging, pathology, and clinic management. The procurement utilizes a Best-Value Tradeoff Source Selection process, evaluating both 15-year and 20-year firm lease terms. A total Tenant Improvement allowance of $24,865,000 is provided, with a target substantial completion timeline of 28 months from award. The facility must adhere to rigorous healthcare and safety standards, including NFPA 101 Life Safety Code, the Architectural Barriers Act Accessibility Standards, and The Joint Commission accreditation. Technical requirements include specific design narratives, a detailed room data matrix, and Facility Security Level II standards. Environmental compliance is mandatory, requiring Two Green Globes certification and adherence to DOE energy performance regulations. Proposals must be submitted by September 28, 2026, and must include comprehensive technical, price, and socio-economic volumes, with specific emphasis on past performance and the qualifications of the design and construction teams.

Office Of Construction & Facilities Management (36C10F)

POSTED

DEADLINE

DMV - TULAREThe California Department of Motor Vehicles is seeking a lease extension for its existing facility located in Tulare, California, within the 93274 zip code. This procurement action is categorized as a forecast and specifically pertains to the continued use of the current space without the requirement for any tenant improvements. The process is being managed by Alissa Navarro, serving as the Leasing Analyst. Interested parties or those seeking further information can coordinate through the provided contact details or refer to the official project link via the CEQA Net portal.

California Motor Vehicles, Department of

POSTED

DEADLINE

OFFICE SPACE WANTED TO LEASE BY STATE OF CALIFORIA - Palmdale

Solicitation # 0000040346

The State of California, specifically the Department of Social Services, is seeking to lease approximately 5,653 usable square feet of office space in the City of Palmdale. The requirement includes a minimum of 25 parking spaces and mandates that the facility be asbestos-free upon occupancy. Properties must be located near public transportation and comply with all seismic safety standards, the Americans with Disabilities Act, the California Building Code, and Title 24 regulations. Interested vendors must adhere to Disabled Veteran Business Enterprise requirements and submit their proposals by the closing date of September 28, 2026, at 6:00 PM. For further inquiries or coordination, the primary contact is Boyce Whitlock. Potential bidders may be required to register on the State of California's official website to participate in this solicitation.

State of California

POSTED

DEADLINE

Lease Office Space, Commission Scolaire LS103415

Solicitation # EV9353

The Government of the Northwest Territories, through Procurement Shared Services, is seeking proposals for the provision of leased office space for Commission Scolaire under solicitation number EV9353. This federal-level procurement opportunity is managed by the Department of Infrastructure and is specifically for performance within the Northwest Territories. Interested parties must submit their responses by the deadline of October 14, 2026. Further documentation and addenda are available through the official procurement portals, and inquiries should be directed to the Contract Administrator via the provided contact information.

Government of the Northwest Territories

POSTED

DEADLINE

in about 1 month

Camp Mabry Portables

Solicitation # TMD27-CFMO-0046097

The Texas Military Department is soliciting competitive sealed bids for the lease, installation, and maintenance of two temporary modular workspace facilities at Camp Mabry in Austin, Texas. These turnkey, code-compliant facilities are required to accommodate 165 personnel, with 110 stationed at the North Site and 55 at the South Site. The project includes the supply and installation of modular units on existing foundations, interior fit-out, and the implementation of mechanical, electrical, plumbing, life safety, and IT/AV infrastructure. Both facilities must be fully installed and ready for occupancy by March 30, 2027. The contract is structured as an initial 36-month lease with two optional one-year renewals and an option for the agency to purchase the facilities. Prospective bidders must adhere to strict submission requirements, including attendance at one of three mandatory site visits in October 2026 and the submission of a mandatory space-fit configuration layout by October 13, 2026. Final bids are due by 11:30 AM CST on October 28, 2026. Award will be based on the lowest-priced responsive bid, with evaluation factors including total cost of ownership, compliance with specifications, delivery timeframe, and past vendor performance. The contract requires compliance with the Davis-Bacon Act for prevailing wages and includes a HUB goal of 21.1% for building construction. Performance and payment bonds are required if the bonded amounts exceed 100,000 dollars and 25,000 dollars, respectively.

Texas Military Department

POSTED

DEADLINE

in about 2 months

Event Host Space Rental (Franklin County)

1003 - MDAR Admininstration

POSTED

DEADLINE

FY27 MDAR RFR- Agricultural Resource Fair Host Location

Solicitation # BD-27-1002-1003-001-133366

The Massachusetts Department of Agricultural Resources is seeking an event host space in Franklin County to conduct a one-day Agricultural Resource Fair on March 5, 2027, with a backup date of March 12, 2027. The selected venue must be ADA compliant, located near major highways, and capable of accommodating approximately 200 attendees and staff. Required facilities include a main hall for 30 to 40 exhibitor tables with accompanying chairs, two to three breakout rooms for 25 to 50 people each, and necessary AV equipment such as projectors and sound systems. Additionally, the vendor must provide catering services for beverages and light snacks. This procurement is designated as a Small Procurement with an annual value under 250,000 dollars and is specifically set aside for the Small Business Purchasing Program and SDO certified businesses. Award decisions will be based on best value, evaluating price, experience, quality, and geographic location. Responses are due by September 28, 2026, and must include a facility description, a detailed price list, and confirmation of service capabilities. The contract period extends from the effective date through June 30, 2027, and requires adherence to the Commonwealth of Massachusetts Terms and Conditions and Executive Order 515 regarding environmentally preferable products.

1003 - MDAR Admininstration

POSTED

DEADLINE

More opportunities from Court Services And Offender Supervision Agency → Court Services Offender Supv Agcy

Same awarding agency

Specialized Transport of X-Ray EquipmentThis subcontract involves the specialized transport of sensitive electronic imaging and X-ray equipment for prime contractors supporting Court Services and Offender Supervision Agency security projects. The service requires hauling equipment from Edgewood, Maryland, to the agency office in Washington, D.C., utilizing air-ride suspension trucks and specialized loading and unloading equipment to ensure the safety of the electronics. The contractor must maintain strict DOT compliance and adhere to specialized handling standards for sensitive electronics throughout the delivery process. Operating under NAICS code 484220, the project focuses on the secure and safe delivery of high-value imaging technology to the designated facility in the 20002 zip code.

Specialized Freight (except Used Goods) Trucking, Local

POSTED

DEADLINE

X-Ray System Installation ServicesThis subcontract for X-Ray System Installation Services supports prime contractors on security projects for the Court Services and Offender Supervision Agency in Washington, D.C. The scope of work involves the physical installation and setup of mobile x-ray units, including unloading, positioning, assembly, and calibration using specialized rigging and imaging tools. The service provider must ensure all work adheres to radiation safety standards as well as local D.C. building and electrical codes. The primary objective is the delivery of a fully installed and operational x-ray system within the 20002 zip code area, falling under NAICS code 238210.

Electrical Contractors and Other Wiring Installation Contractors

POSTED

DEADLINE

HI-SCAN 5030C Mobile X-Ray System SupplyThis subcontract involves the manufacture and delivery of one proprietary HI-SCAN 5030C Mobile US Standard X-Ray System for the Court Services and Offender Supervision Agency. The equipment must meet all US Standard specifications for x-ray screening and will be supplied to prime contractors managing security projects for the agency. The project is categorized under NAICS code 334519 and is designated for performance in the 20002 zip code area. The primary objective is the delivery of a fully functional mobile x-ray unit to the CSOSA office to support their security infrastructure.

Other Measuring and Controlling Device Manufacturing

POSTED

DEADLINE

Notice of Intent to Sole Source for a HI-SCAN 5030C Mobile US Standard X-Ray System

Solicitation # 9594CS26Q0050

The Court Services and Offender Supervision Agency (CSOSA) intends to sole source the purchase and installation of one HI-SCAN 5030C Mobile US Standard X-Ray System along with a one-year iCMORE license and associated hardware from Smiths Detection, located in Edgewood, Maryland. This action is justified under FAR 13.106-1(b)(1)(i) because only one source is reasonably available and no other supplies or services will meet the agency’s requirements. The equipment will be installed at a CSOSA office in Washington, D.C., with an anticipated performance period of 13 months from the date of award. The agency plans to issue a firm-fixed-price Purchase Order under solicitation number 9594CS26Q0050, with no competitive solicitation being released. This notice is purely informational and does not constitute a request for bids or proposals. The contract is classified under NAICS code 334519, and the point of contact for inquiries is Ms. Valerie Wallace, who can be reached via email at valerie.wallace@csosa.gov or by phone at 202-585-7448. No set-aside provisions apply, and the government retains full discretion in determining whether to proceed with the sole source award based on this notice.

Other Measuring and Controlling Device Manufacturing

POSTED

DEADLINE

Psychotherapy Group ServicesThe Court Services and Offender Supervision Agency (CSOSA) is seeking a contractor to provide facilitated group and individual psychotherapy sessions for residents at its Re-Entry and Sanction Center. The services will include both on-site and virtual therapy sessions, each lasting a minimum of 60 minutes, available Monday through Friday between 9:00 am and 9:00 pm. The current contract, held by WALLER PSYCHOTHERAPY, LLC, has a firm fixed price value of $194,688 and is expected to end on March 30, 2027. The procurement is a total small business set-aside under NAICS code 621330 and was competed under the Simplified Acquisition Procedures (SAP). This anticipated recompete opportunity has a medium confidence level of 40 out of 100 indicating likelihood of continuation. The services aim to support offender rehabilitation through consistent therapeutic interventions. Points of contact for this procurement include Lawrence Durden and Elijah Anderson of CSOSA, located in Washington, DC. Specific details and requirements can be found in the attached statement of work, although the solicitation number has not yet been posted.

Offices of Mental Health Practitioners (except Physicians)

POSTED

DEADLINE

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Join 650+ contractors already using CLEATUS