This Solicitation opportunity from Florida was posted on December 29, 2025. The submission period has ended. Browse the details below for market research, or find similar active opportunities.

Top

Resurfacing of City Streets

Closed

IFB26-0134State & Local

Submission Closed01/30/2026, 07:00:45 PM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

Active Opportunities Like This One

NAICS: 237310

New

Terrace Drive Sewer System Improvements, Chimney Rock

Solicitation # terrace-drive-sewer-system-improvements-chimney-rock

This solicitation, issued by Payne, McGinn and Cummins, Inc., is for the Terrace Drive Sewer System Improvements project located in Chimney Rock, North Carolina. The scope of work specifically involves the asphalt milling and overlay of 5,200 square yards. The opportunity is set aside for small businesses, including certified Veteran Owned, Service-Disabled Veteran Owned, Women-Owned, and HUBZone small businesses. Interested parties must submit their responses by the deadline of December 1, 2026. Primary inquiries regarding this project should be directed to Robert M. McGinn, Jr.

Payne, McGinn and Cummins, Inc.

POSTED

DEADLINE

CONSTRUCTION ON STATE HIGHWAY IN LOS ANGELES COUNTY IN SANTA CLARITA BETWEEN PLACERITA CANYON ROAD AND SAND CANYON ROAD

Solicitation # construction-state-highway-los-angeles-county-santa-clarita-between-placerita-canyon-road-sand

Caltrans is seeking bids for a highway construction project located in Santa Clarita, Los Angeles County, specifically spanning the area between Placerita Canyon Road and Sand Canyon Road. Identified by contract number 07-375204, this solicitation falls under NAICS code 237310 for highway, street, and bridge construction. The opportunity is designated as a set-aside for small businesses. Interested parties must submit their responses by the deadline of November 3, 2026. Primary coordination for this project is managed through Bob Swanek at Chumo Construction.

POSTED

DEADLINE

North Hollywood Central Remediation Well Collector Line; IFB No. 8003R1

Solicitation # 8003R1

Kiewit Infrastructure West Co. is soliciting sub-quotes for the North Hollywood Central Remediation Well Collector Line project, an initiative for the City of Los Angeles Department of Water and Power located in California. The comprehensive scope of work includes underground utilities such as tunneling, boring, jacking, and micro tunneling, as well as site work involving land surveying, site clearing, shoring, and subsurface investigation. Additional requirements encompass surface improvements like asphalt paving, landscaping, and the installation of traffic signs, signals, and lighting, along with environmental support services including storm water pollution prevention. Required materials include ready mix supply, precast concrete, and aggregate. This solicitation is open to qualified Small Business, Women-Owned Small Business, and Disadvantaged Business Enterprise subcontractors and suppliers. To be considered, responsive bidders must possess a valid California Contractor's license, provide acceptable insurance, and be capable of providing bonding for 100 percent of their contract value, with bond premiums reimbursed by Kiewit. Bidders must also demonstrate an ability to maintain labor harmony on the project. Interested firms must be issued an Invitation to Bid through the Building Connected electronic system, with a response deadline of November 18, 2025. Primary contact for this effort is Lead Estimator Ken Johnston.

Kiewit Infrastructure West Co.

POSTED

DEADLINE

ND NP THRO 204(1) Buck Hill Road - Solicitation #6982AF25B000004

Solicitation # nd-np-thro-2041-buck-hill-road-solicitation-6982af25b000004

Steve Manning Construction, Inc. is seeking quotes from qualified subcontractors and suppliers for the Buck Hill Road project in North Dakota, identified by solicitation number 6982AF25B000004. The opportunity is open to various small business designations, including SB, SDB, HUBZone, WOSB, VOSB, and SDVOSB firms. Interested parties must submit their responses by November 3, 2026. The scope of work is extensive, covering comprehensive roadway and drainage improvements. Key requirements include survey and staking, soil erosion control, and the removal of existing infrastructure such as bollards, catch basins, and guardrails. Construction tasks involve full depth reclamation, asphalt and concrete pavement installation, the placement of riprap and revetment mats, and the installation of new curb, gutter, and sidewalk systems. Additionally, the project requires specialized services such as paleontologist monitoring, hydraulic seeding, and the installation of traffic control systems and signage.

Steve Manning Construction Inc.

POSTED

DEADLINE

BRIDGES ON DELICATE ARCH ROAD - UT NP ARCH 100(2)

Solicitation # bridges-delicate-arch-road-ut-np-arch-1002

This solicitation, titled Bridges on Delicate Arch Road - UT NP Arch 100(2), involves a comprehensive infrastructure project in Utah. The scope of work includes bridge construction, drainage installation, pavement work, roadway realignment, rehabilitation, widening, asphalt surfacing, and various safety improvements. The primary project area under Schedule A covers 0.99 miles and two parking lots, with additional optional components including Option X for 0.35 miles and Option Y for one parking lot. Managed by WW Clyde, this opportunity is set aside for small businesses, including SDVOSB, WOSB, HUBZone SB, and SDB designations under NAICS code 237310. The solicitation was posted on October 27, 2026, with a response deadline of November 6, 2026. Interested parties may contact Chanel Hope for further information regarding this construction project.

POSTED

DEADLINE

IEUA - Regional Water Recycling Plant No. 5 (RP-5) Offsite Facilities Project NO. EN19001.03

Solicitation # ieua-regional-water-recycling-plant-no-5-rp-5-offsite-facilities-project-no-en1900103

POSTED

DEADLINE

On-Call And Emergency, Repair, Maintenance, Replacement, And Installation Services For Various Public Infrastructure Facilities

Solicitation # 20261027013

POSTED

DEADLINE

Traffic Signal Head Improvements

Solicitation # 20261027011

POSTED

DEADLINE

Church Street And San Bernardino Avenue Traffic Signal Installation

Solicitation # 20261027010

POSTED

DEADLINE

Requirements Contract To Furnish & Install Concrete And Paving Repairs At The Regional Wastewater Reclamation Facility

Solicitation # 20261027008

POSTED

DEADLINE

Traffic Control and Maintenance of Traffic (MOT)

Texas Department of Transportation

POSTED

DEADLINE

Bridge Structural Concrete Repair

Texas Department of Transportation

POSTED

about 7 hours ago

DEADLINE

in 23 days

AI Contract Overview

The City of Orlando is soliciting sealed electronic proposals for the resurfacing of city streets under solicitation number IFB26-0134. Interested respondents must submit their complete proposals via the OpenGov platform by 2:00 pm local time on January 30, 2026, to be considered for contract award. It is the responsibility of respondents to ensure timely and accurate submission because the city will not be liable for any delays or failures in submission. Respondents are expected to thoroughly review the solicitation, specifications, drawings, and all related instructions before submitting their proposals, as failure to do so may jeopardize their eligibility. This project is managed by the Streets and Stormwater agency of Florida, with performance expected within the state. For any questions or clarifications, primary contact is Austin Cowne, Paving Plan Engineer, reachable via email or phone, with a secondary contact available in the Senior Purchasing Agent, Silvia Coste. All required information must be furnished accurately on the submission forms and any accompanying documents as part of the proposal package. Further details and submission instructions can be accessed through the City's OpenGov procurement portal.

General Info

City of Orlando seeks electronic proposals for street resurfacing, deadline January 30, 2026, via OpenGov.

Agency

Florida → Streets and Stormwater

NAICS

237310 - Highway, Street, and Bridge Construction

Place of Performance

FL, USA

Set-Aside

NONE

Documents

IFB26-0134 Resurfacing of City Streets

8 pages · ifb

High

IFB26-0134 Resurfacing of City Streets

8 pages · ifb

High

IFB26-0134 Resurfacing of City Streets

114 pages · ifb

High

AI Contract Breakdown

Uniform Contract Format

Timeline

PhaseClosed

PostedDec 29

Solicitation

Response DeadlineJan 30

Deadline has passed

Submission Closed

01/30/2026, 07:00:45 PM UTC

Find active opportunities like this

Start your free trial to discover similar active contracts, track opportunities, and build proposals with AI assistance.

Organization & Contact Information

AgencyFlorida → Streets and Stormwater

Contacts2 people available

OfficeOrlando, FL, 32801, USA

Organization / AgencyFlorida → Streets and Stormwater

Office AddressOrlando, FL, 32801, USA

Contacts

Austin CownePaving Plan Engineer

contact@example.gov

+1 (555) 000-0000

Silvia CosteSenior Purchasing Agent

contact@example.gov

+1 (555) 000-0000

Interested Companies (36)

Hubbard ConstructionWinter Park, FL

T & L PatchingApopka, FL

Lincoln Surety GroupSarasotat, FL

See All 36 Interested Companies

Start a free trial to view all interested companies, their contact details, and full contractor profiles.

Start Free Trial

Full Description

Notice is hereby given that City of Orlando is accepting sealed responses for Project ID Project Title and they must be submitted electronically by 2:00 pm local time on Proposal Submission Date , in order for a Respondent to be considered for award of a contract. Respondents are solely responsible for ensuring that their submittals are complete, uploaded, and submitted electronically via OpenGov by the due date and time. The City shall not be responsible for any submission delays or failures caused by any occurrence. Respondents are expected to examine this solicitation, specifications, associated drawings, if any, and all instructions. Failure to do so will be at the Respondent's risk. Each Respondent shall furnish the information required on each submittal form and each accompanying sheet thereof on which an entry is made.