This Government Contract opportunity from Georgia was posted on May 21, 2026. The submission period has ended. Browse the details below for market research, or find similar active opportunities.

Top

Roof Repair and Replacement

Closed

State & Local

Submission Closed06/23/2026, 07:00:00 PM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

Active Opportunities Like This One

NAICS: 238160

New

AMC-0191 BFM TOWB Public Announcement

Solicitation # amc-0191-bfm-towb-public-announcement

This solicitation, issued by PTSI Managed Services Inc. (Parsons), involves a comprehensive facility renovation project located in Alabama. The scope of work includes a full PVC roof replacement, electrical work, and the installation and repair of building grounding systems. Additionally, the project covers miscellaneous door repairs and replacements, drywall repairs, floor tile replacements, and plumbing updates. The estimated magnitude of construction for these improvements is valued between 1,000,000 and 5,000,000 dollars. The opportunity is designated as an SBA set-aside, welcoming bids from Small Businesses, including Small Disadvantaged, Women-Owned, HUBZone, and Veteran-Owned Small Businesses. Interested parties must respond by October 19, 2026. The project falls under NAICS code 238160, and inquiries can be directed to the primary point of contact, Kurtis Kinard.

PTSI Managed Services Inc. (Parsons)

POSTED

DEADLINE

Columbus State Community College in Ohio is seeking proposals for the Nestor Hall Roof and Exterior Metal Wall Improvements project under solicitation number 49338. This SLED organization project falls under NAICS code 238160, focusing on roofing and exterior wall enhancements at the specified facility located in Ohio. The solicitation was posted on October 13, 2026, and requires all responses to be submitted by the deadline of October 29, 2026, at 5:30 PM. Interested parties can find further details and submission guidelines through the provided Bid Express link.

Columbus State Community College

POSTED

DEADLINE

Roofing Material Supply

Gwinnett County Public Schools

POSTED

DEADLINE

Commercial Roofing Installation

Gwinnett County Public Schools

POSTED

DEADLINE

Walnut Grove ES, Central Gwinnett HS, Collins Hill HS & North Gwinnett HS - Roof Replacement

Solicitation # PE-77021-NONST-2027-000000221

The Gwinnett County Board of Education is soliciting sealed bids for a stipulated sum contract to perform re-roofing services at four facilities: Walnut Grove Elementary (Bldg 2011), Central Gwinnett High (Bldg 5041), Collins Hill High (Bldg 5011), and North Gwinnett High (Bldg 5080). Bids must be submitted by 3:00 PM on November 12, 2026, to the Board of Education office in Lawrenceville, Georgia. Electronic submissions via email or fax are strictly prohibited. To be eligible for bidding documents, contractors must be licensed in the State of Georgia and submit a completed AIA Document A305 Qualification Statement to the project architect, Hussey Gay Bell, to demonstrate their ability to handle projects of similar scope and complexity. The project is scheduled to begin on May 27, 2027, with a requirement for the contractor to mobilize within ten days of the written Notice to Proceed. All work must reach substantial completion by July 23, 2027. Bidders are required to provide a bid bond equal to five percent of the base bid, while the successful awardee must provide performance and labor and material payment bonds equal to 100 percent of the contract sum. Payments will be issued upon receipt of requests approved by the architect, with retainage withheld as specified in the general conditions. Bids remain valid for sixty days following the opening date.

Gwinnett County Public Schools

POSTED

DEADLINE

Leadwork and Rainwater Goods Installation

Powys Teaching Health Board

POSTED

DEADLINE

Alumasc Flat Roofing Installation

Powys Teaching Health Board

POSTED

DEADLINE

POW-ITT-64317 FLAT ROOF FOR MONNOW WARD, BRONLLYS COMMUNITY HOSPITAL

Solicitation # POW-ITT-64317

Powys Teaching Health Board is seeking a contractor for the replacement of the flat roof covering over Monnow Ward at Bronllys Community Hospital in Brecon under solicitation POW-ITT-64317. The project involves the removal and disposal of a deteriorated roof deck and waterproofing system, followed by necessary structural and timber repairs. The contractor will install a complete warranted Alumasc flat roofing system, including insulation, membranes, trims, and accessories, while also performing lead repairs, replacing affected fascia and soffit boards, and managing rainwater goods. The estimated contract value is 90,000 GBP excluding VAT, with a performance period estimated from December 1, 2026, to March 31, 2027. The contract will be administered under the JCT Minor Works Building Contract with Contractor’s Design, 2024 Edition. Award criteria are weighted at 60 percent for commercial price and 40 percent for technical quality. The successful contractor is responsible for ensuring safe access, edge protection, and structural loading capacity, and must maintain the building as weather-tight throughout the duration of the works. Tenders must be submitted electronically by November 9, 2026, at 12:00 pm.

Powys Teaching Health Board

POSTED

DEADLINE

Roofing and Building EnvelopeThis subcontract opportunity involves the supply and installation of a facility roofing system for prime contractors working on USACE Air Force projects located at Dyess AFB. The scope of work requires the installation of a comprehensive metal roof, including all necessary panels and flashing, to deliver a fully completed and watertight building envelope. Managed by the Department of Defense under the W076 Endist Ft Worth agency, the project falls under NAICS code 238160. The solicitation was posted on October 13, 2026, with a response deadline set for October 30, 2026.

POSTED

DEADLINE

Z--SLV-CB PUMPING PLANT ROOF

Solicitation # 140R4026Q0141

The Bureau of Reclamation, under the Upper Colorado Region of the Department of the Interior, is seeking competitive quotations for the repair or replacement of the flat roof at the San Luis Lakes Pumping Plant Building located near Mosca, Colorado. This acquisition, identified by solicitation number 140R4026Q0141, is classified as a total small business set-aside under NAICS code 238160 for roofing contractors and falls under FAR Part 12 as a commercial construction contract. The work involves addressing leaks, membrane and structural defects, drainage issues, and other building envelope concerns to restore full weather protection and ensure long-term facility reliability, with the contractor responsible for all labor, materials, equipment, and demolition. The solicitation is not posted on SAM, but offerors must maintain an active SAM.gov registration to be eligible for award. Technical capability, past performance, and price will be evaluated to determine best value, with award anticipated to occur within a 90-day performance period following selection. Questions regarding the requirement must be submitted to Ronda Lucero at ronda_lucero@ios.doi.gov no later than August 14, 2026, and quotes are due by August 21, 2026. A site visit will be scheduled to provide additional technical context necessary for proposal development. The contract is not subject to public posting on SAM, and all submissions will be reviewed under a competitive process as required by FAR and DOI policies. Information on the scope is detailed in the attached Statement of Work, and any modifications to the contract must be made by mutual written agreement. The place of performance is in Colorado, while the contracting office is located in Salt Lake City, Utah. Free trade agreements may apply to certain items under this acquisition, and only responsible sources are invited to respond.

Upper Colorado Regional Office

POSTED

DEADLINE

Solicitation # 12441926Q0048

Solicitation 12441926Q0048 is a sealed bid invitation for a total small business set-aside project to replace the roof of building PRD B290 at the Pine Ridge Job Corps Civilian Conservation Center in Chadron, Nebraska. The scope of work involves removing existing gutter systems and installing an insulated PVC membrane roof assembly with polyisocyanate insulation, including necessary flashing and vent extensions. The project requires adherence to ICC and NFPA codes, the use of Energy Star roofing products, and the provision of a 20-year No Dollar Limit warranty. The contract is a lump sum award with a performance period of 90 days after the Notice to Proceed. Award will be based on the Lowest Price Technically Acceptable (LPTA) criteria, evaluating the project schedule, demonstrated prior experience, and price. Offerors must provide a bid guarantee of 20 percent of the contract value, not to exceed 3 million dollars, and must submit payment and performance bonds for the full contract amount within 10 days of award. Bids are due by October 20, 2026, at 1700 EST. The project is subject to the Davis-Bacon Act, requiring prevailing wage rates for construction trades in Nebraska.

USDA Forest Service-Spoc East

POSTED

DEADLINE

Residential Roofing Replacement

Choctaw Nation Housing Authority

POSTED

1 day ago

DEADLINE

in 6 days

AI Contract Overview

This contract involves repairing or replacing damaged sections of the courthouse roofing, which includes work on the underlayment, flashing, and the final roofing material. The project is classified under NAICS code 238160, indicating it is related to roofing contractors. The contract is a subcontract opportunity posted by the Walker County Board of Commissioners in Georgia, with a response deadline set for June 23, 2026. The scope of work requires addressing multiple roofing components to ensure the courthouse roof is restored or replaced properly, emphasizing durability and weatherproofing. While specific details about the place of performance or point of contact are not provided, interested parties can find more information through the linked portal. The contract aims to maintain the structural integrity and appearance of the courthouse, ensuring that the roofing system meets required standards.

General Info

Subcontract for courthouse roof repair or replacement, including underlayment and flashing, due June 23, 2026.

Agency

Georgia → Walker County Board of Commissioners

NAICS

238160 - Roofing Contractors

Place of Performance

GA, USA

Set-Aside

NONE

Documents

This scope was carved out of 2026-010.

The full solicitation package (2 documents), including the RFP, is on the prime solicitation, not on this scope.

View the prime solicitation

2026-10 Walker County Courthouse Attic Remediation and Roof Repair

AI Contract Breakdown

Uniform Contract Format

No documents to break down

The breakdown needs solicitation documents. None were found from this contract's source.

Timeline

PhaseClosed

PostedMay 21

subcontract

Response DeadlineJun 23

Deadline has passed

Submission Closed

06/23/2026, 07:00:00 PM UTC

Find active opportunities like this

Start your free trial to discover similar active contracts, track opportunities, and build proposals with AI assistance.

Organization & Contact Information

AgencyGeorgia → Walker County Board of Commissioners

ContactsNo contacts available

OfficeN/A

Organization / AgencyGeorgia → Walker County Board of Commissioners

Office AddressN/A

ContactsNo contact information available

Full Description

Repair or replace damaged roofing sections, including underlayment, flashing, and final roofing material installation on the courthouse.

Find Active Opportunities Like This

Get AI-powered intelligence on the opportunities still open

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Join 750+ contractors already using CLEATUS