Skip to main contentPsst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveFree Webinar — Wednesday, November 11 at 2:00 PM ET

Register Free →

This Government Contract opportunity from Department Of Defense was posted on December 13, 2010. The submission period has ended. Browse the details below for market research, or find similar active opportunities.

Z--Webbers Falls Generator Rewind

Awarded
W9127S10R0053Federal

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

Active Opportunities Like This One

NAICS: 237990
New
International
2383 Emerson Street - Modular Pump Track - Design-Build Services
Solicitation # RFP 1220-2026-4364
The City of Abbotsford has issued Request for Proposals RFP 1220-2026-4364 for design-build services to create a complete, safe, durable, and fully operational modular pump track facility at 2383 Emerson Street. The project follows a stipulated price contract based on the CCDC 14-2013 Design-Build Agreement. The selected Design-Builder will be responsible for all professional design and engineering services, including the preparation of sealed plans, as well as the provision of all labor, materials, modular pump track units, and site furnishings. Additionally, the contractor must obtain all necessary permits, licenses, and certificates of inspection required by federal, provincial, and local authorities. A mandatory site visit is scheduled for November 9, 2026, at 10:00 AM local time, and attendance is required for proposal submission. The deadline for responses is November 24, 2026, at 10:00 PM. Project acceptance is contingent upon the Consultant and Owner's satisfaction regarding the rectification of deficient work, completion of landscaping and clean-up, and the facility reaching full operational readiness. Payments will be processed via progress payment approvals issued by the City Representative. All work must adhere to the rules and customs of best trade practice and meet the requirements of all governing jurisdictions.
City of Abbotsford

POSTED

1 day ago

DEADLINE

in 24 days

AI Contract Overview

Show more

The Little Rock District Corps of Engineers has issued a firm fixed-price contract for the generator rewind project at the Webbers Falls Power Plant in Oklahoma. The scope of work involves the design, manufacture, delivery, and installation of three complete sets of stator coils and accessories. The selected contractor is responsible for the full disassembly of three generator units, including the rotor, air housing, and exciter equipment, followed by the removal of old coils and the installation and testing of new stator windings. Additional requirements include providing spare parts, reassembling the generators, and conducting comprehensive field tests. The contractor must provide an on-site manufacturer representative to supervise installation and manage start-up and commissioning. All activities must adhere to strict site operations, environmental protection, and safety standards, utilizing skilled labor for painting, welding, machining, and electrical work. This unrestricted acquisition falls under NAICS code 237990.

General Info

Contract Value

$6,051,849.28

NAICS

237990 - Other Heavy and Civil Engineering Construction

Place of Performance

AR, USA

Set-Aside

NONE

Award Issued Date

Documents

0

No documents available

Documents will appear here when they are available.

AI Contract Breakdown

Uniform Contract Format

No documents to break down

The breakdown needs solicitation documents. None were found from this contract's source.

Timeline

7 updates
PhaseAwarded
Posted

Sources Sought

Type Changed

Sources Sought → Presolicitation

Type Changed

Presolicitation → Sources Sought

Notice updated

Notice details unchanged. Attachments may have changed.

Deadline changed

Response deadline changed from Aug 24, 2010 to Sep 8, 2010.

Notice updated

Notice details unchanged. Attachments may have changed.

Deadline changed

Response deadline changed from Sep 8, 2010 to Sep 13, 2010.

Notice updated

Notice details unchanged. Attachments may have changed.

Deadline changed

Response deadline changed from Sep 13, 2010 to Sep 20, 2010.

Notice updated

Notice details unchanged. Attachments may have changed.

Awarded

Contract was awarded

Submission Closed

Find active opportunities like this

Get full access to discover similar active contracts, track opportunities, and build proposals with AI assistance.

Organization & Contact Information

Show more
AgencyDepartment Of Defense → W076 Endist Little Rock
ContactsNo contacts available
OfficeLITTLE ROCK, AR, 72201-3225, USA
Office AddressLITTLE ROCK, AR, 72201-3225, USA
ContactsNo contact information available

Full Description

Show more
The Little Rock District Corps of Engineers Contracting Division has a requirement for the following work at Webbers Falls Power Plant: 1. Design, manufacture, shop test prepare and load for shipment, deliver f.o.b. destination, and unload three complete set of stator coils and specified accessories. 2. Disassemble three generator units, including the exciter equipment, air housing, and rotor. 3. Remove old stator coils. 4. Install and test three new stator windings and accessories specified herein. 5. Furnish spare parts. 6. Reassemble generators, install, and perform field test. 7. Furnish manufacturers representative on-site services to supervise the installation of the generator stator coils and to perform start-up, commissioning, and testing of three generators. 8. Perform all work required complying with the site operations, environmental protection, and safety and health provisions as specified. 9. Perform all work required for painting, miscellaneous welding, machinist, electrician and other skilled craftsman hire. Place of performance is Webbers Falls Power Plant, Webbers Falls, OK. The type of contract is firm fixed-price. The North American Industry Classification System (NAICS) code for this project is 237990, and the acquisition was solicited Unrestricted. The Contract Specialist for this solicitation was contact@example.gov.

More opportunities from Department Of Defense → W076 Endist Little Rock

Same awarding agency

NAICS: 236220
New
Federal
Department of Veteran Affairs - Personnel Security Adjudication Center
Solicitation # W9127S27RA008
The Department of Veteran Affairs, through the U.S. Army Corps of Engineers District Little Rock, is soliciting bids for the turnkey design-build construction of the Personnel Security Adjudication Center (PSAC) at the Eugene J. Towbin VA Healthcare Center campus in North Little Rock, Arkansas. The project involves the creation of a two-story, 10,000 square foot facility designed to accommodate approximately 75 full-time equivalents, including a parking lot with a minimum capacity for 25 vehicles. A contingent option exists for the installation of a physical security fence featuring automated gate access and controls. A critical requirement of the project is achieving ICD 705 accreditation for secured construction areas, which necessitates stringent personnel vetting and compliance with classified information nondisclosure agreements. This is a total small business set-aside contract with a performance completion date of December 31, 2029. Award will be determined using a best value tradeoff methodology, where technical approach is the most important factor, followed by the proposed contract summary schedule, with combined non-price factors outweighing price. Bidders must provide performance and payment bonds and adhere to Davis-Bacon Act prevailing wage requirements. Proposals are submitted through a two-phase selection process, requiring detailed documentation on past performance, execution approach, and management teams. Invoicing and payment will be processed electronically via Wide Area WorkFlow.
Commercial and Institutional Building Construction

POSTED

3 days ago

DEADLINE

in 18 days
View Details
NAICS: 561720
Federal
Janitorial Services, DeQueen Project Office
Solicitation # W9127S27QA004
Solicitation W9127S27QA004 is a request for quotation issued by the US Army Corps of Engineers, Little Rock District, for non-personal janitorial cleaning services at the DeQueen Project Office in DeQueen, Arkansas. This procurement is a 100 percent Small Business Set-Aside under NAICS code 561720. The scope of work includes providing all personnel, equipment, and supplies necessary to maintain several adjacent buildings, including a public customer service lobby and a vehicle compound. The contract structure consists of a base period running from the date of award through October 31, 2027, with two subsequent 12-month option years. Award will be determined based on price only, and offerors must maintain an active SAM registration to be eligible. The contractor is required to provide a designated Contract Manager and a work leader, both of whom must be fluent in English. Performance will be monitored by the Contracting Officer's Representative through a Quality Assurance Surveillance Plan, and the contractor must implement a formal quality control plan and adhere to EM 385-1-1 and OSHA safety standards. All cleaning chemicals used must be appropriately labeled with Safety Data Sheets provided within two weeks of award. Quotes must be submitted in PDF format to the designated point of contact by November 4, 2026, at 10:00 AM CST.
Janitorial Services

POSTED

9 days ago

DEADLINE

in 3 days
View Details

Earlier notices in this NAICS code

Posted before this notice, open and closed

Find Active Opportunities Like This

Get AI-powered intelligence on the opportunities still open

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Miguel
Hillary
Keith Deutsch
Christine

Join 750+ contractors already using CLEATUS