Avionics components for Ocean Sentry Refresh

This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Federal Acquisition Regulation (FAR) Subpart 12.6 and 13.5, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotes are being requested and a written solicitation will not be issued. This Request for Quote (RFQ), HSCG38-17-Q-010028 incorporates provisions and clauses in effect through Federal Acquisition Circular 2005-95. This requirement is unrestricted. All responsible sources may submit a capability statement and a quotation, which shall be considered by the agency. The applicable North American Industry Classification Standard (NAICS) Code is 334511. The small business size standard is 1,250 employees. The USCG intends to award a firm fixed price purchase order to the Original Equipment Manufacturer (OEM) Rockwell Collins (Cage Code: 13499), 400 Collins Road NE, Cedar Rapids, IA 52498 and/or distributors than can provide traceability. Traceability means that the awardees must be able to show clear, documented, auditable paper trail for ownership and transfer of each part from the OEM to the final vendor. This requirement will be satisfied using commercial acquisition procedures specified in FAR parts 12.6 and 13.6. Schedule of Supplies The USCG requires firm fixed pricing for the brand name procurement of Rockwell Collins avionics equipment required for the avionics system upgrade of the Ocean Sentry Refresh (HC-144B). A detailed CLIN structure, "Schedule of Supplies" is provided at the end of this solicitation. Offerors shall use this format for the priced portion of the quotation. Only new items are acceptable. Reconditioned or used items are not acceptable. Drawings or specifications are not available and cannot be furnished by the Government. Vendors having the specifications, drawings, and certifications to provide these items are invited to submit complete information discussing the same within ten (10) calendar days from this posting. The information submitted must include a letter from the OEM verifying the Offeror is an authorized distributor and verifying the OEM will provide proprietary data. This solicitation will not be extended or the award delayed for a vendor to submit capability determination data. Requested delivery schedule varies by part and is specified on the Schedule of Supplies. Partial and early deliveries are acceptable if at no additional cost to the USCG. All requests for delivery schedule extension shall be in writing and shall include substantiation of the need for such extension in accordance with FAR 52.212-4 (f), Excusable delays. If nonperformance is not covered by an excusable delay, the Contractor and the Contracting Officer shall negotiate consideration for the approval of the extended delivery date at which time a modification will be issued to reflect the consideration and extension. F.O.B. Destination is requested as the F.O.B. point for Deliverables. Quotes submitted offering F.O.B. Origin should include estimated shipping charges to the USCG. Packaging, Marking and Preservation The offeror shall comply with ASTM D3951-10, Standard Practice for Commercial Packaging. Packaging, packing, and preservation shall be in accordance with best commercial practices to enable shipment to destination and transshipment to USCG units without repackaging or incurring damage during shipment and handling. Items shall be individually packaged and labeled. Packaging material shall not consist of the following: popcorn, shredded paper, Styrofoam of any type, or peanut packaging. The internal packaging material shall be sufficient to prevent damage during shipment, handling, and storage. Preservation protection must be sufficient to prevent corrosion, deterioration, or decay during warehouse storage. Packing Slip At the time of delivery of supplies, the offeror shall furnish the Government a completed packing slip. Labeling shall include the National Stock Number, Part Number, Serial Number, Nomenclature, Quantity, Contract Line Item Number, and Contract Number. Labeling data shall be attached to the outside of the shipping container. Bar coding is not required. FAA 8130-3, EASA-1 form or COC shall be attached to or included with the part and a copy placed on the outside of the shipping container. Shipping Instructions Items shall be shipped to the following address: USCG Aviation Logistics Center Receiving Section, Bldg. 63 Elizabeth City, NC 27909-5001 Mark For: Purchase Order No. ____________________________ (To be assigned at time of award) The following Federal Acquisition Regulation (FAR) and Homeland Security Acquisition Regulation (HSAR) provisions and clauses are incorporated by reference: 52.212-1 Instructions to Offerors - Commercial Items (Jan 2017) Consistent with FAR Provision 52.212-1: (c) Period for acceptance of offers. Prices must remain effective for 120 days after closing of solicitation. Additional Addenda: Quotes shall be submitted on company letterhead and include the following information: - Solicitation Number; - Contractor's name, address, telephone, and DUNS; - Terms of standard commercial warranty and any extended warranty offered; - Delivery terms if different that the Government's desired delivery; - Remit to address if different than the company mailing address; - Agreement with the terms and conditions specified herein. (End of Provision) 52.252-1 Solicitation Provisions Incorporated by Reference (Feb 1998) This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address https://www.acquisition.gov/far. (End of Provision) 52.204-16 Commercial and Government Entity Code Reporting (Jul 2016) 52.247-45 F.O.B. Origin and/or F.O.B. Destination Evaluation (Apr 1984) 52.209-7 Information Regarding Responsibility Matters (Jul 2013) (a) Definitions. As used in this provision- "Administrative proceeding" means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables. "Federal contracts and grants with total value greater than $10,000,000" means- (1) The total value of all current, active contracts and grants, including all priced options; and (2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules). "Principal" means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions). (b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000. (c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information: (1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions: (i) In a criminal proceeding, a conviction. (ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more. (iii) In an administrative proceeding, a finding of fault and liability that results in- (A) The payment of a monetary fine or penalty of $5,000 or more; or (B) The payment of a reimbursement, restitution, or damages in excess of $100,000. (iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision. (2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence. (d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7). (End of Provision) 52.215-20 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data (Oct 2010) ALT IV (Oct 2010) (a) Submission of Cost or Pricing data is not required. (b) The offeror shall submit, at minimum, information on prices at which the same item or similar items have previously been sold in the commercial market that is adequate for evaluating the reasonableness of the price for this acquisition. (End of Provision) 52.233-2 Service of Protest (Sep 2006) (a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from: USCG Aviation Logistics Center MRS, Attn: David Tanner 1664 Weeksville Road Elizabeth City, NC 27909-5001 (b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO. (End of Provision) Evaluation - Commercial Items The provision at FAR 52.212-2 Evaluation of Commercial Items is not applicable to this solicitation. In lieu of this provision, quotes will be evaluated in accordance with FAR 13.106-2 based on the criteria listed below. Evaluation Method Quotes will be evaluated utilizing the Lowest Price Technically Acceptable (LPTA) selection process to achieve the best value for the Government. Only the lowest priced offer will be evaluated for Technical Acceptability. Should the lowest priced offer not receive an acceptable technical or past performance rating, the process will continue in order of lowest priced offer until the lowest priced, technically acceptable offer with acceptable or neutral past performance is identified. Evaluation Criteria - Price: The Offeror's quote will be evaluated using the techniques defined in FAR 13.106-3, in order to determine if it is fair and reasonable. - Technical Acceptability: Technically Acceptable quotes will be evaluated by the following pass/fail criteria: 1. The ability of the offeror to provide new manufactured commercial items from sources able to provide a FAA 8130-3 or equivalent European Aviation Safety Agency (EASA-1) Certification, a Certificate of Conformance (COC), and verification of being an authorized OEM distributor. All offerors will need to provide in writing with their quote a validation that they are able to provide the required technical acceptability certificates upon delivery of the parts on the schedule. 2. Vendor must provide exact part numbers with no substitutions. 3. Vendor is registered and current within the System for Award Management (www.SAM.gov). - Past Performance: Past performance will be evaluated as pass, fail or neutral: The Government may use information available from previous USCG contracts or purchase orders and information from the Federal Government Past Performance Information Retrieval System (PPIRS). In the case of an offeror without a record of relevant past performance or for whom information on past performance is not available, the offeror will be given a neutral past performance rating. 52.212-3 Offeror Representations and Certifications - Commercial Items (Jan 2017) ALT I (Oct 2014) The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) website accessed through http://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision. (End of Provision) 52.252-2 Clauses Incorporated by Reference (Feb 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address https://www.acquisition.gov/far. 52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights (Apr 2014)(DHS - USCG Deviation 14-01) 52.225-8 Duty Free Entry (Oct 2010) 52.232-40 Providing Accelerated Payment to Small Business Subcontractors (Dec 2013) 52.242-13 Bankruptcy (Jul 1995) 52.246-15 Certificate of Conformance (Apr 1984) 52.252-6 Authorized Deviations in Clauses (Apr 1984) (a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause. (b) The use in this solicitation or contract of any Homeland Security Acquisition Regulation (48 CFR 30) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation. (End of Clause) 52.212-4 Commercial Terms and Conditions - Commercial Items (Jan 2017) with the following included by Addendum: (a) Inspection/Acceptance. Inspection of items under this contract shall be performed at destination by USCG, Aviation Logistics Center (ALC) Quality Assurance. Acceptance of items provided on this contract shall be by Certificate of Conformance (COC). FAA 8130-3, EASA-1 form, or COC shall be attached to the outside of the shipping container. (g) Invoice. The original contractor invoice shall be submitted to the designated billing office address stated below or emailed to the email address below. Submitting invoices for payment electronically is the preferred method. ALC-Fiscal@uscg.mil USCG, Aviation Logistics Center Fiscal Branch, Bldg. 63 Elizabeth City, NC 27909-5001 Mark For: Purchase Order No. ____________________________ (To be assigned at time of award) 52.212-5 Contract Terms and Conditions Required to Implement Statutes or Executive Orders-Commercial Items (Jan 2017) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015) (3) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553). (4) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77, 108-78 (19 U.S.C. 3805 note)). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] X (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402). ___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509). ___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009). X (4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note). ___ (5) [Reserved] ___ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). ___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). X (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (31 U.S.C. 6101 note). X (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313). ___ (10) [Reserved] ___ (11) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a). ___ (ii) Alternate I (Nov 2011) of 52.219-3. ___ (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a). ___ (ii) Alternate I (Jan 2011) of 52.219-4. ___ (13) [Reserved] ___ (14) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644). ___ (ii) Alternate I (Nov 2011). ___ (iii) Alternate II (Nov 2011). ___ (15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644). ___ (ii) Alternate I (Oct 1995) of 52.219-7. ___ (iii) Alternate II (Mar 2004) of 52.219-7. X (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)). X (17) (i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637 (d)(4)). ___ (ii) Alternate I (Nov 2016) of 52.219-9. ___ (iii) Alternate II (Nov 2016) of 52.219-9. ___ (iv) Alternate III (Nov 2016) of 52.219-9. ___ (v) Alternate IV (Nov 2016) of 52.219-9. ___ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)). ___ (19) 52.219-14, Limitations on Subcontracting (Jan 2017) (15 U.S.C. 637(a)(14)). X (20) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). ___ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657f). X (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)). ___ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)). ___ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)). X (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755). X (26) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126). X (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). X (28) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246). X (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212). X (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). X (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212). X (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). X (33) (i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627). ___ (ii) Alternate I (Mar 2015) of 52.222-50, (22 U.S.C. chapter 78 and E.O. 13627). ___ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) ___ (35) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (Oct 2016). (Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017). Note to paragraph (b)(35): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. X (36) 52.222-60, Paycheck Transparency (Executive Order 13673) (Oct 2016). ___ (37) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ___ (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O.13693). ___ (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693). ___ (40) (i) 52.223-13, Acquisition of EPEAT -Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514 ___ (ii) Alternate I (Oct 2015) of 52.223-13. ___ (41) (i) 52.223-14, Acquisition of EPEAT -Registered Television (Jun 2014) (E.O.s 13423 and 13514). ___ (ii) Alternate I (Jun 2014) of 52.223-14. ___ (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b). ___ (43) (i) 52.223-16, Acquisition of EPEAT -Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514). ___ (ii) Alternate I (Jun 2014) of 52.223-16. X (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011) (E.O. 13513). ___ (45) 52.223-20, Aerosols (Jun 2016) (E.O. 13693). ___ (46) 52.223-21, Foams (Jun 2016) (E.O. 13696). ___ (47) (i) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a). ___ (ii) Alternate I (Jan 2017) of 52.224-3. X (48) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83). ___ (49) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43). ___ (ii) Alternate I (May 2014) of 52.225-3. ___ (iii) Alternate II (May 2014) of 52.225-3. ___ (iv) Alternate III (May 2014) of 52.225-3. X (50) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). ___ (51) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). ___ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). ___ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150). ___ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). ___ (55) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505), 10 U.S.C. 2307(f)). X (56) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)). ___ (57) 52.232-33, Payment by Electronic Funds Transfer- System for Award Management (Jul 2013) (31 U.S.C. 3332). ___ (58) 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management (Jul 2013) (31 U.S.C. 3332). ___ (59) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332). ___ (60) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a). ___ (61) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(12)). ___ (62) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). ___ (ii) Alternate I (Apr 2003) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] ___ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495) ___ (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67.). ___ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). ___ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C.206 and 41 U.S.C. chapter 67). ___ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). ___ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67). ___ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67). ___ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O. 13658). ___ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706). ___ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). ___ (11) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). ___ (12) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008) (31 U.S.C. 5112(p)(1)). (d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509). (ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (iii) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (iv) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (1) of FAR clause 52.222-17. (v) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). (vi) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246). (vii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212). (viii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). (ix) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212). (x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (xi) 52.222-41, Service Contract Labor Standards (May 2014), (41 U.S.C. chapter 67). (xii) (A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627). (B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 E.O. 13627). (xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.) (xiv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67) (xv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989). (xvi) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015). (xvii) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (Oct 2016) (Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 2...