Top

Cryogenic Liquid Nitrogen Piping Installation

Active

Federal

Response Deadline08/17/2026, 11:00:00 AM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

General Info

Agency

Department Of Veterans Affairs → Rpo East (36C24E)View Agency

NAICS

238220 - Plumbing, Heating, and Air-Conditioning ContractorsView NAICS

Place of Performance

Set-Aside

NONE

Documents

This scope was carved out of 36C24E26Q0098.

The full solicitation package (1 document), including the RFP, is on the prime solicitation, not on this scope.

View the prime solicitation

6515--Facility Support Services - Install Cryogenic Liquid Nitrogen Piping - LA | EDA: 9/25/26

AI Contract Breakdown

Uniform Contract Format

No contract breakdown available.

Cannot generate Contract Breakdown because no documents were found from this contract's source.

Timeline

PostedAug 13

subcontract

Response DeadlineAug 17

Submission deadline

Response Deadline

08/17/2026, 11:00:00 AM UTCin 3 days

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

AgencyDepartment Of Veterans Affairs → Rpo East (36C24E)

ContactsNo contacts available

OfficeN/A

Organization / Agency

Department Of Veterans Affairs → Rpo East (36C24E)

View Agency Profile

Office AddressN/A

ContactsNo contact information available

Full Description

Turnkey installation of a cryogenic liquid nitrogen piping system to support biospecimen preservation in a medical research environment.

Similar Contracts

Same NAICS industry code

NAICS: 238220

New

RFQ7519 Backflow Preventor Repair Services

Solicitation # 7519

Management & Training Corporation (MTC) is seeking bids for a subcontracting opportunity to provide plumbing services at the Sierra Nevada Job Corps Center in Reno, Nevada. The scope of work specifically involves the repair of three backflow preventers, including fixing two failed units and one leaking unit with necessary repair parts, as well as the replacement of two backflow shut-off valves located in the gymnasium. This solicitation is open to various small business categories, including SDB, WOSB, HUBZone, and Veteran-Owned businesses, under NAICS code 238220. Bids and required documentation must be submitted via email to Tom Williams by August 25, 2026, at 3:00 PM PST. The contract is subject to several federal regulations and special requirements, including the Service Contract Labor Standards with Wage Determination 2015-5595 (Rev 28). Contractors must maintain comprehensive insurance coverages, including general liability of 1,000,000 dollars per occurrence and worker's compensation with employer's liability of at least 500,000 dollars. Additionally, first-tier subcontractors with awards exceeding 30,000 dollars must disclose their debarment status per FAR 52.209-6. The agreement is governed by the laws of the state of Utah, and MTC retains the right to cancel the contract immediately if government funding is discontinued. Payment is issued upon the submission of invoices for materials or services that have been delivered and accepted.

Sierra Nevada Job Corps Center

POSTED

DEADLINE

Boiler and Mini-Split

Solicitation # boiler-mini-split-0

This subcontracting opportunity, issued by Grafton Job Corps Center and Adams and Associates, Inc., involves the installation of two DX mini-split air conditioning units in the Building 17 server room and the installation of two high-efficiency central heating boilers in Building 7. The mini-split project requires 3-ton R-32 systems, specifically Daikin model DC9VSA3610A or approved equals, while the boiler project specifies Weil-McLain Series 2 Condensing Hot Water Boilers (model SVF-1500 S2) with 1500 MBH input. All work must be performed at the Grafton Job Corps Center in North Grafton, Massachusetts, and must comply with EPA, OSHA, and state of Massachusetts regulations. The contract is a single lump sum award based on best value, with evaluation weighted toward price (60 percent), quality (20 percent), past performance (10 percent), and schedule (10 percent). Bidders must be licensed in Massachusetts and provide a 90-day bid guarantee, a detailed cost breakdown, and proof of comprehensive insurance, including general liability of at least 1 million dollars per occurrence. Performance begins within 14 days of the Notice to Proceed, with a one-year guarantee on workmanship. Compliance with prevailing wage rates for Worcester County is mandatory, and all certified payroll records must be submitted to the center. Proposals are due by August 26, 2026, to Shelia Lozada.

POSTED

DEADLINE

AC Compressor Replacements for Gym, Academic and Kitchen Area

Solicitation # ac-compressor-replacements-gym-academic-kitchen-area

The Miami Job Corps Center is seeking proposals for AC compressor replacements across its gym, academic, and kitchen areas in Florida. This solicitation is open to various small business categories, including Small Disadvantaged, Women-Owned, HUBZone, and Veteran-Owned small businesses. The project falls under NAICS code 238220, focusing on plumbing, heating, and air-conditioning contractual work. Interested parties must submit their responses by the deadline of September 3, 2026. The primary point of contact for this opportunity is Fernande Frederic, who can be reached via email or phone for further inquiries regarding the submission process and project requirements.

Miami Job Corps Center

POSTED

DEADLINE

CBP#3642 HVAC Replacement for Building F

Solicitation # cbp3642-hvac-replacement-building-f

Management & Training Corporation (MTC) is soliciting bids for a lump sum subcontracting opportunity to replace the HVAC rooftop unit (ACU-F1) at the Charleston Job Corps Center in Charleston, West Virginia. The project requires the installation of a new 10-ton cooling, 205 MBH gas heating input packaged rooftop unit, including all necessary labor, materials, equipment, and permits. The contractor is responsible for the removal and disposal of existing components per EPA and ASHRAE 15 standards and must provide a minimum five-year compressor warranty and a one-year parts and labor warranty. Bids are due by August 31, 2026, and will be evaluated based on overall best value. The project must be completed within 30 consecutive business days following the Notice to Proceed, with liquidated damages of 100 dollars per calendar day for incomplete or unsatisfactory work. For bids equal to or greater than 25,000 dollars, a bid bond of 20 percent and performance and payment bonds of 100 percent are required. Contractors must maintain comprehensive insurance coverage, including general liability of 1 million dollars per occurrence and workers compensation with employer liability of at least 500,000 dollars. This opportunity is set aside for various small business categories, and awarded contractors must possess a Unique Entity Identifier (UEI) and comply with federal regulations, including FFATA reporting for contracts valued at 40,000 dollars or more and specific Department of Labor training and records management requirements.

Management & Training Corporation

POSTED

DEADLINE

2026-Maui-Dorm Exhaust Fans

Solicitation # 2026- Maui- Dorm Exhaust Fans

Management and Training Corporation (MTC) is seeking bids for a fixed-price, single lump sum subcontracting project to remove and replace approximately 25 exhaust fans across three dormitories at the Hawaii Job Corps Center in Makawao, Hawaii. The scope of work includes the safe removal and disposal of existing fans, installation and testing of new approved units, restoration of damaged drywall and plaster to match existing finishes, and the provision of two operation and maintenance manuals along with two hours of on-site training for facility personnel. Bids must be submitted via email to Karllene Allen and Mila Handel by 3:00 PM HST on August 28, 2026. A physical site visit and signature on an attendance roster are mandatory prerequisites for bid submission. The award will be based on overall best value, requiring bidders to provide three references for projects of comparable scope and value. Required submission documents include the MTC Bid for Lump Sum Contract form, a detailed cost breakout on company letterhead, a completed MTC Supplier Packet (including W-9 and self-certification), and proof of insurance. For bids equal to or greater than $25,000, a bid bond of 20% is required, and performance and payment bonds of 100% of the contract price must be provided upon award. The contractor must comply with Federal Contractor Minimum Wage requirements per Executive Order 13658, submit weekly certified payroll reports, and adhere to strict DOL privacy and security guidelines. Payment is processed via AIA G702/G703 forms, with a 10 percent retainage held until substantial completion and final acceptance.

Management & Training Corporation

POSTED

DEADLINE

NJCC Building 32 Boiler Replacement in Vermont

Solicitation # njcc-building-32-boiler-replacement-vermont

This subcontracting opportunity is a solicitation for the replacement of an oil-fired boiler system with a high-efficiency propane steam boiler at Building 32 of the Northlands Job Corps Center in Vergennes, Vermont. The scope of work includes the demolition and disposal of the existing boiler and blow down separator, installation of a new propane steam boiler and gas burner meeting FEMP efficiency standards, and the replacement of critical components such as the duplex boiler feed tank, control panel, condensate tanks, and steam traps. The project also requires the installation of new boiler feed water piping with a reduced pressure backflow preventer and a propane gas tank. All work must comply with various international codes, including the IMC, IECC, IPC, IFGC, and NEC, as well as NFPA Life Safety 101 and NFPA 58 standards. Bids are due by 12:00 p.m. on August 20, 2026, and must be submitted to Jeana Bradford at the Northlands Job Corps Center. To be considered, respondents must provide a detailed bid sheet with line-item pricing for equipment, materials, and labor, a proposed service schedule, and all required Vermont licensing and credentials. Mandatory documentation includes a W-9, Vendor Acknowledgement Form, and certificates of insurance listing the Center/ETR as the certificate holder. Depending on the project value, performance and payment bonds may be required for contracts exceeding 35,000 dollars. The winning bidder must maintain an active registration at Sam.gov and possess a Unique Entity ID. Award selection is at the sole discretion of ETR and is not based solely on the lowest bid.

Northlands Job Corps Center /ETR

POSTED

DEADLINE

RFQ#3857 Freezer Door Replacement

Solicitation # RFQ#3857

Management & Training Corporation (MTC) is seeking a qualified subcontractor for RFQ#3857 to replace three walk-in refrigeration doors at the Charleston Job Corps Center in Charleston, West Virginia. The scope of work includes providing all labor, materials, equipment, and supervision to install one walk-in cooler door and two walk-in freezer doors, including all necessary hardware, gaskets, and accessories. The contractor is responsible for the removal and disposal of old doors and debris, providing manufacturer warranties, and ensuring all installations meet OSHA and refrigeration industry standards. This is a fee-for-service opportunity requiring a lump sum bid, with the award based on best value as determined by MTC. Eligible bidders must self-certify under NAICS code 238220 and provide a completed supplier packet, W-9, proof of insurance, and three references by August 17, 2026. Required insurance coverage includes 1 million per occurrence for general liability, 1 million for auto, and 500,000 for worker's compensation. The contract is subject to FAR 52.222-41 Service Contract Labor Standards and Wage Determination 2015-4347. Additionally, the contractor must comply with Department of Labor privacy and records management requirements, and they will benefit from a sales tax exemption under the Workforce Investment Act. Invoices are to be submitted weekly or bi-weekly and must include the purchase order number and a detailed pricing breakdown.

Management & Training Corporation

POSTED

DEADLINE

CBP#3839 HVAC Replacement for Building A

Solicitation # CBP#3839

Management & Training Corporation (MTC) is soliciting bids for a subcontracting opportunity to replace the rooftop HVAC system at the Charleston Job Corps Center in Charleston, West Virginia. The project, identified as CBP#3839, specifically targets Building A (Maintenance/Warehouse) and involves the installation of four units: three 4-ton cooling units (ACU-A1, A2, A3) and one 7.5-ton cooling unit (ACU-A5). This is a fixed-price, single lump sum contract with an estimated value between $25,000 and $100,000. The selected contractor must provide all labor, materials, equipment, and supervision, ensuring the system is fully operational and compliant with federal, state, and local codes. Deliverables include operation and maintenance manuals, startup documentation, a minimum five-year compressor warranty, and a one-year parts and labor warranty. The opportunity is open to various small business categories, including SDB, WOSB, HUBZone, and SDVOSB, under NAICS code 238220. Bids must be submitted by August 31, 2026, and include a detailed bid breakout, proof of insurance, and three comparable references. Performance must be completed within 30 consecutive business days following the Notice to Proceed, with liquidated damages of $100 per day for delays. Key requirements include compliance with prevailing wage determinations, weekly certified payroll reporting, and the provision of performance and payment bonds. The award will be based on overall best value, with MTC serving as the sole judge. Final payment is contingent upon the submission of a Notice of Final Completion, a release of liens, and the approval of a final punch list.

Management & Training Corporation

POSTED

DEADLINE

Solicitation # Plumbing Services 8-2026

Management & Training Corporation is soliciting a fixed-price, single lump sum subcontract for plumbing services at the Centennial Job Corps Center in Nampa, Idaho. The primary scope of work involves rectifying failures in a dry type sprinkler system compressor and replacing the sprinkler pipes in their entirety at the Men's Dormitory Building CM, in accordance with NFPA 25 and applicable building codes. Bids must be submitted via email to Sandra Clore by August 28, 2026, at 3:00pm MST. A pre-bid meeting and walk-through are scheduled for August 20, 2026, at 10:00am MST. Award will be based on overall best value, and the contractor must complete the work within 30 business days of the Notice to Proceed. This opportunity is set aside for various small business categories, including SDB, WOSB, HUBZone, and SDVOSB. For bids equal to or exceeding $25,000, a 20% bid bond guarantee is required, as well as performance and payment bonds totaling 100% of the contract price from an A-rated surety company. Contractors must comply with the Davis-Bacon Act, provide weekly certified payroll, and maintain specific insurance limits, including $1 million per occurrence for general liability and $500,000 for worker's compensation. Submissions must include a detailed cost breakout, three comparable references, and a signed MTC Bid for Lump Sum Contract form. Failure to complete work satisfactorily may result in liquidated damages of $200 per calendar day.

Management & Training Corporation/Centennial Job Corps Center

POSTED

DEADLINE

Principle Health Care - Holly Springs

Solicitation # principle-health-care-holly-springs

The Principle Health Care project in Holly Springs, North Carolina, involves the complete new construction of a healthcare facility. The scope of work is comprehensive, encompassing general construction as well as specialized electrical, mechanical, and plumbing installations. This solicitation is managed by H.G. Reynolds Co., Inc., with an estimated project start date scheduled for 60 days following the bid date. This opportunity is designated as an SBA set-aside, making it available to various small business categories, including Small Disadvantaged, Women-Owned, HUBZone, and Veteran-Owned small businesses. While the primary NAICS code is 238220, the project covers a wide range of construction and specialty trade codes. Interested parties must submit their responses by August 18, 2026, and can coordinate with the primary point of contact, Jesse Hill.

H.G. Reynolds Co., Inc

POSTED

DEADLINE

OJCA Dormitory Shower Ventilation

Solicitation # ojca-dormitory-shower-ventilation

Education Training & Resources LLC is soliciting bids for the replacement of shower ventilation at the Oneonta Job Corps Academy in New York. The project requires the removal and disposal of eight inline exhaust fans, existing ductwork, ceiling registers, and wall or roof terminations. The contractor must install eight new inline exhaust fans in existing locations with capacities ranging from 200 to 400 CFM depending on the specific room, and provide ductwork insulation to prevent condensation and energy loss. All work must comply with IMC, NEC, NFPA, and ASHRAE standards, as well as OSHA regulations, and include a minimum one-year parts and labor warranty. This is an SBA set-aside solicitation open to various small business categories, including SDB, WOSB, HUBZone, VOSB, and SDVOSB, under NAICS code 238220. Bids must be submitted by August 27, 2026, using a Fee-For-Services model that includes all labor, materials, and supervision. Required submissions include a completed bid sheet, a detailed cost breakdown, a proposed service schedule, a W-9, and a Certificate of Liability Insurance listing Center/ETR as the certificate holder. Award selection is at the sole discretion of ETR and is not based solely on the lowest bid. Performance bonds are required for projects exceeding $35,000, and all purchases are tax exempt.

Education Training & Resources LLC

POSTED

DEADLINE

Offline Disinfection & System Flushing

California Department of General Services

POSTED

about 15 hours ago

DEADLINE

in 19 days

View Details

More opportunities from Department Of Veterans Affairs → Rpo East (36C24E)

Same awarding agency

NAICS: 484220

New

Federal

Specialized Material Hauling and Logistics

Specialized Freight (except Used Goods) Trucking, Local

POSTED

DEADLINE

Mechanical System Integration and Testing

POSTED

DEADLINE

Stainless Steel Valve and Fitting Supply

Plumbing Fixture Fitting and Trim Manufacturing

POSTED

DEADLINE

Thermal Insulation for Cryogenic Piping

Other Building Equipment Contractors

POSTED

DEADLINE

6515--Facility Support Services - Install Cryogenic Liquid Nitrogen Piping - LA | EDA: 9/25/26

Solicitation # 36C24E26Q0098

The Department of Veterans Affairs, West Los Angeles VA Medical Center, intends to award a sole source contract to Cornerstone Mechanical Inc. for the turnkey installation of a specialized, insulated liquid nitrogen piping distribution system. This project involves providing all labor, materials, and supervision to install 1/2-inch Type L copper piping, fiberglass insulation with metal jackets, stainless steel ball valves, and cryogenic hose assemblies. The system will connect VA-furnished tanks to seven research freezers to ensure critical backup cryogenic protection for Veteran biospecimens. The government is pursuing a sole source procurement under FAR 6.302-1 because market research failed to identify other local sources capable of providing these specific turnkey services and ensuring compatibility with existing equipment. While this is a notice of intent rather than a request for quotes, interested parties capable of meeting the exact specifications may submit capability statements to Stacy Taylor by August 17th at 7 AM EST. The final decision to compete the requirement remains at the sole discretion of the government.

Analytical Laboratory Instrument Manufacturing

POSTED

DEADLINE

6515--Autoclave Steam Sterilizers

Solicitation # 36C24E26Q0101

The Veterans Health Administration is conducting market research to identify qualified vendors capable of providing two medium laboratory autoclave steam sterilizers for the Louis Stokes Cleveland VAMC. The required equipment must meet specific dimensions to fit existing infrastructure and include features such as a non-proprietary Allen-Bradley control system, vacuum capabilities, and specific door and piping configurations. The scope of work encompasses the delivery and installation of the sterilizers and associated loading carriages, as well as the deinstallation and disposal of the existing system and generators. This is a Sources Sought notice intended for acquisition planning and size determination under NAICS code 334516, not a request for quotes. Interested parties must be the original equipment manufacturer or an authorized distributor. Respondents are required to submit a capability statement, small business information, and technical specification sheets for proposed systems or equivalents to the contracting office by August 18, 2026.

Analytical Laboratory Instrument Manufacturing

POSTED

DEADLINE

AN24-- Good Clinical Practice (GCP) Clinical Research Quality Associate (CRQA) Monitoring Services

Solicitation # 36C24E26Q0054

Solicitation 36C24E26Q0054 is a combined synopsis and solicitation issued by the Department of Veterans Affairs, Regional Procurement Office East, for Good Clinical Practice (GCP) Clinical Research Quality Associate (CRQA) Monitoring Services. This contract is set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB) under NAICS code 541990. The estimated contract value ranges from a minimum of 20,000 dollars to a maximum of 2,000,000 dollars, with a total period of performance of three years, typically spanning from September 16, 2026, to September 15, 2029. The scope of work involves providing CRQA monitoring services, including site visits and non-conformance reporting, adhering to strict regulatory standards such as ICH E6 (R2), 45 CFR 46, 38 CFR 16, and various FDA and VHA directives. Contractor personnel must meet rigorous qualification standards, including a bachelor's degree in a scientific or health-related field or professional licensure, GCP training, and a minimum of 10 years of relevant experience. Security requirements include background investigations ranging from Tier 1 to Tier 5 depending on the risk level of the duties. Proposals must be submitted via email to the Contracting Officer, Renee Kale, by August 25, 2026, at 10:00 AM EDT. Submissions must be organized into separate, clearly labeled electronic files across six specific sections, including technical, price, and past performance volumes, with strict page limits for technical narratives and past performance references. Invoicing must be processed electronically through the VA Electronic Invoice Presentment and Payment (EIPP) System.

All Other Professional, Scientific, and Technical Services

POSTED

DEADLINE

AN41-- ****Intent to Sole Source***** Independent Ventilated Cage Systems-Columbia

Solicitation # 36C24E26Q0089

The Department of Veterans Affairs, specifically the Columbia Missouri Healthcare System, intends to award a sole source procurement to Allentown LLC for independently ventilated cage systems and related components. The requirement includes a variety of IVC mouse cages, rabbit units, bottles, feeders, and blower assemblies. This procurement is intended to maintain consistency with the University of Missouri academic affiliate, ensuring equipment compatibility, shared standard operating procedures, and the safe exchange of animals and equipment. The solicitation is categorized under NAICS code 332999 with a business size standard of 750 employees. While this is a notice of intent for a sole source award rather than a request for competitive quotes, interested parties may submit their capabilities and relevant specifications to the contracts specialist by August 20, 2026. The final determination regarding whether to compete the requirement remains at the sole discretion of the government.

All Other Miscellaneous Fabricated Metal Product Manufacturing

POSTED

DEADLINE

Emergency or On-Demand Dry Ice Logistics and Transportation

Specialized Freight (except Used Goods) Trucking, Local

POSTED

DEADLINE

Dry Ice Supply – 250 lb Bin Delivery (Sepulveda Outpatient Clinic, Building 7, Room 140)

Industrial Gas Manufacturing

POSTED

DEADLINE

Dry Ice Supply – 500 lb Bin Delivery (West Los Angeles VAMC, Building 500)

Industrial Gas Manufacturing

POSTED

DEADLINE

Dry Ice Supply – 1,000 lb Slab Delivery (West Los Angeles VAMC, Building 114)

Industrial Gas Manufacturing

POSTED

2 days ago

DEADLINE

in 3 days

View Details