Skip to main contentPsst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveFree Webinar — Wednesday, November 11 at 2:00 PM ET

Register Free →

General Contractor / Prime Construction Services

Open
Federal

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

The Department of the Interior, through the Reclamation Contracting Activity, is seeking a General Contractor for Prime Construction Services to perform heavy and civil engineering work. The selected subcontractor will be responsible for the overall project coordination and execution of civil engineering tasks as outlined in the draft drawings and Specification No 20-C0952. Qualified candidates must demonstrate a proven track record of past performance on projects valued between 5 million and 10 million dollars. This opportunity falls under NAICS code 237990, with a response deadline set for November 18, 2026.

General Info

Interior Department seeks general contractor for civil engineering work by November 18, 2026.

NAICS

237990 - Other Heavy and Civil Engineering Construction

Place of Performance

CO

Set-Aside

NONE

Documents

This scope was carved out of 140RR027R0017.

The full solicitation package (1 document), including the RFP, is on the prime solicitation, not on this scope.

View the prime solicitation

East Bear Creek Pumping Plant and Pipeline Moderni

AI Contract Breakdown

Uniform Contract Format

No documents to break down

The breakdown needs solicitation documents. None were found from this contract's source.

Timeline

Posted

subcontract

Response Deadline

Submission deadline

Response Deadline

Ready to pursue this opportunity?

Get full access to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more
AgencyDepartment Of The Interior → Reclamation Contracting Activity
ContactsNo contacts available
OfficeN/A
Office AddressN/A
ContactsNo contact information available

Full Description

Show more
Performs general heavy and civil engineering construction for the Government as defined by Specification No 20-C0952. Manages overall project coordination and execution of civil engineering works described in draft drawings and specifications. Requires proven past performance on projects between $5M and $10M. Delivers the completed construction project per Specification No 20-C0952.

Similar Contracts

Same NAICS industry code

NAICS: 237990
New
SLED
(RFP) 27-21, Richard Craig Park Athletic Complex Renovation
Solicitation # 27-21
Henry County Parks and Recreation is seeking qualified contractors for a single-prime turnkey renovation and modernization of the Richard Craig Park Athletic Complex in McDonough, Georgia. The project involves a comprehensive overhaul of eight baseball and softball fields, as well as the Sunshine League therapeutic field, which requires a specialized ADA-accessible cushioned playing surface. Key technical requirements include selective demolition, laser grading, drainage improvements, irrigation replacement, and the installation of certified 419 Bermuda sod. Additionally, the scope covers the reconstruction of infields, installation of new fencing, backstops, dugout roof systems, and the conversion of an existing batting cage into a five-station training facility, alongside renovations to the concession facility. To minimize operational disruptions, construction will be executed in two distinct phases. Phase One focuses on the renovation and turnover of Fields 1 through 5, which must reach final acceptance before the contractor proceeds to Phase Two, covering Fields 6 through 8, the therapeutic field, and the remaining facility improvements. Proposals are due by 3:00 PM on November 11, 2026, via the County's eProcurement Portal. Award selection is based on the most qualified firm, with evaluation criteria including technical competence, qualifications, and cost. Successful bidders must provide a five percent bid bond, 100 percent performance and payment bonds, and certify compliance with the Georgia Security and Immigration Compliance Act and Drug-Free Workplace regulations.
Parks & Recreation

POSTED

about 5 hours ago

DEADLINE

in 6 days
View Details
NAICS: 237990
New
SLED
Freedom Park Boardwalk Repairs - Boardwalks 1 & 2
Solicitation # 26-8700
Solicitation 26-8700 is an Invitation to Bid issued by the Collier County Board of County Commissioners for the repair and restoration of Boardwalks 1 and 2 at Fred W. Coyle Freedom Park in Naples, Florida. The project has an anticipated budget of 1,300,000 dollars and a performance timeline of 134 calendar days from the Notice to Proceed. The scope of work includes replacing deteriorated decking, structural supporting timber, fasteners, and hardware, as well as replacing damaged pilings and support beams. Specific technical requirements include the use of IPE Wood, Class IV concrete, and the installation of structural integral pile jackets and floating turbidity barriers in compliance with FDOT and ASCE standards. The contract will be awarded to the lowest responsive and responsible bidder. Bidders must provide a 5% bid bond and, upon award, furnish payment and performance bonds for 100% of the contract amount. Key submission requirements include a completed bid schedule, five project references from the last five years, a valid State of Florida General or Building Contractor license, and E-Verify documentation. The project includes an Owner's Allowance of 198,120 dollars for unforeseen conditions. Failure to achieve substantial completion will result in liquidated damages of 1,534 dollars per calendar day. Contractors must adhere to strict environmental, health, and safety requirements, including mangrove protection and compliance with the Florida Trench Safety Act.
Procurement

POSTED

about 6 hours ago

DEADLINE

in 1 day
View Details
NAICS: 237990
New
SLED
Improvements to Roddy Road and Expansion to the Amite River Boat Launch Dock in Port Vincent
Solicitation # REC250034
The Parish of Ascension in Louisiana is soliciting bids for the Improvements to Roddy Road and Expansion to the Amite River Boat Launch Dock in Port Vincent, identified by solicitation number REC250034. The project scope involves expanding the existing Amite River dock from 25 feet to approximately 100 feet to enhance public and recreational access. Key deliverables include the construction of a new ADA-compliant pedestrian path connecting the parking area to the dock, the development of accessible parking spaces with required signage and markings, and the installation of timber, steel sheet piles, concrete slabs, curbs, and sidewalks. All work must adhere to ADA accessibility requirements and specific 2016 laboratory standards for structural and geotechnical testing of concrete. The contract will be awarded to the lowest responsible and responsive bidder whose total bid amount is within the contract budget. Bidders must submit their offers by December 1, 2026, at 10:00 a.m. local time, either via the centralauctionhouse.com portal or in a sealed opaque envelope. Required financial securities include a bid security of 5% of the total bid, with the winning bidder required to provide performance and payment bonds each equal to 100% of the total contract amount. Contract times commence 30 days after the effective date or upon receipt of a Notice to Proceed. The Engineer is responsible for judging the acceptability of the work and reviewing monthly applications for payment, which must be submitted at least 20 days before the payment date.
Parish of Ascension

POSTED

about 6 hours ago

DEADLINE

in 26 days
View Details
NAICS: 237990
New
Federal
Maintenance Dredging of the Isle au Haut Thoroughfare near Isle au Haut, Maine
Solicitation # W912WJ27BA003
Solicitation W912WJ27BA003 is a sealed bid project for the maintenance and advance maintenance dredging of the Isle au Haut Thoroughfare Federal Navigation Project located between Isle au Haut and Kimball Island, Maine. The scope of work involves the mechanical dredging of approximately 3,355 cubic yards of highly compacted coarse sand, gravel, cobbles, and isolated boulders from a 1,200-foot long channel. The objective is to achieve a depth of -7 feet Mean Lower Low Water (MLLW), with an allowable one-foot overdepth for a maximum dredging depth of -8 feet MLLW. All dredged materials are to be disposed of at the Flake Island Disposal Site, approximately 0.9 nautical miles northwest of the project site, to enhance juvenile lobster and cod habitats. This project is a total small business set-aside under NAICS 237990, with an estimated price range between 1,000,000 and 3,000,000 dollars. Performance is strictly limited to an environmental window between September 15 and April 1 to protect spawning shellfish and other benthic resources, with a mandatory performance period of 120 calendar days after the Notice to Proceed. Bidders must submit proposals via the Procurement Integrity Enterprise Environment (PIEE) and provide bid, performance, and payment bonds. The contract requires adherence to EM 385-1-1 safety standards and the implementation of a comprehensive Contractor Quality Control Plan utilizing a three-phase control system.
W2SD Endist New England

POSTED

about 7 hours ago

DEADLINE

in 5 days
View Details
NAICS: 237990
New
Federal
Fishtrap Lake Intake Structure and Dam Rehabilitation; W91237-26-R-A020
Solicitation # W9123726RA020
Solicitation W9123726RA020 is a new acquisition issued by the Department of the Army, Huntington District, for the rehabilitation of the intake structure and dam at Fishtrap Lake in Shelbiana, Kentucky. The scope of work includes comprehensive electrical and mechanical replacements, specifically focusing on spillway gate machinery, the installation of a new electric service entrance, and the replacement of power and control wiring. The project also requires specialized remediation for asbestos and lead, as well as the removal and replacement of various mechanical components such as line shafts, bearings, and Tainter gate brakes. The base contract must be completed within 270 calendar days from the Notice to Proceed, with four optional tasks for the rehabilitation of cylinders, cranes, elevators, and hydraulic systems that could extend the total period of performance to a maximum of 720 calendar days. Proposals are evaluated based on past performance, a small business participation plan, and the reasonableness and completeness of the cost proposal. Submissions must be uploaded in searchable PDF format via the PIEE Solicitation Module. The contractor is required to comply with the Davis-Bacon Act for prevailing wages in Pike County, Kentucky, and must adhere to USACE EM 385-1-1 (2024) safety standards. Key requirements include the designation of a DOT-certified Transportation and Disposal Coordinator for hazardous materials and the maintenance of comprehensive general and automobile liability insurance. Final acceptance is subject to inspections by the Contracting Officer and a third-party QEI Certified Elevator Inspector where applicable.
W072 Endist Huntington

POSTED

about 7 hours ago

DEADLINE

in 15 days
View Details

More opportunities from Department Of The Interior → Reclamation Contracting Activity

Same awarding agency

NAICS: 237110
New
Federal
Y--Turnout Buildings
Solicitation # 140R4026B0002
Solicitation 140R4026B0002 is a sealed bid Invitation for Bid issued by the Bureau of Reclamation for the turnkey construction of potable water delivery turnout buildings and associated site improvements as part of the Navajo-Gallup Water Supply Project. The project scope includes the installation of precast concrete buildings and foundations, buried piping, valves, fiberoptic infrastructure, gravel surfacing, drainage, and steel fencing at multiple sites, with specific requirements for access roads at the Coyote Canyon and Window Rock locations. The estimated project magnitude is between 18 million and 23 million dollars, with a period of performance spanning from December 16, 2026, to April 16, 2029. Award will be granted to the responsible, compliant offeror with the lowest Total Bid Price, calculated as the sum of price schedules 1 through 7 excluding certain taxes. The contractor is required to perform at least 30 percent of the total work and must adhere to strict technical specifications, including the use of precast concrete and protective coatings for buried materials due to highly corrosive soil conditions. Compliance requirements include the Davis-Bacon Act for prevailing wages in San Juan and McKinley Counties, ADA standards, and the submission of a Small Business Subcontracting Plan. Bidders must provide a bid guarantee, and the successful contractor will be required to furnish performance and payment bonds.
Water and Sewer Line and Related Structures Construction

POSTED

1 day ago

DEADLINE

in 26 days
View Details
NAICS: 237990
New
Federal
East Bear Creek Pumping Plant and Pipeline Moderni
Solicitation # 140RR027R0017
The Department of the Interior Bureau of Reclamation is conducting market research for the modernization of the East Bear Creek Pumping Plant and Pipeline located at two sites on the San Luis National Wildlife Refuge in Merced County, California. The project scope includes the installation of a fish screen, sheet pile wall, pipeline, access road, and butterfly valves, as well as modifications to the pumping plant discharge and electrical systems. Specific work at the pumping plant site involves electrical and controls upgrades and the furnishing of a fish screen, while the regulating tank site requires the replacement of controls components. The anticipated construction period is 560 calendar days from the Notice to Proceed, with an estimated project magnitude between 5 million and 10 million dollars. This effort is currently in the Sources Sought phase under NAICS 237990 to determine the most effective procurement approach, such as a small business set-aside or full and open competition. Interested contractors must submit capability statements, business information, and up to three relevant past performance projects from the last five years to the designated points of contact by November 18, 2026. All respondents must maintain an active registration in the System for Award Management. Draft specifications and drawings are available upon request to assist qualified firms in providing their statements of interest.
Other Heavy and Civil Engineering Construction

POSTED

1 day ago

DEADLINE

in 13 days
View Details
NAICS: 237990
New
Federal
Y--Shasta Powerplant (SH-PP) Compressor Room Modernization
Solicitation # 140RR027R0018
The Department of the Interior, Bureau of Reclamation, has issued a Sources Sought Notice for the modernization of the compressor room at the Shasta Powerplant, located approximately 9 miles northwest of Redding, California. This market research effort aims to identify qualified contractors capable of completely replacing all equipment in the compressor room with modern systems. The project magnitude is estimated between 1,000,000 and 2,000,000 dollars, with an anticipated construction period of 365 calendar days from the Notice to Proceed. The scope includes field verification of existing conditions and strict requirements for the protection of existing installations, including the prevention of dust in ventilating systems and the prohibition of disturbing asbestos-containing materials. The government is currently evaluating the best procurement approach, considering options such as a total small business set-aside, full and open competition, or the use of existing contract vehicles like the BIA Construction Multiple Award Contract or FWS Multiple Award Task Order Contract. Interested respondents must be registered in the System for Award Management under NAICS 237990 and provide business information, a statement of intent, and up to three relevant past performance projects from the last five years. The preliminary procurement schedule anticipates issuing the formal solicitation on January 20, 2027, with a projected award date of March 30, 2027.
Other Heavy and Civil Engineering Construction

POSTED

1 day ago

DEADLINE

in 14 days
View Details
NAICS: 541690
New
Federal
B--INJECTION WELL FAILURE MODE EVALUATION
Solicitation # 140RR027Q0004
The Department of the Interior, through the Reclamation Contracting Activity, is soliciting quotes for an Injection Well Failure Mode Evaluation at the Paradox Valley Unit in western Colorado. This total small business set-aside under NAICS 541690 requires a contractor to identify, evaluate, and document potential risks and failure modes for the surface, subsurface, and reservoir systems of the PVU Injection Well. The scope of work includes a comprehensive system review of project documentation, the definition of failure indicators, and the recommendation of monitoring and diagnostic methods. Key deliverables include a draft and final report, which must be signed and stamped by a registered professional engineer, and participation in bi-weekly progress meetings. The government intends to award a single fixed-price purchase order based on the lowest price, technically acceptable (LPTA) offer. Technical evaluations will focus on the proposed methods, work schedule, quality control plan, and personnel qualifications, specifically requiring a minimum of ten years of relevant industry experience in deep brine disposal wells. Past performance will be rated as acceptable or not acceptable, though a lack of past performance is also considered acceptable. The period of performance is scheduled from January 20, 2027, through April 30, 2027. Quotes must be submitted via email by November 10, 2026, and all payment requests must be processed through the Invoice Processing Platform.
Other Scientific and Technical Consulting Services

POSTED

2 days ago

DEADLINE

in 8 days
View Details
NAICS: 561720
New
Federal
BGNDRF CUSTODIAL SERVICES
Solicitation # 140RR027Q0001
Solicitation 140RR027Q0001 is a Total Small Business Set-Aside for a firm-fixed-price contract to provide housekeeping and custodial janitorial services at the Brackish Groundwater National Desalination Research Facility (BGNDRF) in Alamogordo, New Mexico. The scope of work covers approximately 6,000 square feet of office, laboratory, and restroom space, including specific requirements for tiled surfaces, carpeted areas, and concrete test bays. The contract consists of a one-year base period starting November 24, 2026, with four subsequent option years and a potential six-month extension, not to exceed a total duration of five years. Services include routine cleaning twice per week and periodic tasks such as deep cleaning tile floors, shampooing carpets, and cleaning exterior windows and painted walls four times per year. Award will be based on a comparative evaluation of technical capability, past performance, and price, with non-price factors weighted approximately equal to cost. The successful contractor must adhere to Bureau of Reclamation Safety and Health Standards and OSHA regulations, maintaining a Quality Control Plan with quarterly inspections to meet the government's Acceptable Quality Level. Invoicing is managed electronically through the Invoice Processing Platform (IPP) following approval from the Contracting Officer's Representative. Proposals must be submitted electronically to the Contract Specialist by November 18, 2026, and must include a cover sheet, a completed price schedule, a signed SF-1449, and separate technical and past performance volumes.
Janitorial Services

POSTED

2 days ago

DEADLINE

in 13 days
View Details

Earlier notices in this NAICS code

Posted before this notice, open and closed

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Miguel
Hillary
Keith Deutsch
Christine

Join 750+ contractors already using CLEATUS