This Pre-Solicitation opportunity from General Services Administration was posted on July 6, 2026. The submission period has ended. Browse the details below for market research, or find similar active opportunities.

Top

General Construction Services for Elevator Modernization at the Thurgood Marshall U.S. Courthouse, New York, NY

Closed

47PB5126R0018Federal

Submission Closed07/21/2026, 08:00:00 PM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

Active Opportunities Like This One

NAICS: 236220

New

SLED

BEQ- Sanitize & Paint Rooms, B4167, Multi Rooms, MASS1, Station

Solicitation # N400857607511

Solicitation N400857607511 is a task order under MACC contract N4008525D for the remediation, preparation, and painting of 22 barracks rooms and associated bathrooms at MCAS Cherry Point, North Carolina. The contractor is responsible for providing all labor, supplies, and equipment to eradicate active microbial growth using EPA-registered disinfectants and antimicrobial solutions. The scope of work includes preparing approximately 18,562 square feet of barracks room surfaces and 3,840 square feet of bathroom surfaces by removing failed paint and applying a heavy-duty, mold-and-mildew-resistant sealing primer. Final finishing requires a minimum of two coats of specialized mold/mildew-resistant paint that matches the existing color and sheen, ensuring a uniform finish without visible patching or roller marks. The project is estimated between 25,000 and 100,000 dollars, with the award based on the lowest price. All work must be completed within 60 calendar days of the award. Proposals were due by September 16, 2026, and must include a completed price proposal form and a list of subcontractors. Bonding requirements vary by proposal value, with payment bonds required for projects between 35,000 and 150,000 dollars. The contractor must comply with the Buy American Act, the Davis-Bacon Act, and FAR 28.307-2 liability insurance requirements. A qualified Quality Control Manager is required to oversee project standards, and all site cleanup must be completed to return the area to its original condition prior to final acceptance by the Contracting Officer's Representative.

Bristol Alliance of Companies

POSTED

DEADLINE

DB Construction for HC-130J Flight Simulator Facility at USCG Elizabeth City, NC

Solicitation # 32000479

This design-build project involves the construction of a full motion Weapons System Trainer flight simulator facility for C-130J aircraft at USCG Base Elizabeth City, North Carolina. The approximately 13,000 gross square foot facility will include a simulator bay for a Government Furnish, Government Installed mobile simulator, classrooms, administrative offices, debriefing spaces, and essential support areas for mechanical, electrical, and telecommunications systems. The scope of work extends to site development, including the installation of sidewalks and landscaping, while utilizing existing parking areas. A critical technical requirement is the integration of a Siemens Building Automation System to ensure compatibility with existing installation-wide systems. Issued under the DHS National Multiple Award Construction Contract III, Pool Two, the project has a magnitude estimate of approximately 16 million dollars and a performance period of 719 calendar days. The award is based on a best-value tradeoff selection, weighing price against non-price factors such as planning, organization, communication, and the contractor's specific experience with military or commercial flight simulators. Strict security and compliance protocols are in place, requiring all on-site personnel to be US citizens and necessitating adherence to Davis-Bacon wage determinations, Buy American requirements, and various environmental and historic preservation consultations.

Bristol Alliance of Companies

POSTED

DEADLINE

CP2713M Replace Runway Switches

Solicitation # N400857563909

Solicitation N400857563909 is a task order for the replacement of runway switches at Marine Corps Air Station Cherry Point in Havelock, North Carolina. The scope of work involves the demolition of four existing 15KV S&C pad-mounted air switches and the installation of new S&C pad-mounted SF6 switches on new concrete box pads. Additionally, the contractor must replace existing tee splices in adjacent manholes with dead front junctions in above-ground junction box enclosures. The project is estimated to be valued between 1,000,000 and 5,000,000 dollars, with a required completion period of 240 calendar days after the award. The contract will be awarded based on the lowest price. Proposals are due by 1200 local time on September 17, 2026. Key requirements include adherence to the Buy American Act, Davis-Bacon Act wage determinations, and specific bonding requirements for proposals exceeding 150,000 dollars, which include bid, payment, and performance bonds. The contractor is responsible for providing a QC Manager to oversee acceptance checks and tests in accordance with NFPA 70B, NETA ATS, and ANSI standards. Invoicing is processed via Wide-Area Workflow using NAVFAC forms, and the contractor must comply with specific cybersecurity and safety regulations, including the provision of an Accident Prevention Plan and Activity Hazard Analysis.

Bristol Alliance of Companies

POSTED

DEADLINE

Upgrade Life Health Safety Systems in Hangar 250

Solicitation # N400857190530

Solicitation N400857190530 involves upgrading the life health safety systems within Hangar 250 at MCAS Cherry Point, North Carolina. The scope of work includes architectural improvements, modifications to fire alarm and fire protection systems, and the rerouting of plumbing and electrical systems. Because the work will be performed in an occupied facility, the contractor must coordinate closely with base operations and adhere to strict safety and security requirements. The project is estimated to be valued between 1,000,000 and 5,000,000 dollars, with a required completion timeframe of 380 calendar days after the award. The contract will be awarded based on the lowest price, and proposals are due by September 21, 2026. Key requirements include compliance with the Buy American Act, the Davis-Bacon Act, and specific bonding requirements for proposals exceeding 150,000 dollars, which include bid, payment, and performance bonds. Deliverables consist of a facility operating plan, comprehensive data packages for system maintenance, and functional performance test reports. Invoicing is managed through the Wide Area WorkFlow system, and the contractor must submit a detailed schedule of prices within 15 calendar days of the award. Quality control is paramount, requiring the submission and acceptance of a Contractor QC Plan before construction begins.

Bristol Alliance of Companies

POSTED

DEADLINE

REPAIR DORMITORY B.464

Solicitation # repair-dormitory-b464

The Repair Dormitory B.464 project, managed by Cooper Tacia General Contracting Company, is a comprehensive construction solicitation located in South Carolina. The scope of work encompasses a wide array of trades, including demolition, cast-in-place concrete, unit masonry, structural steel, and millwork. Additionally, the contract covers waterproofing, glazing, openings, drywall, painting, flooring, and the installation of specialties, fire suppression systems, and full plumbing, mechanical, and electrical services. This opportunity is designated as a set-aside for Women-Owned Small Businesses, HUBZone Small Businesses, Veteran-Owned Small Businesses, and Service-Disabled Veteran-Owned Small Businesses under NAICS code 236220. The solicitation was posted on September 12, 2026, with a response deadline of September 18, 2026. Interested parties may contact Neelesh Vodala for further information regarding the submission process.

COOPER TACIA GENERAL CONTRACTING COMPANY

POSTED

DEADLINE

Cape Cod Space Force Microgrid Power Station - Bourne, MA

Solicitation # cape-cod-space-force-microgrid-power-station-bourne-ma

J&J Contractors, Inc. is seeking bids for the Cape Cod Space Force Microgrid Power Station project located in Bourne, Massachusetts. The scope of work is extensive, covering masonry, structural steel, miscellaneous metals, metal paneling and siding, roofing, drywall, flooring, painting, fire protection, plumbing, mechanical, electrical, and sitework. This solicitation is open to various small business categories, including SDB, WOSB, HUBZone, VOSB, and SDVOSB entities. The project adheres to Davis Bacon Wage Rates and is exempt from sales tax. Interested parties must submit their responses by October 30, 2026. To receive a formal bid invitation through Building Connected, applicants should contact Rahul Maheshwari directly via email.

J&J CONTRACTORS, INC.

POSTED

DEADLINE

AMC-0194 GPT ATCT Public Announcement

Solicitation # amc-0194-gpt-atct-public-announcement

The AMC-0194 GPT ATCT project is a comprehensive facility maintenance and repair contract managed by PTSI Managed Services Inc. (Parsons) located in Mississippi. The scope of work encompasses a wide range of multidisciplinary improvements, including electrical corrections for grounding and SPDS replacement, mechanical repairs for copper piping and chilled water systems, and civil reinforcements such as gate and foundation repairs. Additionally, the project involves structural painting and sealing, as well as architectural updates including floor tile replacement, window caulking, and gutter installation. The estimated magnitude of construction for this solicitation is between 500,000 and 1,000,000 dollars. This opportunity is set aside for various small business categories, including Small Disadvantaged, Women-Owned, HUBZone, and Veteran-Owned Small Businesses. The solicitation was posted on September 12, 2026, with a response deadline of November 18, 2026, under NAICS code 236220.

PTSI Managed Services Inc. (Parsons)

POSTED

DEADLINE

P084 NEXT GENERATION TORPEDO INTEGRATION LAB & P1016 Consolidated RDT&E Systems Facility – Newport, RI

Solicitation # p084-next-generation-torpedo-integration-lab-p1016-consolidated-rdte-systems-facility-newport-ri

J&J Contractors, Inc. is seeking pricing for the construction of the Next Generation Torpedo Integration Lab and the P1016 Consolidated RDT&E Systems Facility in Newport, Rhode Island. The project involves the creation of a 12,920 square foot multi-story steel frame laboratory and office facility, as well as an optional 17,978 square foot laboratory facility. Construction features include shallow foundations, standing-seam roofs, and exterior walls composed of masonry and metal panels. The scope of work is extensive, covering everything from demolition and site preparation, including underground stormwater retention and utilities, to specialized trades such as structural steel, mechanical, electrical, and fire protection. This solicitation is set aside for various small business categories, including SDB, WOSB, HUBZone, and SDVOSB firms. All work must adhere to Davis Bacon Wage Rates and is exempt from sales tax. Interested parties should contact Rahul Maheshwari to receive bid documents via Building Connected. The response deadline for this opportunity is November 30, 2026.

J&J CONTRACTORS, INC.

POSTED

DEADLINE

AMC-0196 HATTIESBURG RCAG FACILITY REPAIR AND REINFORCEMENT Public Announcement

Solicitation # amc-0196-hattiesburg-rcag-facility-repair-reinforcement-public-announcement

This solicitation, managed by PTSI Managed Services Inc. (Parsons), seeks a contractor to perform comprehensive electrical, mechanical, civil, architectural, and structural repairs and reinforcements for the Hattiesburg Remote Communications Air/Ground (RCAG) facility in Mississippi. The scope of work includes critical infrastructure upgrades such as HVAC and roof replacements, grounding improvements, lighting updates, and site access enhancements. The estimated value of the contract is between 250,000 and 500,000 dollars. The opportunity is open to various small business set-asides, including Small Disadvantaged Businesses, Women-Owned Small Businesses, HUBZone, and Veteran-Owned Small Businesses. Interested parties must submit their responses by the deadline of October 9, 2026. The project falls under NAICS code 236220 and is coordinated through the primary point of contact, Kurtis Kinard.

PTSI Managed Services Inc. (Parsons)

POSTED

DEADLINE

South Concourse Evolution (SCE) Bid Package 3

Solicitation # south-concourse-evolution-sce-bid-package-3

The South Concourse Evolution (SCE) Bid Package 3 is a solicitation issued by Hensel Phelps for the Seattle-Tacoma International Airport project in Washington. This opportunity is specifically set aside for Small Disadvantaged Businesses under the 8(a) program, falling under NAICS code 236220. The contract encompasses a wide range of construction and installation scopes, including glass and aluminum systems, vertical transportation, the demolition and installation of passenger loading bridges, masonry, drywall, doors, frames and hardware, miscellaneous metals, firestopping, joint sealants, and paint and epoxy flooring. The solicitation was posted on September 11, 2026, with a response deadline of September 24, 2026. As the General Contractor/Construction Manager, Hensel Phelps requires bidders to adhere to specific bonding and labor agreement requirements. Interested parties must follow the provided bid submission instructions and are encouraged to participate in the scheduled pre-bid meetings and site walks to ensure a comprehensive understanding of the project requirements and budget ranges.

POSTED

DEADLINE

NJCC Bathroom Renovations for Buildings 17 & 18

Solicitation # njcc-bathroom-renovations-buildings-17-18

Education & Training Resources is soliciting bids for a fee-for-service subcontract to perform comprehensive bathroom renovations at the Northlands Job Corps Center in Vergennes, Vermont. The project involves the complete renovation of four bathroom areas in Building 17, totaling approximately 944 square feet, and five bathroom areas in Building 18, totaling approximately 1,260 square feet. The scope of work includes the demolition of existing fixtures and the installation of institutional-grade acrylic or FRP shower pans, vitreous China toilets, high-pressure laminate countertops, non-slip porcelain flooring, and LED lighting. To maintain center operations, contractors must execute the renovations in a phased sequence, completing one dormitory at a time. Bidders may submit a unified proposal for both buildings or standalone bids for each. Proposals must include a detailed bid sheet with a cost breakdown separating materials and labor, a project schedule specifying calendar days and working hours, current Vermont state professional licensing, and certificates of insurance. The winning bidder must maintain an active registration in Sam.gov with a Unique Entity ID. Award selection is based on technical alignment with the scope of work and risk mitigation rather than the lowest bid. The contract requires strict adherence to ADA, OSHA, and NFPA 101 Life Safety codes, as well as compliance with the Davis-Bacon Act and various FAR clauses, including 100 percent performance and payment bonds. Payment terms are net 30 days upon receipt of a proper invoice and final project acceptance, which requires a signed punch list and applicable warranties.

Northlands Job Corps Center /ETR

POSTED

DEADLINE

B221 Substation Switchgear Replacement

Solicitation # b221-substation-switchgear-replacement

The B221 Substation Switchgear Replacement project, managed by Sauer Construction, involves electrical upgrades and architectural improvements located in Texas. This solicitation is open to various small business categories, including Small Disadvantaged, Women-Owned, HUBZone, and Veteran-Owned small businesses, under NAICS code 236220. The opportunity was posted on September 12, 2026, with a response deadline of October 15, 2026. Interested parties can coordinate through the primary point of contact, Adam Houck, via email at jmarques@sauer-inc.com.

Sauer Construction

POSTED

about 10 hours ago

DEADLINE

in about 1 month

AI Contract Overview

The U.S. General Services Administration intends to procure construction services for the modernization of seventeen elevators and the upgrade of mechanical, electrical, and fire protection systems within their machine rooms at the Thurgood Marshall U.S. Courthouse located at 40 Foley Square in New York, NY. The work must be performed while the courthouse remains fully operational, requiring strict scheduling to minimize disruption, with most activities confined to after-business hours and within elevator shaftways. The selected contractor must comply with the Public Buildings Service Interim Core Building Standards and the U.S. Courts Design Guide, ensuring all work aligns with federal security, accessibility, energy efficiency, and environmental requirements. The contract will be awarded on a Firm-Fixed Price basis with a base lump sum and optional line items, with an estimated total value between $20 million and $40 million. The period of performance is approximately fifty months from the notice to proceed. All offerors must maintain an active SAM.gov registration throughout the proposal, award, performance, and payment phases. A bid guarantee of 20% of the bid price, not to exceed $3 million, is required at proposal submission, and upon award, performance and payment bonds equaling 100% of the contract value are mandatory, with failure to secure them rendering a firm ineligible. Compliance with Homeland Security Presidential Directive 12 and FAR 52.204-9 is required for all personnel entering federal space, necessitating Personal Identity Verification credentials. The procurement will follow best value tradeoff procedures under FAR Subparts 15.1 and 15.2, utilizing GSA class deviations, and will not be set aside for any socioeconomic categories. The NAICS code is 236220 with a small business size standard of $45 million in average annual receipts over three years. The solicitation is anticipated to be issued on or about August 3, 2026, with proposals due at least thirty days later via SAM.gov exclusively; no paper submissions or telephone inquiries will be accepted. Specific inspection and performance standards include compliance with the I-Codes, NFPA 70 and 101, ASCE standards for design loads and subsurface utilities, OSHA regulations, and requirements for hazardous material handling, stormwater management, and flood-resistant construction.

General Info

Procure elevator modernization at Thurgood Marshall Courthouse for $20M–$40M under firm-fixed-price, after-hours work, strict compliance, and SAM.gov registration.

Agency

General Services Administration → Pbs Project Delivery Capital Construction - Branch NortheastView Agency

NAICS

236220 - Commercial and Institutional Building ConstructionView NAICS

Place of Performance

New York, NY, 10007, USA

Set-Aside

NONE

Documents

(1)

PBS Interim Core Building Standards Memorandum 24FEB2025

PDF•memorandum

AI Contract Breakdown

Uniform Contract Format

Timeline

PhaseClosed

PostedMar 2

Sources Sought

Type ChangedJul 6

Sources Sought → Presolicitation

Response DeadlineJul 21

Deadline has passed

Submission Closed

07/21/2026, 08:00:00 PM UTC

Find active opportunities like this

Start your free trial to discover similar active contracts, track opportunities, and build proposals with AI assistance.

Organization & Contact Information

AgencyGeneral Services Administration → Pbs Project Delivery Capital Construction - Branch Northeast

Contacts1 person available

OfficeWashington, DC, 20405, USA

Organization / Agency

General Services Administration → Pbs Project Delivery Capital Construction - Branch Northeast

View Agency Profile

Office AddressWashington, DC, 20405, USA

Contacts

Natalia Lugo-Vina Cruz

contact@example.gov

Full Description

THIS IS A SYNOPSIS/PRE-SOLICITATION NOTICE ONLY. This notice is not a request for offers or proposals. This notice does not represent a commitment by the Government to issue a solicitation or award a contract.

The U.S. General Services Administration (GSA), Public Buildings Service, Acquisition Project Delivery – Capital Construction Division, intends to solicit for a highly qualified Contractor who can provide construction services for a project at the Thurgood Marshall U.S. Courthouse, situated at 40 Foley Square in New York, NY. This project will include scope to modernize seventeen (17) elevators, as well as upgrade mechanical, electrical and fire protection equipment within the elevator machine rooms.

The Courthouse will remain fully operational throughout the duration of the project. To ensure minimal disruption to Government operations, the work must be phased to limit interruptions to operations and any disruptive work must be executed after business hours, predominately work taking place within the elevator shaftways. The selected General Contractor will be required to ensure full compliance with the Government’s requirements for access and security. Additionally, the General Contractor will be required to complete this project in accordance with the construction drawings and specifications that will be issued for this project.

The selected General Contractor will be required to ensure full compliance with the Public Buildings Service Interim Core Building Standards, and the U.S. Courts Design Guide.

Contract Type: The contract type for this procurement will be Firm-Fixed price. The line item schedule will include a lump sum item for the Base. There will be option line items for this procurement.

Price: The total magnitude of this project at award is between $20,000,000 and $40,000,000.

Selection and Schedule: This requirement will be competitively procured in accordance with Federal Acquisition Regulation (FAR) 15.1–Source Selection Processes and Techniques ((GSA Class Deviation RFO-2025-15) and FAR 36.101-2 (GSA Class Deviation RFO-2025-36)). The awardee will be competitively chosen using best value tradeoff procedures in accordance with FAR Subparts 15.1 and 15.2 (GSA Class Deviation RFO-2025-15).

The period of performance for the proposed contract will be for approximately fifty (50) months upon issuance of notice to proceed.

NAICS: This procurement will be conducted under North American Industry Classification System (NAICS) Code 236220--Commercial and Institutional Building Construction. The Small Business size standard is an average annual sales and receipts for the past three (3) years that are equal to or less than $45,000,000.

Solicitation Information: GSA anticipates issuing the Solicitation on or about August 3, 2026, with receipt of proposals at a minimum of thirty (30) calendar days later. All information, amendments and questions concerning this solicitation will be electronically posted to the Government-wide Point of Entry at www.SAM.gov. No telephone requests will be accepted and no paper copies will be mailed to prospective offerors.

A bid guarantee (bid bond) will be required at twenty (20) percent of the bid price or $3 million, whichever is less, at the time of proposal submission.

Upon contract award, both the Performance and Payment bonds will be required at 100% of the total contract value. Any firms unable to meet the bond requirements will be ineligible for a contract award.

All offerors are required to have an active registration in the System for Award Management (www.SAM.gov) at the time of offer submission, and shall continue to be registered until time of award, during performance and through final payment of the contract.

In addition, in order for contractors to have access to Federal space, the contractor will be required to adhere to the Homeland Security Presidential Directive 12, Directive Clearance Process, in accordance with FAR 52.204-9 - Personal Identity Verification of Contractor Personnel (JAN 2011) as well as other security clearances that may be required.