Skip to main contentPsst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveFree Webinar — Wednesday, October 28 at 2:00 PM ET

Register Free →

McCall Air Base Apron Replacement-Payette NF

Active
12026119R0001Federal

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

This contract involves the reconstruction of the Forest Service Aircraft Apron at the McCall Smokejumper Base in McCall, Idaho, to support the Fire Aviation Program. The project scope includes removal and replacement of existing pavements, installation of security fencing and gates, construction of additional parking areas, resurfacing of asphalt over aggregate surfaces to mitigate rotor downwash effects, and related site improvements such as seeding and signage. The concrete apron pavement will be installed using a slip form paver. The contract includes a base bid covering the core apron replacement along with several optional work items—ranging from installing security fencing and fuel containment basins to constructing overflow parking, helipad asphalt paving, and multiple parking area enhancements with associated gates and security features. Bidders are required to propose on the base and all option items, with the government reserving the right to award any subset of options. The project is located at the McCall Smokejumper Base Admin site on Forest Service property in Valley County, Idaho, with an estimated project value between $1 million and $5 million. The procurement is a total small business set-aside under NAICS code 237310, with a firm-fixed-price contract anticipated. The contract duration is set for 120 calendar days from an estimated June 1, 2019 start date. Prospective contractors must inspect the site and attend a scheduled site visit, and they are required to register in the System for Award Management. All solicitation documents, including specifications and drawings, are available exclusively through the FedBizOpps website. Wage rates are governed by applicable Department of Labor decisions, ensuring compliance with construction labor standards.

General Info

Reconstruction of aircraft apron, parking, fencing, and site improvements at McCall Smokejumper Base.

NAICS

237310 - Highway, Street, and Bridge Construction

Place of Performance

MCCALL, ID, 83638, USA

Set-Aside

SBA

Documents

20

Determination of Responsibility Letter for McCall Air Base Apron Replacement

DOC, High priority: read this firstdetermination-of-responsibility
High

Amendment__1.pdf

PDF

Amendment__2.pdf

PDF

Amendment__3.pdf

PDF

Amendment__4.pdf

PDF

Attach_1_McCall_Apron_Specs_Final.pdf

PDF

Attach_2_McCall.Airbase.Apron.Replacement.DWG_04.02.2019.pdf

PDF

Attach__3_Wage_Determination.pdf

PDF

Attach_4_DETERMINATION_OF_RESPONSIBILITY_LETTER.pdf

PDF

Attach_5_Past_Performance_Questionnaire.pdf

PDF

Attach_6_Workman%27s_comp_sheet_with_link.pdf

PDF

G2.revised.5.10.2019.pdf

PDF

McCall_Air_Base_Tarmac_Replacement_Project_Questions_%284.25.pdf

PDF

McCall_Air_Base_Tarmac_Replacement_Project_Questions_%284.30.pdf

PDF

McCall_Aire_Base_Tarmac_Replacemnt_Q_and_A_-5-1-19.pdf

PDF

McCall_Apron_specs_FINAL.revised.5.10.2019.pdf

PDF

R0001.pdf

PDF

S1.revised.5.10.2019.pdf

PDF

SIte_Visit_Sign_in_Sheet.pdf

PDF

SOI.revised.5.10.2019.pdf

PDF

AI Contract Breakdown

Uniform Contract Format

Contract not broken down yet

CLEATUS splits the solicitation into Uniform Contract Format (UCF) sections: scope, pricing, deliverables, and evaluation criteria.

Timeline

6 updates
PhaseSolicitation
Posted

Presolicitation

Notice updated

Notice details unchanged. Attachments may have changed.

Notice updated

Notice details unchanged. Attachments may have changed.

Notice updated

Notice details unchanged. Attachments may have changed.

Notice updated

Notice details unchanged. Attachments may have changed.

Notice updated

Notice details unchanged. Attachments may have changed.

Notice updated

Notice details unchanged. Attachments may have changed.

Type Changed

Presolicitation → Solicitation

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more
AgencyDepartment Of Agriculture → Boise National Forest
Contacts1 person available
OfficeBOISE, ID, 83709, USA
Office AddressBOISE, ID, 83709, USA
Contacts
Tanya SpanfellnerContracting Officer

Full Description

Show more
Presolicitation Notice MCCALL AIR BASE APRON REPLACEMENT FAR 52.236-27 -- Site Visit (Construction) (Feb 1995) (a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed. (b) An organized site visit has been scheduled for -- _________November 15, 2018_@ 1000 am___ (c) Participants will meet at -- __MCCALL SMOKEJUMPER BASE PARKING LOT 605 MISSION ST, MCCALL, ID 83638 Respondents may email questions and RSVP to the Site Visit and request A DRAFT COPY of the Specifications and Overall Site Plan, before November 14, 2018 to tspanfellner@fs.fed.us. A. This project consists of reconstructing the Forest Service Aircraft Apron at the McCall Airport in support of the Fire Aviation Program. Additional work at the site includes installing security fencing and gates, constructing additional parking, replacing existing asphalt parking areas, and asphalt pavement over existing aggregate surfacing to limit the effects of rotor downwash. The project also included the removal and disposal of existing pavements and fencing on the site. Apron concrete pavement shall be placed using a slip form paver. B. Base Bid: The base bid work includes the removal of existing apron pavements, full pavement replacement section, tie down installation, paint striping, fence relocation, signing, and seeding. C. Bid Options: 1. Option A: Security Fencing. Work includes removing existing fencing along the south forest service boundary, installing new chain link fencing, removal of an existing roll gate at the Helibase Entrance and installation of an automatic vertical pivot gate with associated key pad. 2. Option B: Fuel Containment Basin. Work includes removal of existing asphalt, construction of concrete fuel containment basin and asphalt repair. 3. Option C: Helipad Asphalt Paving. Work includes placement of asphalt over existing aggregate base material around existing helipads. 4. Option D: Overflow Parking. Work includes the removal of large trees, construction of overflow parking area and access road, culvert installation, construction of asphalt path, installation of man gate with security locks, grading for new landscaped berms, signing, and seeding. 5. Option E: Helibase Parking. Work includes full section construction of additional parking stalls and paint striping, and seeding. 6. Option F: North Smokejumper Access. Work includes removal of existing asphalt surfacing, removal of existing wheel stops, removal of existing culvert, and removal of existing manual slide gate. Work also includes: installation of new culvert, full depth asphalt section installation, paint striping, installation of new automatic slide gate with key pad, signing, and seeding. 7. Option G: Airtanker Base Parking Area and additional Asphalt. Work includes removal of existing culverts, removal of asphalt pavement, removal of wheel stops, removal of gates, and the installation of new culverts, full asphalt pavement section, man gates, automatic slide gate, swing gate, paint striping, signing, and seeding. Option H: North Access Road. Work includes installation of full asphalt pavement section, manual slide gates, signing, and seeding. 8. Option I: Smokejumper Base Parking Area. Work includes pulverization and removal of existing asphalt parking lot, removal of culvert, installation of full asphalt pavement section, installation of culvert, and paint striping. D. The base project and the optional items are identified in the schedule of items. The drawings and specifications provide more definition of the work required under each work item. The Contractor must bid on the base project and all option items. The Government reserves the right to award any and all option items. PROJECT LOCATION E. The project site is located within the McCall Smokejumper Base Admin site, INFRA site No. SO003(McCall Smokejumper Base, McCall Helibase and McCall Retardant Tanker Base reside on this site) located within the City of McCall, Idaho at 605 S. Mission on Forest owned property in T.18N., R.3E., section 16, Boise Meridian (Valley County, ID). The magnitude of proposed project is between $1,000,000 and $5,000,000. Project drawings will be provided as attachments to the Request for Proposal (RFP). Dept. of Labor, Construction Wage Rate General Decision Numbers: ID20170086 shall apply. The complete solicitation package will be attached and made available only through FedBizOpps (FBO) website https://fbo.gov on or around January 2019. Anyone wishing to participate in this proposed procurement must obtain their copy from FBO. Copies will not be mailed from the Contracting Office. All amendments will be posted on FBO. Contractors will be solely responsible for obtaining amendments from this site to update files. This requirement is being solicited as a Small Business set-aside in accordance with Federal Acquisition Regulation (FAR) 19.5, with the intent to award a Firm-Fixed Price contract. A single award will be made from the solicitation. All prospective contractors must be registered in the System for Award Management (SAM) database at http:www.sam/gov/ before award of contract; failure to register in the SAM database may cause your firm to be ineligible for the award and removed from consideration. Estimated Start Date: June 1, 2019, contract time 120 Calendars Days. NAICS: 237310, $36.5M

Similar Contracts

Same NAICS industry code

NAICS: 237310
New
Joliet Job Corps-Request for Quote Parking Lot and Road Repairs
Solicitation # joliet-job-corps-request-quote-parking-lot-road-repairs
Management & Training Corporation (MTC) is seeking bids for a subcontracting opportunity to perform road and parking lot repairs at the Joliet Job Corps Center in Illinois. This fixed-price, single lump sum contract has an estimated value between $100,000 and $250,000. The scope of work includes asphalt pavement replacement covering approximately 62,500 square feet across five key areas, including the guard shack, dorm parking lot, and kitchen/BCT areas. Additionally, the contractor must repair five storm sewer drain structures and five potholes, ensuring all work meets industry standards and proper drainage grades. The project must be completed within 90 consecutive business days following a written Notice to Proceed. Bids will be evaluated based on overall best value, and submission requires a signed MTC Bid for Lump Sum Contract form, a detailed cost breakout on company letterhead, and proof of a mandatory physical site visit. For bids equal to or exceeding $25,000, a bid bond of 20% is required, and the awarded contractor must provide performance and payment bonds from a surety with at least an A- rating. This opportunity is set aside for small businesses, including VOSB, SDVOSB, WOSB, and HUBZone certified firms. Compliance with Construction Wage Rate Requirements (CWRR) is mandatory, requiring weekly certified payroll and adherence to prevailing wage determinations. Final payment is contingent upon a successful final inspection and the submission of operation and maintenance manuals.
Joliet Job Corps

POSTED

about 13 hours ago

DEADLINE

in about 15 hours
View Details
NAICS: 237310
New
SLED
Environmental Trust Department, Owhi Flats 2026
Solicitation # Owhi-Flats-RFB-2026.pdf
The Confederated Tribes of the Colville Reservation Environmental Trust Department is soliciting bids for the Owhi Flats 2026 project, a firm fixed price construction contract focused on watershed restoration within the Little Nespelem WMU. The primary objectives are to improve water quality, enhance riparian habitats, promote natural water flow, and reduce the impact of open-road density on wildlife. The scope of work requires the contractor to decommission six road segments totaling 3.29 miles, install two tank traps, and transport all removed non-natural materials, such as culverts and fencing, to a COR-approved disposal facility. All activities must adhere to specific Colville Indian Reservation Tribal Law and Order Codes regarding cultural resources, forest practices, water quality, hydraulic practices, fire management, and industrial safety, as well as 43 CFR 10.4 for inadvertent discoveries. This is an Indian Preference set-aside under the Tribal Employment Rights Ordinance (TERO), requiring a minimum of 51 percent of seasonal or project-based employees to be of Indian preference origin. Award will be granted to the lowest, responsive, and responsible bidder who demonstrates technical experience in stream crossings, road cross drainage, and bank stabilization. Bidders must submit a comprehensive packet by October 29, 2026, including a signed bid sheet for the entire project, a detailed work plan with equipment and schedules, TERO certification, a debarment form, and proof of liability insurance of at least 1,000,000 dollars. The Contracting Officer Representative (COR) will oversee material acceptance and work plan approval to ensure compliance with environmental and safety standards.
Confederated Tribes of the Colville Reservation

POSTED

about 14 hours ago

DEADLINE

in 8 days
View Details
NAICS: 237310
New
SLED
FY 2027 Asphalt Resurfacing Program
Solicitation # BCFY27-17
The Boone County Fiscal Court is soliciting bids for the FY 2027 Asphalt Resurfacing Program, solicitation number BCFY27-17, to perform milling and paving services on identified county roads and streets. The scope of work includes improving profiles and cross sections using Class 2 Asphalt Surface 0.38D PG64-22, which involves milling existing pavement at a minimum width of six feet from the gutter line, road preparation, and the installation of trackless tack coat. The contractor is also responsible for adjusting manholes, drainage structures, and valve boxes, as well as providing pavement markings and temporary traffic control in accordance with KYTC and MUTCD standards. The project is scheduled for a purchase order issuance on December 1, 2026, with a final completion deadline of June 1, 2027. Eligibility is limited to contractors prequalified by the Kentucky Transportation Cabinet. Bidders must submit an electronic bid bond equal to 5% of the bid, and the successful awardee must provide a surety bond for 100% of the contract amount from a Kentucky-licensed surety. The contract will be awarded to the lowest responsive and responsible bidder, with considerations for Kentucky resident and qualified bidder preferences. Required submittals include a W-9 form, a certificate of insurance, and a Critical Path Method schedule. Performance is subject to strict quality inspections regarding mix design, compaction, and ride quality, with a penalty of 2,500 dollars per day for failure to complete the work by the final deadline.
Public Works

POSTED

about 14 hours ago

DEADLINE

in 21 days
View Details
NAICS: 237310
New
SLED
Main Street Concrete Curbing, Sidewalk, and Driveways.
Solicitation # 27-02
The City of Bartow, Florida, has issued solicitation 27-02 for the Main Street Concrete Curbing, Sidewalk, and Driveways project. This initiative focuses on improving roadway conditions, pedestrian accessibility, and compliance with current standards along Main Street, extending from Highway 60 west to the railroad crossing east of Highway 17. The scope of work includes full roadway repaving and the installation or replacement of concrete curbing, sidewalks, and driveways. All work must adhere to the 2026 FDOT Standard Specifications for Road and Bridge Construction, specifically FDOT Curb and Gutter 300 and Sidewalk 310, as well as MUTCD requirements for traffic management. The successful bidder must provide all labor, materials, equipment, and supervision, including the development of a City-approved Maintenance of Traffic plan and the restoration of all disturbed areas. The contract will be awarded to the lowest responsive and responsible bidder, with preferences afforded to Veteran Business Enterprises and Women/Minority Business Enterprises. Bidders must have been in business under the same name and tax identification number for at least three years. Required submittals include a variety of affidavits and certifications, such as non-collusion, drug-free workplace, and trench safety compliance. Financial security requirements include a bid bond for the submission and performance and payment bonds for contracts exceeding 250,000 dollars. Insurance carriers must maintain an AM Best Rating of A-VII or better. Compensation is based on unit prices applied to actual field measurements, and combined overhead and profit for change orders are capped at 10 percent. Responses are due by November 25, 2026, via the OpenGov portal or in-person delivery to the City of Bartow.
Public Works

POSTED

about 14 hours ago

DEADLINE

in about 1 month
View Details

More opportunities from Department Of Agriculture → Boise National Forest

Same awarding agency

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Miguel
Hillary
Keith Deutsch
Christine

Join 750+ contractors already using CLEATUS