Skip to main contentPsst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveFree Webinar — Wednesday, October 14 at 2:00 PM EDT

Register Free →

This Government Contract opportunity from Department Of The Interior was posted on September 2, 2026. The submission period has ended. Browse the details below for market research, or find similar active opportunities.

Site Electrical Installation

Closed
Federal

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

Active Opportunities Like This One

NAICS: 238210
New
SLED
RFP2026-113 Solar Installation on Tybee Island Marine Science Center
Solicitation # 2026-113
The City of Tybee Island, Georgia, is soliciting proposals under RFP 2026-113 for the installation of a fully functional solar array on the flat roof of the Marine Science Center located at 37 Meddin Drive. The project requires a minimum power output of 42kW, utilizing US-made Q-Cell PV modules with a minimum of 400 Watts per panel and SMA Sunny Boy string inverters. All equipment must be UL certified, and the installation must withstand wind loads of 141 miles per hour while complying with all federal, state, and local building codes. To preserve the existing GAF TPO roof warranty, the contractor must be GAF certified, follow a specific six-step process, and utilize the OMG Power Grip System Plus for structural attachment. Sealed proposals must be submitted to Aleesha Robinson at Tybee Island City Hall by 12:00 PM on November 3, 2026, with a pre-proposal meeting and site visit scheduled for October 13, 2026. A responsive bid must include a comprehensive set of documents, including a bid bond, insurance certificates, an occupational tax certificate, and various affidavits regarding E-Verify, SAVE, and debarment. Award selection is based on merit rather than the lowest price. The successful contractor will be required to provide performance and payment bonds for 100 percent of the total contract amount. Payment terms are net 30, with the city retaining 5 percent of the gross value of completed work until specific project milestones are met.
City of Tybee Island

POSTED

3 days ago

DEADLINE

in 28 days
NAICS: 238210
New
SLED
CI-275 Solano Hall Rm 1201 AV Installation
Solicitation # CI-275
California State University Channel Islands is soliciting bids for Project CI-275, a turnkey audiovisual and control system installation for the Solano Hall FIT Studio Room 1201 in Ventura, California. The project requires a qualified contractor to furnish, install, integrate, program, test, and warrant a system that incorporates an existing 75-inch display and Mac mini with new equipment, including two ceiling array microphones, four pendant speakers, digital signal processing and amplification, a wall-mounted touchpanel, and controllable USB switching. All work must be completed between November 2 and November 6, 2026, with a final operational deadline of 5:00 p.m. on November 6, 2026. The project budget is estimated at 30,000 dollars, and delays beyond the completion date are subject to liquidated damages of 200 dollars per calendar day. This is a Design-Bid-Build project requiring a lump sum base bid submitted electronically via the PlanetBids platform by October 16, 2026, at 2:00 p.m. Pacific Time. Bidders must provide bid security equal to 10 percent of the total bid and maintain all required California contractor licenses. The contract mandates compliance with prevailing wage requirements per California Labor Code sections 1720 to 1815 and requires 3 percent Disabled Veteran Business Enterprise participation. A 5 percent preference is available for qualified small businesses. Award criteria are based on the total lump sum bid, and the successful contractor will be responsible for daily site maintenance and the removal of all construction debris.
CSU, Channel Islands

POSTED

3 days ago

DEADLINE

in 11 days

AI Contract Overview

Show more

This subcontract opportunity, titled Site Electrical Installation, involves performing electrical wiring and infrastructure for prime contractors on USACE site improvement projects. The selected provider will be responsible for installing site electrical systems in accordance with Division 26 specifications to deliver fully energized systems. The project is being managed by the Dsc Contracting Services Division under the Department of the Interior and is designated as a total Small Business Set Aside under NAICS code 238210. Interested parties must submit their responses by September 17, 2026.

General Info

Small business subcontract for USACE site electrical installation, due September 17, 2026.

NAICS

238210 - Electrical Contractors and Other Wiring Installation Contractors

Place of Performance

CO

Set-Aside

SBA

Documents

This scope was carved out of 140P2026R0078.

The full solicitation package (49 documents), including the RFP, is on the prime solicitation, not on this scope.

View the prime solicitation

Y--YELL 326141 YELLOWSTONE MODULAR HOUSING

AI Contract Breakdown

Uniform Contract Format

No documents to break down

The breakdown needs solicitation documents. None were found from this contract's source.

Timeline

PhaseClosed
Posted

subcontract

Response Deadline

Deadline has passed

Submission Closed

Find active opportunities like this

Start your free trial to discover similar active contracts, track opportunities, and build proposals with AI assistance.

Organization & Contact Information

Show more
AgencyDepartment Of The Interior → Dsc Contracting Services Division
ContactsNo contacts available
OfficeN/A
Office AddressN/A
ContactsNo contact information available

Full Description

Show more
Performs electrical wiring and infrastructure for prime contractors on USACE site improvement projects. Installs site electrical systems per Division 26 specifications. Delivers energized site electrical systems.

More opportunities from Department Of The Interior → Dsc Contracting Services Division

Same awarding agency

NAICS: 236220
New
Federal
Z--DENA 332037 Eielson Roof Replacement
Solicitation # 140P2026R0087
Solicitation 140P2026R0087 is a total small business set-aside for the rehabilitation of the Eielson Visitor Center, a remote, off-grid facility located within Denali National Park and Preserve, Alaska. This firm-fixed-price contract, with an estimated value between 5 million and 10 million dollars, encompasses a comprehensive scope of work including the replacement of vegetated and living roof systems, building envelope and waterproofing repairs, interior rehabilitation, and the reconfiguration of renewable energy systems, specifically hydroelectric alternators and energy storage. Additional requirements include selective demolition, microbial remediation, and the rehabilitation of fire suppression sprinkler systems. The project is expected to have a performance period of 442 calendar days from the date of award. The government will utilize the Best Value Continuum Tradeoff Process for award, where non-price factors—including project experience in remote locations, technical approach, management capability, construction schedule, and past performance—are considered significantly more important than price. Contractors must comply with the Davis-Bacon Act for labor rates and adhere to strict environmental standards, including the use of biodegradable packaging and weed-free certification for imported soils. Due to the site's remote nature, proposals must include a detailed narrative on logistics, seasonal constraints, and resource protection. Proposals are due by October 15, 2026, and must be submitted electronically to the National Park Service Denver Service Center.
Commercial and Institutional Building Construction

POSTED

4 days ago

DEADLINE

in 10 days
View Details
NAICS: 237110
New
Federal
Y--BRCA 318695 - CONSTRUCTION
Solicitation # 140P2026B0004
Solicitation 140P2026B0004 is a total small business set-aside invitation for bid issued by the National Park Service for the rehabilitation of the main water system at East Creek and Yovimpa within Bryce Canyon National Park. The project scope includes the installation of new potable water distribution piping, sanitary sewer laterals, and updated water storage tank piping, as well as the decommissioning of obsolete assets. The estimated value of the contract is between 15 million and 20 million dollars, with a performance period running from August 21, 2026, to February 22, 2028. Award will be granted to the lowest responsible bidder who provides pricing for four base line items and seven option line items. The contract requires strict adherence to quality and safety standards, including hydrostatic testing for HDPE piping and compliance with the Americans with Disabilities Act for exterior entry ramps. Contractors must provide bid, performance, and payment bonds, and assign key personnel, including a Quality Control Manager who may also serve as the Site Safety Officer. Payments are processed electronically through the Invoice Processing Platform, requiring a draft submission to the Contracting Officer's Representative seven days prior to final billing. Liquidated damages for construction delays are set at 1,420 dollars per day. Bidders must be registered in the System for Award Management and comply with Davis-Bacon prevailing wage determinations for Garfield and Kane Counties, Utah.
Water and Sewer Line and Related Structures Construction

POSTED

4 days ago

DEADLINE

in 3 days
View Details
NAICS: 237110
New
Federal
Y--Rehabilitation of Water and Wastewater System
Solicitation # 140P2026B0003
Solicitation 140P2026B0003 is a total small business set-aside Invitation for Bid issued by the National Park Service Denver Service Center for the rehabilitation of water and wastewater systems at Curecanti National Recreation Area, Colorado. The project scope involves replacing and upgrading potable water distribution and wastewater collection systems at Elk Creek and Lake Fork, including the refurbishment of septic tanks, leach fields, sewage lagoon liners, pumps, and generators. Key deliverables include the installation of a supervisory control and data acquisition system for remote monitoring and the construction of a potable water truck filling station. The estimated contract value is between 10 million and 15 million dollars, with a performance period extending from July 20, 2026, through October 31, 2028. The contract will be awarded to the lowest responsible bidder based on a combination of five base line items and four option line items. Bidders must provide original bid bonds and maintain comprehensive liability and builder's risk insurance. Technical requirements include strict adherence to OSHA safety standards via a project-specific Accident Prevention Plan, ADA compliance for entry ramps, and specific cybersecurity protocols for facility hardware. Performance is subject to rigorous inspection, including witness testing of control equipment at the contractor's manufacturing facility and the use of qualified testing agencies for on-site quality control. Payment requests must be processed electronically through the Invoice Processing Platform System with required supporting documentation such as pay estimates and current construction schedules.
Water and Sewer Line and Related Structures Construction

POSTED

4 days ago

DEADLINE

in 1 day
View Details
NAICS: 237110
Federal
Y--HAVO 326181 Rehabilitate Rainshed&Water Treatment
Solicitation # 140P2026R0091
Solicitation 140P2026R0091 is an Invitation for Bid issued by the National Park Service Denver Service Center for the rehabilitation of the Rainshed and Water Treatment System at Hawaii Volcanoes National Park. The project involves a comprehensive scope of work including the rehabilitation of the park's rainwater and water treatment systems, the replacement of Building 43 with a new metal building, and the replacement of Building 241 with a new open-air and CMU structure. Additional optional components include the replacement of the 241 SAR Building, further water treatment improvements, perimeter fence replacement, and ground catchment pavement replacement. The contract is a firm-fixed-price agreement with a performance period of 610 calendar days, scheduled from November 1, 2026, to July 3, 2028. The procurement utilizes a best value tradeoff process under FAR Part 15.1, evaluating technical and management factors—such as project experience, technical approach, and construction schedule—alongside proposed pricing. Bids are due by October 23, 2026. The project is subject to the Davis-Bacon Act for prevailing wages and requires bid, performance, and payment bonds. Technical requirements include compliance with ADA standards, Buy American Act and BABA regulations, and specific environmental protections. Site-specific challenges include managing construction phasing to maintain water production and addressing lead-based paint identified in hazardous material surveys. Invoicing must be processed electronically through the Invoice Processing Platform.
Water and Sewer Line and Related Structures Construction

POSTED

8 days ago

DEADLINE

in 18 days
View Details
NAICS: 238990
Federal
Z--NAMA 320066 Rehabilitate WWII Memorial Infrastruct
Solicitation # 140P2026R0108
Solicitation 140P2026R0108, issued by the Department of the Interior's National Park Service Denver Service Center, is a sources-sought notice for a design-build project to rehabilitate infrastructure systems at the WWII Memorial in Washington, D.C. The scope of work involves comprehensive technical improvements, including storm drainage enhancements, granite restoration, fountain waterproofing, and the replacement of MEP systems. Specific technical requirements include the installation of jet grout columns socketed into bedrock at depths of 35 to 50 feet, the implementation of new electrical feeders and lighting control systems, and the integration of Siemens building automation system controllers. The project is scheduled for a period of performance from February 1, 2027, to January 31, 2028. The government is currently conducting market research to determine the acquisition strategy and the potential for a small business or socio-economic set-aside. Interested respondents were required to submit capabilities statements by October 15, 2026. Anticipated contract requirements include bid, performance, and payment bonds, as well as significant insurance coverage for general liability, automobile liability, and accident coverage. Contractors must adhere to strict environmental regulations, including weekly erosion and sediment control inspections and coordination with the District Department of the Environment prior to any land-disturbing activities. Although the solicitation is listed as cancelled, the original framework established a requirement for ADA-compliant installations and strict site safety controls to ensure emergency vehicle access.
All Other Specialty Trade Contractors

POSTED

14 days ago

DEADLINE

in 9 days
View Details

Find Active Opportunities Like This

Get AI-powered intelligence on the opportunities still open

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Miguel
Hillary
Keith Deutsch
Christine

Join 750+ contractors already using CLEATUS