This Solicitation opportunity from Cherokee Nation was posted on July 13, 2026. The submission period has ended. Browse the details below for market research, or find similar active opportunities.

Top

Solicitation A10-05-26-9277- Bid 3- Housing Rehab- Adair County

Closed

Procurement #164753State & Local

Submission Closed07/27/2026, 06:00:00 AM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

Active Opportunities Like This One

NAICS: 236118

New

SLED

Exterior Elevated Elements Repairs - Yucaipa

Solicitation # 20260911008

The Housing Authority of the County of San Bernardino is seeking bids for the Exterior Elevated Elements Repairs project located in Yucaipa, California. This solicitation, identified by number 20260911008, falls under NAICS code 236118 and is managed by the state of California. Interested parties must submit their responses by the deadline of October 6, 2026. Primary points of contact for this opportunity include Rehab Project Coordinator Jesus Medina and Procurement Officer Claudia Nunez.

Housing Authority of the County of San Bernardino (HACSB)

POSTED

DEADLINE

ADA Accessibility Audit and Modification

California Department of General Services

POSTED

DEADLINE

Structural Repair and General Building Maintenance

0411 Aq Hq Contract Augmented

POSTED

DEADLINE

Sector San Diego- UPH - 05 Bathrooms Renovation

Solicitation # 37250PR260000047

Solicitation 37250PR260000047 is a total small business set-aside for the complete renovation of two bathrooms, specifically restrooms C9/C10 and C13/14, located in Building C-2 at USCG Sector San Diego. The scope of work includes lead-safe demolition of existing flooring, fixtures, and partitions, followed by the installation of approximately 240 square feet of heavy-duty waterproof vinyl flooring and new plumbing fixtures, including toilets, urinals, sinks, showers, valves, and flushometers. Additional installations include new toilet partitions, shower pans, mirrors, and dispensers. The project requires a performance period of 60 days from the Notice to Proceed and mandates compliance with Davis-Bacon Act prevailing wage requirements for San Diego County. The contractor must adhere to strict hazardous material policies, including the non-disturbance of wall asbestos-containing materials and compliance with Cal/OSHA Lead in Construction standards, NESHAP, and AHERA regulations. All work must meet local and federal building codes and OSHA safety regulations. Final acceptance is contingent upon a joint walkthrough and the resolution of a government-issued punch list. To enter the facility, personnel must possess REAL ID compliant identification and provide proof of general liability and workers compensation insurance along with all necessary trade licenses. Site visits were scheduled for September 14th, with a response deadline of September 19, 2026.

Base Los Angeles/long BEACH(00037)

POSTED

DEADLINE

Army Family Housing (AFH) Maintenance Services

Solicitation # W91QVN26RAA86

The United States Army 411th Contracting Support Brigade is conducting market research through a Sources Sought Notice for comprehensive maintenance and facility support services for Army Family Housing at USAG Humphreys in the Republic of Korea. This effort, identified by solicitation number W91QVN26RAA86 and NAICS code 236118, seeks vendors capable of providing all personnel, equipment, and supervision for the upkeep of residential facilities and grounds. The scope of work includes scheduled and unscheduled maintenance of HVAC, plumbing, electrical, fire protection, and structural components, as well as elevator and lift system coordination. Additionally, the contractor will be responsible for groundskeeping services such as mowing, fertilizing, and snow removal, and residency management tasks including interior painting and cleaning for change-of-occupancy services. Interested vendors must demonstrate the ability to manage work orders through systems like GFEBS and ArMA and adhere to strict Army regulations, federal laws, and safety codes. A critical requirement is that vendors must be legally authorized to operate within the Republic of Korea and provide evidence of business registration and any applicable Korean government licenses. Responses, which must include a two-page capability statement and detailed experience in facility management and residency services, are due by October 12, 2026. This notice is issued for planning purposes only and does not constitute a formal request for proposals or a commitment to issue a solicitation.

0411 Aq Hq Contract Augmented

POSTED

DEADLINE

Carpentry and Drywall Installation

Cherokee Nation Housing Authority

POSTED

DEADLINE

Solicitation A10-05-26-9215- Housing Rehab- Nowata County

Solicitation # A10-05-26-9215

Solicitation A10-05-26-9215 is a request for bids issued by the Housing Authority of the Cherokee Nation for the rehabilitation of a single-family home located at 506 N Maple St, Nowata, Oklahoma. The scope of work includes comprehensive repairs encompassing carpentry, drywall, electrical, flooring, paint, and plumbing. Specific tasks involve interior wall partitioning in the bathroom, installing metal roof fascia, constructing a treated wood wheelchair ramp with concrete landings, and repairing and refinishing kitchen cabinetry, including the replacement of the sink, faucet, and garbage disposal. Because the property tested positive for lead-based paint, the contractor must adhere to safe work practices and HUD/EPA clearance standards. The contract will be awarded to the responsible bidder providing the lowest responsive bid, with preference given to TERO-certified bidders. The project must be completed within 45 working days, and work is required to commence within two weeks of notification. Failure to meet the end date will result in liquidated damages of 100 dollars per working day. Bidders must comply with the Davis-Bacon Act wage determination OK20260005 and Buy American provisions. Required submittals include a mandatory bid response form, a detailed bid breakdown, Form HUD-5369-A, and proof of TERO certification. Final payment is contingent upon a 100 percent Statement of Completion and approval from the HACN Inspector.

Cherokee Nation Housing Authority

POSTED

DEADLINE

Solicitation A10-09-26-9570- Housing Rehab- Adair County

Solicitation # A10-09-26-9570

The Housing Authority of the Cherokee Nation is soliciting bids for the rehabilitation of a single-family home in Adair County, Oklahoma, under solicitation A10-09-26-9570. The scope of work focuses on carpentry and roofing, including roof replacement and structural repairs to rafters, ceiling joists, and bracing in the kitchen, living room, and bathroom/laundry areas. The project must be completed within 20 working days, with work commencing within two weeks of notification. Failure to meet the completion deadline will result in liquidated damages of 100.00 dollars per working day. Payment will be issued as a single lump sum of 100 percent upon the submission of closing documents and a Statement of Completion approved by a HACN inspector. To be considered responsive and responsible, bidders must submit a fully completed Mandatory Bid Response sheet, a Bid Breakdown sheet, and the Work Write Up by October 1, 2026. Preference will be given to bidders who provide proof of TERO certification through the Cherokee Nation Tribal Employment Rights Office. The contract requires strict adherence to HUD general conditions, the Buy American Act for all iron, steel, and manufactured goods, and Davis-Bacon Wage Rate OK20260005. Additionally, the successful contractor must provide a one-year warranty against faulty materials or workmanship and provide a Certificate of Insurance naming the Housing Authority of the Cherokee Nation of Oklahoma as the certificate holder. Award will be granted to the lowest, most responsive, and responsible bidder.

Cherokee Nation Housing Authority

POSTED

DEADLINE

Solicitation A10-09-26-9599- Housing Rehab- Cherokee County

Solicitation # A10-09-26-9599

Solicitation A10-09-26-9599 is a request for bids issued by the Housing Authority of the Cherokee Nation for the comprehensive rehabilitation of a single-family home located at 15739 W 811 Rd in Tahlequah, Oklahoma. The scope of work encompasses multiple trades, including electrical, plumbing, HVAC, carpentry, concrete, drywall, flooring, painting, and the installation of appliances, sheetmetal, and gutters. Specific tasks include updating kitchen cabinetry, installing vent-a-hoods, replacing interior and exterior doors, and performing electrical upgrades such as GFCI outlets and CO detectors. The project must be completed within 45 working days of the Notice to Proceed, with work beginning within two weeks of notification. Failure to meet the deadline results in liquidated damages of 100 dollars per working day. The contract is awarded to the lowest responsive and responsible bidder, with a strong preference given to TERO certified bidders, Indian Organizations, and Indian Owned Economic Enterprises. Bidders must comply with HUD general conditions, including Form HUD-5369-A and HUD-5370-EZ, and adhere to Davis-Bacon Wage Rate OK20260005. Because the property has tested positive for asbestos-containing materials, contractors must follow NESHAP and OSHA safety standards. Required submittals include a mandatory bid response sheet, work write-up, proof of TERO certification, and various insurance certificates. The contractor must provide a one-year warranty on all labor and materials, and final payment is contingent upon a 100 percent Statement of Completion approved by the HACN Inspector.

Cherokee Nation Housing Authority

POSTED

DEADLINE

Interior Build-out (Offices & Restrooms)

POSTED

DEADLINE

Carpentry & General Building Trades

POSTED

DEADLINE

Residential Rehabilitation - Parker (1704 SW 5th Place)

Solicitation # city-of-ocala-ITB--CHS-260810-2026

The City of Ocala is seeking quotes from Florida-licensed general or building contractors to perform residential rehabilitation work at 1704 SW 5th Place, Ocala, Florida. The selected contractor must provide all necessary labor, materials, and equipment to complete the project in accordance with the Florida Building Code and provided specifications. A non-mandatory pre-bid meeting is scheduled for September 21, 2026, at 10:00 AM EST at the project site. Bidders are required to submit a completed price proposal covering all line items on a lump-sum basis, including all direct and indirect costs. The contract will be awarded to the lowest bidder who meets all specified requirements. All responses must be submitted by the deadline of September 29, 2026. Relevant project documentation includes the scope of work, work write-ups, and asbestos and lead-based paint reports.

City Of Ocala — Purchasing

POSTED

2 days ago

DEADLINE

in 17 days

AI Contract Overview

The Housing Authority of the Cherokee Nation is soliciting bids for the rehabilitation of a single home in Adair County, Oklahoma, with all work to be performed in accordance with a specified work write-up and completed within ten working days. Contractors must begin work within two weeks of receiving notification, or face liquidated damages of $100 per working day for any delay beyond the contracted completion date. To qualify as a responsive and responsible bidder, respondents are required to fully complete both the Mandatory Bid Response sheet and the Work Write Up. Preference will be given to bidders who are TERO certified through the Cherokee Nation Tribal Employment Rights Office, and proof of this certification must be included with all submissions. The successful bidder must fully comply with all applicable Tribal rules and regulations, including TERO requirements, ensuring alignment with the Cherokee Nation's employment and contracting standards.

General Info

Cherokee Nation seeks bids to rehab Oklahoma home in ten days, TERO certification preferred, delays incur $100/day penalties.

Agency

Cherokee Nation Housing AuthorityView Agency

NAICS

236118 - Residential RemodelersView NAICS

Place of Performance

Adair County, OK, USA

Set-Aside

NONE

Documents

(5)

RFB A10-05-26-9277 Roofing Rehabilitation Adair County

PDF•rfb

HUD Representations and Certifications for Bidders

PDF•representations-certifications

164753_Scope_of_Work-_Write_Up_Bid_Document_.pdf

PDF

164753_Driving_Directions_.pdf

PDF

164753_Wage_Rates_OK20260005.pdf

PDF

AI Contract Breakdown

Uniform Contract Format

Timeline

PhaseClosed

PostedJul 13

Solicitation

Response DeadlineJul 27

Deadline has passed

Submission Closed

07/27/2026, 06:00:00 AM UTC

Find active opportunities like this

Start your free trial to discover similar active contracts, track opportunities, and build proposals with AI assistance.

Organization & Contact Information

AgencyCherokee Nation Housing Authority

Contacts1 person available

OfficeN/A

Organization / Agency

Cherokee Nation Housing Authority

View Agency Profile

Office AddressN/A

Contacts

Baylee Scott

contact@example.gov

+1 (555) 000-0000

Full Description

The Housing Authority of the Cherokee Nation is seeking bids from interested parties for the rehabilitation of one home located in Adair County. Work will be completed according to the work write-up. This job must be completed in 10 working days. Work should begin within two weeks of notification or $100.00 will be charged for liquidated damages to the contractor for each working day of extension over the contract end date. To be considered a responsive/responsible bidder, the Mandatory Bid Response sheet and the Work Write Up must be fully completed. To receive preference, bidder must be TERO certified through the Cherokee Nation Tribal Employment Rights Office; proof of certification must accompany submittals. Successful bidder will be obligated to comply with Tribal rules and regulations and TERO.