USCGC REEF SHARK (WPB_87371) DOCKSIDE REPAIRS

NOTICE FOR FILING AGENCY PROTESTS United States Coast Guard Ombudsman Program It is the policy of the United States Coast Guard (USCG) to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time-consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the Government Accountability Office (GAO). Interested parties are encouraged to seek resolution of their concerns within the USCG as an Alternative Dispute Resolution (ADR) forum rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest with the Contracting Officer or Ombudsman. Informal Forum with the Ombudsman. Interested parties who believe a specific USCG procurement is unfair or otherwise defective should first direct their concerns to the applicable Contracting Officer. If the Contracting Officer is unable to satisfy their concerns, interested parties are encouraged to contact the U.S. Coast Guard Ombudsman for Agency Protests. Under this informal process the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting office, Contracting Officer, and solicitation closing date (if applicable). Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the Contracting Officer through open and frank discussions. If the protester's concerns are unresolved, an Independent Review is available by the Ombudsman. The protester may file a formal agency protest to either the Contracting Officer or as an alternative to that, the Ombudsman under the OPAP program. Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for urgent and compelling reasons or is determined in writing to be in the best interest of the Government. The agency's goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth in FAR 33.103(d) (2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. To be timely protests must be filed within the period specified in FAR 33.103(e). Formal protests filed under the OPAP program should be submitted to: COMMANDANT (CG-9131) U S COAST GUARD OMBUDSMAN PROGRAM FOR AGENCY PROTESTS 2100 2ND ST SW STOP 7112 WASHINGTON DC 20593-7112 The Ombudsman Hotline telephone number is +1 (555) 000-0000. COMBINED SYNOPSIS/ SOLICITATION FOR DOCKSIDE REPAIRS FOR USCGC REEF SHARK (WPB-87371) This is a combined synopsis/solicitation for commercial services prepared in accordance with the format in FAR Subpart 12.6, supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotations are being requested and a separate written solicitation will not be issued. The solicitation is issued as a Request for Quotation (RFQ). This solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 2005-65. This requirement is being solicited as a Total Small Business Set-aside using Simplified Acquisition Procedures per FAR Subpart 13. The NAICS Code is 336611, Ship Building and Repairing with a small business size standard of 1,000 employees. The solicitation number is HSCG80-13-Q-P45E60. REQUIRED DOCUMENT Each quoter shall furnish the information required by the solicitation, which includes: 1. Price Schedule filled out with a cost associated with each CLIN 2. Past Performance Documentation 3. Small Business Self Certification 4. Proof of Insurance (Statement of Coverage from current Insurance carrier) 5. Welding certification and Qualifications PLACE OF PERFORMANCE The place of performance will be at the USCGC REEF SHARK (WPB-87371) located at INDUSTRIAL MIAMI, 100 MACARTHUR CAUSEWAY, MIAMI BEACH, FL 33139. ANTICIPATED AWARD DATE The anticipated award date is on or about 01 April 2013, however it is subject to change. The government intends to award a fixed priced contract resulting from this solicitation to the responsible vendor whose complete quote, conforming to the solicitation, provides the best value. Work covered by this solicitation shall be completed within twenty-one (21) calendar days from the date the vessel becomes available to the Contractor. The availability is scheduled to start on or about April 02, 2013 and end on or about April 22, 2013. An arrival conference normally will be held within 48 hours of the scheduled start date. QUESTIONS AND REQUEST FOR DRAWING Drawings are available on CD free of charge upon contractor's request. For questions regarding this solicitation, contact Jaime Smith, Contract Specialist at +1 (555) 000-0000 or contact@example.gov QUOTATION DUE DATE Quotations must arrive no later than 3:00 p.m. EST, Mar 04, 2013. Quotations may be sent via electronic mail (e-mail) to contact@example.gov, or quotations may be sent via the US Postal Service or hand delivered to: USCG Surface Forces Logistics Center, Attn: Jaime Smith, 300 E. Main Street, Suite 600, Norfolk, VA 23510. As per FAR 52.215-5 FACSIMILE PROPOSALS (OCT 1997), vendors may submit facsimile quotes as responses to this solicitation. E-mail and Facsimile proposals are subject to the same rules as paper proposals. The telephone number for receiving facsimiles is +1 (555) 000-0000/4676. DESCRIPTION OF WORK The Contractor shall furnish all necessary labor, material, equipment and such other things as are necessary, except as otherwise specified, to perform dockside repairs and alterations to the vessel, in accordance with this solicitation and attached USCGC REEF SHARK (WPB-87371) Specification for Dockside Repairs 2013, Rev-0 dated 23 January 2013. Failure to read the specifications in their entirety will not relieve the quoter from the responsibility for properly estimating the difficulty or price of successfully performing the work. Failure to do so will be at the quoter's risk. Each quoter shall furnish the information required by the solicitation. PRICING DATA Base Contract Line Item Numbers (CLINs) are marked as "D" for Definitive. Optional CLINs are marked "O" for Optional. Insert unit prices in all CLINs listed in the Schedule unless "NSP" is printed in the Unit Price column for any CLIN. "NSP" in the section means "Not Separately Priced." CLIN D-002, "Travel and Per Diem", is applicable only to Contractors not within the local commuting area (50 miles) of the vessel's location. It is anticipated that any Contractors within the 50 mile commuting area will enter "zero" (0) or "N/A" for the unit and extended price for this CLIN, on the Schedule of Supplies or Services. The place of performance will be at the vessel located at INDUSTRIAL MIAMI, 100 MACARTHUR CAUSEWAY, MIAMI BEACH, FL 33139. ITEM DESCRIPTION UNIT PRICE UNIT QTY EXTENDED PRICE D-001 Main Diesel Engine Assembly, Port and Starboard, Perform W5 Maintenance JOB 1 D-002 Travel and Per Diem JOB 1 O-A Composite Labor Rate Hour 1 D-B GFP Report NSP EA 1 NSP Total Price of Definite Items Total Price of Optional Items Total Price of Definite and Optional Items Inspection and Acceptance is at destination CONTRACT CLAUSES &PROVISIONS (1) 52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS-COMMERCIAL ITEMS (JAN 2013) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.222-50, Combating Trafficking in Persons (FEB 2009) (22 U.S.C. 7104(g)). ___ Alternate I (AUG 2007) of 52.222-50 (22 U.S.C. 7104(g)). (2) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553). (3) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer Check as appropriate.] _X_ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 253g and 10 U.S.C. 2402). ___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)). ___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009). _X_ (4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Aug 2012) (Pub. L. 109-282) (31 U.S.C. 6101 note). ___ (5) 52.204-11, American Recovery and Reinvestment Act-Reporting Requirements (Jul 2010) (Pub. L. 111-5). _X_ (6) 52.209-6, Protecting the Government' Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Dec 2010) (31 U.S.C. 6101 note). ___ (7) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Feb 2012) (41 U.S.C. 2313). ___ (8) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (May 2012) (section 738 of Division C of Public Law 112-74, section 740 of Division C of Pub. L. 111-117, section 743 of Division D of Pub. L. 111-8, and section 745 of Division D of Pub. L. 110-161). ___ (9) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a). ___ (10) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Jan 2011) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a). ___ (11) [Reserved] _X (12) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644). ___ (ii) Alternate I (Nov 2011). ___ (iii) Alternate II (Nov 2011). ___ (13) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644). ___ (ii) Alternate I (Oct 1995) of 52.219-7. ___ (iii) Alternate II (Mar 2004) of 52.219-7. ___ (14) 52.219-8, Utilization of Small Business Concerns (Jan 2011) (15 U.S.C. 637(d)(2) and (3)). ___ (15) (i) 52.219-9, Small Business Subcontracting Plan (Jan 2011) (15 U.S.C. 637 (d)(4).) ___ (ii) Alternate I (Oct 2001) of 52.219-9. ___ (iii) Alternate II (Oct 2001) of 52.219-9. ___ (iv) Alternate III (July 2010) of 52.219-9. _ _ (16) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)). _ _ (17) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)). ___ (18) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). ___ (19) (i) 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns (Oct 2008) (10 U.S.C. 2323) (if the offeror elects to waive the adjustment, it shall so indicate in its offer). ___ (ii) Alternate I (June 2003) of 52.219-23. ___ (20) 52.219-25, Small Disadvantaged Business Participation Program-Disadvantaged Status and Reporting (Dec 2010) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323). ___ (21) 52.219-26, Small Disadvantaged Business Participation Program-Incentive Subcontracting (Oct 2000) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323). ___ (22) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657f). _X_ (23) 52.219-28, Post Award Small Business Program Rerepresentation (Apr 2012) (15 U.S.C. 632(a)(2)). ___ (24) 52.219-29, Notice of Set-Aside for Economically Disadvantaged Women-Owned Small Business (EDWOSB) Concerns (Apr 2012) (15 U.S.C. 637(m)). ___ (25) 52.219-30, Notice of Set-Aside for Women-Owned Small Business (WOSB) Concerns Eligible Under the WOSB Program (Apr 2012) (15 U.S.C. 637(m)). _X_ (26) 52.222-3, Convict Labor (June 2003) (E.O. 11755). _X_ (27) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Mar 2012) (E.O. 13126). _X_ (28) 52.222-21, Prohibition of Segregated Facilities (Feb 1999). _X_ (29) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246). _X_ (30) 52.222-35, Equal Opportunity for Veterans (Sep 2010) (38 U.S.C. 4212). _X_ (31) 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C. 793). _X_ (32) 52.222-37, Employment Reports on Veterans (Sep 2010) (38 U.S.C. 4212). ___ (33) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). ___ (34) 52.222-54, Employment Eligibility Verification (Jul 2012). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) ___ (35) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ___ (36) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b). ___ (37) (i) 52.223-16, IEEE 1680 Standard for the Environmental Assessment of Personal Computer Products (Dec 2007) (E.O. 13423). ___ (ii) Alternate I (Dec 2007) of 52.223-16. _X_ (38) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011). _X_ (39) 52.225-1, Buy American Act--Supplies (Feb 2009) (41 U.S.C. 10a-10d). ___ (40) (i) 52.225-3, Buy American Act--Free Trade Agreements--Israeli Trade Act (May 2012) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, Pub. L. 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, and 112-42). ___ (ii) Alternate I (Mar 2012) of 52.225-3. ___ (iii) Alternate II (Mar 2012) of 52.225-3. ___ (iv) Alternate III (Mar 2012) of 52.225-3. ___ (41) 52.225-5, Trade Agreements (May 2012) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). _X_ (42) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). ___ (43) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150). ___ (44) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). ___ (45) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)). ___ (46) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)). _X_ (47) 52.232-33, Payment by Electronic Funds Transfer-Central Contractor Registration (Oct. 2003) (31 U.S.C. 3332). ___ (48) 52.232-34, Payment by Electronic Funds Transfer-Other Than Central Contractor Registration (May 1999) (31 U.S.C. 3332). ___ (49) 52.232-36, Payment by Third Party (Feb 2010) (31 U.S.C. 3332). ___ (50) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a). ___ (51) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). ___ (ii) Alternate I (Apr 2003) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] ___ (1) 52.222-41, Service Contract Act of 1965 (Nov 2007) (41 U.S.C. 351, et seq.). ___ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 1989) (29 U.S.C. 206 and 41 U.S.C. 351, et seq.). ___ (3) 52.222-43, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Multiple Year and Option Contracts) (Sep 2009) (29 U.S.C.206 and 41 U.S.C. 351, et seq.). ___ (4) 52.222-44, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Sep 2009) (29 U.S.C. 206 and 41 U.S.C. 351, et seq.). ___ (5) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.). ___ (6) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (Feb 2009) (41 U.S.C. 351, et seq.). ___ (7) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247). ___ (8) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008) (31 U.S.C. 5112(p)(1)). (d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)). (ii) 52.219-8, Utilization of Small Business Concerns (Dec 2010) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (iii) [Reserved] (iv) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246). (v) 52.222-35, Equal Opportunity for Veterans (Sep 2010) (38 U.S.C. 4212). (vi) 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C. 793). (vii) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (viii) 52.222-41, Service Contract Act of 1965, (Nov 2007), (41 U.S.C. 351, et seq.) (ix) 52.222-50, Combating Trafficking in Persons (Feb 2009) (22 U.S.C. 7104(g)). ___ Alternate I (Aug 2007) of 52.222-50 (22 U.S.C. 7104(g)). (x) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.) (xi) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (Feb 2009) (41 U.S.C. 351, et seq.) (xii) 52.222-54, Employment Eligibility Verification (Jul 2012). (xiii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (xiv) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (2) While not required, the contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. (End of Clause) (2) FAR 52.211-3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL SPECIFICATION AND STANDARDS AND COMMENRCIAL ITEMS DESCRIPTIONS (JUN 1988) a. Orders for U.S. Coast Guard specification reference drawings must be placed within 10 days of the solicitation issue date. To request drawings, contact the Contract Specialist listed herein. All requests should identify the solicitation number. U.S. Coast Guard specification reference drawings are available in CD-ROM format and are provided free of charge. The CD-ROM(s) contain WINDOWS compliant raster/vector formats (e.g. *.TIF, *.TIF (group4), *.DWG, and *.DWF, etc.). Drawing measurements should be verified by the Contractor prior to ordering materials. (End of Provision) (3) FAR 52.212-2 EVALUATION - COMMERCIAL ITEMS (JAN 1999) QUOTES SHALL BE EVALUATED USING THE FOLLOWING CRITERIA: (a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers: FACTOR 1 - PAST PERFORMANCE: The offeror shall identify at least two (2) but no more than three (3) relevant (construction, overhaul, repair and alteration of ships) and current federal, state or local government or private contracts performed during the last three (3) years. For each contract, list: (a) Contract number and customer point of contact (including two (2) points of contact with telephone numbers) (b) Dollar value of the contract (Original and Final) (c) Type of service performed and whether Prime or subcontractor (d) Required completion date for the contract (e) Date the services were actually completed (f) Ship Name, Hull Number (g) Contract type (FFP, IDIQ, Requirement, Cost Type) (h) Percentage of growth in contract price (Additional work divided by award price) If subcontracting arrangement is proposed, the above data must also be provided for each first tier subcontractor. If a joint effort or teaming arrangement is proposed, highlight previous experience with the proposed team or subcontractor. The past performance evaluation will take into account the guidelines outlined at FAR 15.305(a) (2) Past Performance Evaluation. The Contractor's past performance will be evaluated according to the following factors and questions: Quality of Product or Service Did the customer get what was specified? Did the customer consider the final product high in quality? If warranty issues arose, were they promptly corrected? Schedule Was the contract completed on time? If not, reason why not (growth work, Contractor delayed, government delayed?) Business Relations How was the customer service? Was the Contractor committed to customer satisfaction? Would you use this company again (Why/Why not)? Management of Key Personnel Were subcontracts involved? Comments? In evaluating Contractors past performance, the government intends to also review U.S. Coast Guard Contractor Performance Assessment Reports and other existing past performance ratings on relevant contracts. A quoter without a record of past performance will not be evaluated favorably or unfavorably on past performance. General trends in a Contractor's performance will also be considered. FACTOR 2 - PRICE: Offeror's price shall represent the best price in response to the request for quotes. The price shall be evaluated to determine fairness and reasonableness. ****Past Performance is more important than Price**** Award may be made without any type of discussions or negotiations. This is based on the Contracting Officer's determination after an evaluation has been completed on all offers. (End of FAR 52.212-2) (4) FAR 52.215-20 REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR PRICING DATA (OCT 2010) ALT IV (a) Submission of cost or pricing data is not required (b) If the contracting officer cannot determine price reasonableness either in the initial solicitation or in any change to the contract after award, the contracting officer will require submission information in sufficient detail in order to make such determination. The information may be as follows: REQUEST FOR INFORMAL COST BREAKDOWN In addition to placing your offer in the appropriate place in Schedule of supplies and Prices, it is requested that you provide a breakdown of your costs, to include but not be limited to, those items identified in the sample format below: Trade (i.e. laborers, rigger, etc.) Breakdown of labor grades by trade category Man hours per trade, per labor grade Cost/hour/trade Supplies/materials (description & cost of each) Sub-total Pension Plans Overhead at a rate of ______% Profit at a rate of ________% Total for item _____________ (5) FAR 52.217-7 OPTION FOR INCREASED QUANTITY - SEPARATELY PRICED LINE ITEM (MAR 1989) - VARIATION The Government may require the performance of the numbered line items, identified in the Schedule as option items, at the unit prices stated in the Schedule. The option quantities shown in the Schedule are estimates only. The Government has the right to require performance of these items at the quantities deemed necessary. Therefore, the Government may exercise an option item on more than one occasion during the contract performance period. The Contracting Officer will provide initial notification of the exercise of an option either verbally, by facsimile, or both. When time is of essence initial notification will be provided verbally followed within 24 hours by a facsimile of confirmation. A contract modification will be executed shortly thereafter to include those options wherein exercise notification was provided. Such options may be exercised at any phase during the contract performance period as stated herein, or any extension of the performance period. To maintain the contract performance period the Contractor shall commence performance of an option item immediately upon receiving initial notification; but, not later than 24 hours thereafter, unless proper sequencing of the work requires a delay in beginning performance of the option. In that case, the option item shall be commenced as soon as proper sequencing permits. The exercise of any option item listed in the Schedule will not normally extend the contract performance period. However, the Contracting Officer may consider a request by the Contractor for contract extension if an option is exercised after 50% of the contract performance period has expired. (End of Clause) (6) 52.232-99, PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS (DEVIATION 2012-O0014) (AUG 2012) This clause implements the temporary policy provided by OMB Policy Memorandum M-12-16, Providing Prompt Payment to Small Business Subcontractors, dated July 11, 2012. (a) Upon receipt of accelerated payments from the Government, the contractor is required to make accelerated payments to small business subcontractors to the maximum extent practicable after receipt of a proper invoice and all proper documentation from the small business subcontractor. (b) Include the substance of this clause, including this paragraph (b), in all subcontracts with small business concerns. (c)The acceleration of payments under this clause does not provide any new rights under the Prompt Payment Act. (7) FAR 52.237-1 SITE VISIT (APR 1984) The Request for Quotation (RFQ)/solicitation is for the Dockside Repairs of the USCGC REEF SHARK hereinafter referred to as "vessel". The vessel is located at INDUSTRIAL MIAMI, 100 MACARTHUR CAUSEWAY, MIAMI BEACH, FL 33139. The point of contact for site surveys is MKC Heather Friedrich, who can be reached at +1 (555) 000-0000. The Contract Specialist is Jaime Smith, who can be reached at +1 (555) 000-0000. (8) FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: http://www.arnet.gov/far/index.html FAR 52.211-15 Defense Priority and Allocation Requirements (APR 2008) DO N5 Rating FAR 52.215-5 Facsimile Proposals. (OCT 1997) FAR 52.223-3 Hazardous Material Identification and Material Safety Data (JAN 1997) Alternate I (JUL 1995) FAR 52.228-5 Insurance - Work on a Government Installation (JAN 1997) FAR 52.232-18 Availability of funds (APR 1984) FAR 52.245-1 Government Property (APR 2012) FAR 52.245-9 Use and Charges (APR 2012) HSAR 3052.211-70 Index for Specifications (DEC 2003) HSAR 3052.217-91 Performance (DEC 2003) HSAR 3052.217-92 Inspection and Manner of Doing Work (DEC 2003) HSAR 3052.217-93 Subcontracts (DEC 2003) HSAR 3052.217-95 Liability and Insurance (DEC 2003) HSAR 3052.217-96 Title (DEC 2003) HSAR 3052.217-97 Discharge of liens (DEC 2003) HSAR 3052.217-98 Delays (DEC 2003) HSAR 3052.217-99 Department of Labor Safety and Health Regulations for Ship Repair (DEC 2003) HSAR 3052.217-100 Guarantee (JUN 2006) HSAR 3052.222-70 Strikes or Picketing Affecting Timely Completion of the Contract Work (DEC 2003) HSAR 3052.222-71 Strikes or Picketing Affecting Access to a DHS Facility (DEC 2003) HSAR 3052.223-90 Accident and Fire Reporting (DEC 2003) HSAR 3052.242-71 Dissemination of Contract Information (DEC 2003) HSAR 3052.242-72 Contracting Officer's Technical Representative (DEC 2003) HSAR 3052.245-70 Government Property Reports (AUG 2008) [Deviation]) (9) HSAR 3052.209-70 PROHIBITION ON CONTRACTS WITH CORPORATE EXPATRIATES (JUNE 2006) (a) Prohibitions. Section 835 of the Homeland Security Act, 6 U.S.C. 395, prohibits the Department of Homeland Security from entering into any contract with a foreign incorporated entity which is treated as an inverted domestic corporation as defined in this clause, or with any subsidiary of such an entity. The Secretary shall waive the prohibition with respect to any specific contract if the Secretary determines that the waiver is required in the interest of national security. (b) Definitions. As used in this clause: Expanded Affiliated Group means an affiliated group as defined in section 1504(a) of the Internal Revenue Code of 1986 (without regard to section 150...