Skip to main contentPsst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveFree Webinar — Wednesday, July 22 at 2:00 PM EDT

Register Free →
logo
Get CLEATUSFree Trial

Electronic Health Record Modernization Infrastructure Upgrades - Construction - Togus, ME

Active
36C77626R0062Federal

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

The Department of Veterans Affairs is soliciting proposals for the Electronic Health Record Modernization Infrastructure Upgrades at the Togus VA Medical Center in Augusta, Maine, under solicitation number 36C77626R0062. The project involves comprehensive construction, alterations, and renovations to support the modernization of EHR infrastructure, including electrical system upgrades (power, emergency, bonding, and UPS), HVAC system assessments and modifications, architectural demolition and reconfiguration of existing spaces, and the addition of a new 170-square-foot telecommunications tower building at B200/200E to house ten new telecommunications rooms. Work must be carefully phased to avoid disruption to ongoing medical operations and must comply with detailed construction documents, including architectural drawings, specifications, geotechnical and hazardous materials reports, and design calculations. The contract is a Firm-Fixed-Price agreement requiring full cost loading of all work activities, with pricing submitted via a detailed Division Cost Breakdown. The period of performance is approximately 730 calendar days following the Notice to Proceed, tentatively scheduled for October 1, 2026, with contractors required to submit a revised Critical Path Method schedule within 30 days of award and provide monthly progress updates for payment approval. Proposals must be submitted electronically in three separate volumes—Technical, Price, and Administrative—each as a searchable PDF under five megabytes, limited to specific formatting criteria including Times New Roman 12-point font and page limits. Technical proposals are capped at 40 pages excluding cover and table of contents and must not include any pricing. Contractors must demonstrate technical approach, key personnel qualifications, past performance in similar projects, socioeconomic participation through SDVOSB or VOSB certification, and competitive pricing, with technical factors weighted significantly higher than cost. All contractors must provide Standard Form 24 bid guarantees (up to $3 million), and upon award, performance and payment bonds on SF 25 and SF 25A are required, effective through construction. Compliance is mandated with stringent standards for hazardous materials handling per DOT and IATA regulations, packaging and marking requirements, indoor storage conditions, and data security obligations under 38 U.S.C. 5725, with potential liquidated damages for privacy breaches. Contractors must also adhere to Buy American provisions, construction wage rates under DBA, patent indemnity, anti-kickback procedures, and IT accessibility standards. Monthly payment applications require certification of redlines, RFI and change order logs

General Info

VA awards $50M-$100M fixed-price contract for Togus VAMC EHRM IT infrastructure upgrades, due 2028.

Agency

Department Of Veterans Affairs → Pcac (36C776)View Agency

NAICS

236220 - Commercial and Institutional Building ConstructionView NAICS

Place of Performance

Augusta, ME, 04330, USA

Set-Aside

NONE

Documents

(56)

SOW Attachment 01 Drawing Volume 1A EHRM Infra Upgrades Construction Togus

PDF•sow

SOW Att 10 Specs Vol 4 EHRM Infra Upgrades Togus 02182026

PDF•specifications

SOW Attachment 40 Cut Sheet 18 EHRM Infra Upgrades Constr Togus

PDF•sow

RFP 36C77626R0062 Electronic Health Record Modernization Infrastructure Upgrades

DOCX•rfp

S06+-+Amend+0001+-+RFIs+-+07132026+-+EHRM+Infra+Upgrades+-+Constr+-+Togus.pdf

PDF

SOW Attachment 02 Drawing Volume 1B EHRM Infra Upgrades Construction Togus

PDF•sow

SOW Attachment 27 Cut Sheet 05 EHRM Infra Upgrades Construction Togus

PDF•sow

S02+-+SOW+-+Att+13+-+Const+Sch+-+02132026+-+EHRM+Infra+Upgrades+-+Constr+Togus.pdf

PDF

Past Performance Questionnaire for EHRM Infra Upgrade - Togus

DOCX•past-performance

SOW Attachment 28 Cut Sheet 06 EHRM Infra Upgrades Construction Togus

PDF•sow

S06+-+Amend+0001+-+Att+02+-+SV+-+Attendance+SHT+-+06292026+-+EHRM+Infra+-+Togus.pdf

PDF

SOW Attachment 05 - Demolition and Telecom Plans for EHRM Infra Upgrades

PDF•sow

SOW Attachment 03 Drawings Vol 1C EHRM Infra Upgrades Construction Togus

PDF•sow

EHRM Infrastructure Upgrades Togus ME Level 1 Demolition Plan

PDF•sow

SOW Att 38 Cut Sheet 16 EHRM Infra Upgrades Constr Togus

PDF•sow

VHA Pre-Construction Risk Assessment for EHRM Infrastructure Upgrades Project

PDF•sow

Wage Rates DBA Kennebec Maine EHRM Infra Upgrade 05182026

PDF•wage-determination

SOW Att 14 Design Calculations EHRM Infra Upgrades Togus

PDF•sow

SOW Attachment 32 Cut Sheet EHRM Infra Upgrades Constr Togus

PDF•sow

SOW Att 08 Specs Vol 1 Div 02-14 EHRM Infra Upgrades Togus

PDF•specifications

Geotechnical Report for VA Togus Infrastructure Upgrades

PDF•sow

VAAR 852.219-75 Certification and Limitations on Subcontracting for EHRM Infra Upgrade

PDF•certification

SOW Attachment 20 - PCRA 2 - Cabling and Data Outlets - EHRM Infra Upgrades - Togus

PDF•sow

SOW Attachment 23 Cut Sheet EHRM Infra Upgrades Constr Togus

PDF•sow

S06+-+Amend+0001+-+36C77626R0062+-+07142026+-+EHRM+Infra+-+Togus.pdf

PDF

SOW - EHRM Infrastructure Upgrades - Togus VA Medical Center

PDF•sow

SOW Attachment 41 Cut Sheet 19 EHRM Infra Upgrades Construction

PDF•sow

SOW Attachment 25 Cut Sheet EHRM Infra Upgrades Constr Togus

PDF•sow

Limited Asbestos and Lead Inspection Report - Togus VA Medical Center

PDF•sow

SOW Attachment 37 Cut Sheet 15 EHRM Infra Upgrades Constr

PDF•sow

SOW Attachment 26 Cut Sheet 04 EHRM Infra Upgrades Construction

PDF•sow

SOW Att 29 Cut Sheet 07 EHRM Infra Upgrades Constr Togus

PDF•sow

SOW Att 15 Design Narrative EHRM Infra Upgrades Togus 02182026

PDF•sow

SOW Attachment 33 Cut Sheet 11 EHRM Infra Upgrades Construction

PDF•sow

SOW TS-000 EHRM Infra Upgrades Construction Togus

PDF•sow

S06+-+Amend+0001+-+Att+03+-+SV+-+Agenda+-+RFP+-+06292026+-+EHRM+Infra+-+Togus.pdf

PDF

Division Cost Breakdown - EHRM Infra Upgrade - Togus

XLSX•cost-estimate

Project Information Sheet for Contractors - EHRM Infra Upgrade - Togus

DOCX•past-performance

S06+-+Amend+0001+-+Att+01+-+Rvd+Structural+Drwg+-+06192026+-+EHRM+Infra+-+Togus.pdf

PDF

VHA Pre-Construction Risk Assessment for EHRM Infrastructure Upgrades

PDF•sow

SOW Att 34 Cut Sheet 12 EHRM Infra Upgrades Constr

PDF•sow

SOW Attachment 35 Cut Sheet 13 EHRM Infra Upgrades Construction

PDF•sow

SOW Attachment 04 Drawings Vol 2 EHRM Infra Upgrades Togus

PDF•sow

SOW Att 07 Specs Vol 1 Div 00-01 EHRM Infra Upgrades Togus

PDF•sow

SOW Attachment 30 Cut Sheet EHRM Infra Upgrades Togus

PDF•sow

SOW Attachment 16 Submittal Register for EHRM Infra Upgrades Construction Togus

XLSX•sow-submittal-register

Compliance Letter for Togus VA Medical Center Infrastructure Design

PDF•certification-letter

SOW Att 18 Memo Project Standards Compliance EHRM Infrastructure Upgrades Togus

PDF•sow

SOW Attachment 31 Cut Sheet EHRM Infra Upgrades Construction

PDF•sow

SOW Attachment 36 Cut Sheet 14 EHRM Infra Upgrades Construction

PDF•sow

SOW Attachment 42 Cut Sheet 20 EHRM Infra Upgrades Togus

PDF•sow

SOW Attachment 39 Cut Sheet 17 EHRM Infra Upgrades Constr

PDF•sow

RFP 36C77626R0062 EHRM Infra Upgrade Togus VA Medical Center

PDF•rfp

Justification and Approval for Other Than Full and Open Competition - EHRM Infra Upgrade Togus

PDF•justification-and-authorization

SOW Attachment 24 Cut Sheet 02 EHRM Infra Upgrades Constr Togus

PDF•sow

SOW Att 09 Specs Vol 3 EHRM Infra Upgrades Togus 02182026

PDF•specifications

AI Contract Breakdown

Uniform Contract Format

Sign up to view the full breakdown with detailed analysis of each section.

Timeline

1 update
PhaseSolicitation
Posted

Presolicitation

Type Changed

Presolicitation → Solicitation

Amendment 1

Contract was updated

Response Deadline

Submission deadline

Response Deadline

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more
AgencyDepartment Of Veterans Affairs → Pcac (36C776)
Contacts2 people available
OfficeINDEPENDENCE, OH, 44131, USA
Organization / Agency
Department Of Veterans Affairs → Pcac (36C776)
View Agency Profile
Office AddressINDEPENDENCE, OH, 44131, USA
Contacts
Penhollow Zachary E
contact@example.gov
+1 (555) 000-0000
Joelle M Mascarenas
contact@example.gov
+1 (555) 000-0000

Full Description

Show more

Electronic Health Record Modernization (EHRM) Infrastructure Upgrades - Construction - Togus, ME
Amendment 0001 - Site Visit; RFI's 52.211-12; and 52.211-13

Similar Contracts

Same NAICS industry code

NAICS: 236220
New
SLED
Checkpoint Security Grill Replacement - DBBThe contract anticipates the complete replacement of the Checkpoint 5 security grill at the Port of Seattle, encompassing full design, permitting, and construction services under a design-bid-build delivery method. The scope requires a comprehensive site assessment, development of design drawings and technical specifications that adhere to TSA CRPG Section 3-5 standards, and submission for regulatory review and permit acquisition. The project includes the safe removal and proper disposal of the existing grill, followed by the fabrication and installation of a new system that must be seamlessly integrated with existing structural, electrical, and security badge access infrastructure. All work must be coordinated with relevant stakeholders to ensure strict compliance with security protocols and to minimize disruption to airport operations. The contracting entity is the Aviation Project Management Group under the Port of Seattle, with the project classified under NAICS code 236220 for commercial and institutional building construction. While the solicitation number is not provided, the forecast was posted on July 18, 2026, and will be managed by Yanet Maldonado as the primary point of contact and Collette Deardorff as the project manager. The work is to be performed at Checkpoint 5 within the Port of Seattle facility, requiring close collaboration with aviation and security personnel to maintain operational continuity throughout the project lifecycle. Contractors will be expected to demonstrate experience with high-security aviation infrastructure and regulatory compliance in a live operational environment.
Aviation Project Management Group

POSTED

about 3 hours ago

DEADLINE

N/A
View Details
NAICS: 236220
New
SLED
Rental Car Facility (RCF) Customer Service Building (CSB) Re-DemisingThe Rental Car Facility Customer Service Building Re-Demising project involves comprehensive renovations to support a new Concession Agreement and facilitate tenant construction beginning June 1, 2027. Scope includes updating wayfinding signage to reflect new tenant layouts, constructing a new break room and flex space for transit operations, renovating existing restrooms in the Customer Service Building, replacing outdated car wash equipment in Quick Turn Around areas, and replacing expansion joints on the 5th Floor plaza. Structural repairs are also required to address cracking and repair post-tension cables to ensure long-term integrity. The work is being managed by the Port of Seattle’s Aviation Project Management Group with primary contact Angela Peterson and Project Manager Julia Ruzon. The project is classified under NAICS code 236220 for commercial building construction and is currently listed as a forecast with no set-aside details provided.
Aviation Project Management Group

POSTED

about 3 hours ago

DEADLINE

N/A
View Details
NAICS: 236220
New
SLED
CM/GC for New TSD District OfficeTimpanogos School District is seeking a Construction Manager/General Contractor to deliver services for the construction of a new central administrative office in Lindon, Utah, to serve as the district’s headquarters. The contract will be awarded to the most qualified and responsive offeror based on a scoring system aligned with state procurement code, with the solicitation number TSD07302026 required on all submissions. The closing date for proposals is Thursday, July 30, 2026, at 2:00 PM Mountain Time, and it is the offeror’s responsibility to ensure timely submission. The project is scheduled to begin construction in October 2026 and is expected to be completed by June 2027, with the contract duration spanning the entire lifecycle of the project. Alpine School District’s Department of Purchasing is the issuing procurement unit, while Timpanogos School District’s Physical Facilities Department is the conducting unit overseeing the process. All communication and documentation must reference the official solicitation number and be directed to the designated point of contact, Heath Mills, at hmills@alpinedistrict.org.
Utah

POSTED

about 14 hours ago

DEADLINE

in 12 days
View Details
NAICS: 236220
New
SLED
General Construction ManagementThe contract titled General Construction Management requires oversight of project execution, coordination of subcontractors, and delivery of all work in strict accordance with contract documents. The scope centers on managing construction activities to ensure alignment with established plans and standards, with emphasis on seamless collaboration among multiple parties to meet project objectives. This subcontract is issued under NAICS code 236220, which classifies it within the commercial and institutional building construction sector, and is managed by the Community Development agency in Michigan. The solicitation was posted on July 17, 2026, with a response deadline of July 30, 2026, at 1:00 PM, and the place of performance is not specified beyond the state level. All work must be conducted in compliance with the contractual requirements, and the point of contact details are not provided in the available data.
Community Development

POSTED

about 19 hours ago

DEADLINE

in 12 days
View Details
NAICS: 236220
New
SLED
General Contracting for Building RemodelingThe contract is for general contracting services related to building remodeling, with a focus on comprehensive project management including regulatory compliance, coordination of subcontractors, and end-to-end execution of retrofit and renovation work. The NAICS code 236220 indicates the work falls under commercial and institutional building construction, requiring expertise in structural modifications, safety standards, and seamless integration of modern systems. The contract is classified as a subcontract and is being managed under the Finance agency in Arizona, with all work performance expected to occur within the state. Proposals are due by August 18, 2026, and interested parties must respond through the designated online portal by the specified deadline to be considered.
Finance

POSTED

about 19 hours ago

DEADLINE

in about 1 month
View Details
NAICS: 236220
New
SLED
General Construction ManagementThe contract entails comprehensive construction management services for a project in Florida, requiring full oversight of all phases including scheduling, quality assurance, safety compliance, and coordination of subcontractors. The work is classified under NAICS code 236220, indicating it involves commercial and institutional building construction services, and is structured as a subcontract allowing qualified firms to bid on supporting roles within the larger construction effort. Performance is expected to occur within the state of Florida though specific location details are not provided, and all activities must adhere to strict standards of execution, timeline adherence, and regulatory compliance. The solicitation was posted on July 17, 2026, with responses due by August 31, 2026, leaving bidders approximately six weeks to prepare and submit proposals. There is no set-aside designation specified, meaning the opportunity is open to all eligible entities regardless of business size or ownership characteristics. The contracting authority is listed as Procurement under the Florida agency, though no point of contact or physical address is provided. All relevant information and submission logistics can be accessed through the provided official portal link.
Procurement

POSTED

about 22 hours ago

DEADLINE

in about 1 month
View Details
NAICS: 236220
New
SLED
Collier Senior Center Expansion ProjectThe Collier Senior Center Expansion Project aims to increase capacity at the existing facility to better serve the growing senior population in Collier County, Florida, by expanding into the adjacent Golden Gate Library space, creating a more integrated hub for senior services. The center currently operates critical community programs including a daily hot lunch, job placement and training for low-income seniors, a weekly food pantry, and serves as a post-emergency recovery center. The expansion will address aging infrastructure and increased demand, enhancing the delivery of services for seniors and their caregivers. The solicitation, issued by Collier County’s Procurement Services Division and publicly posted on July 17, 2026, with a response deadline of August 31, 2026, seeks a contractor to execute the full scope of work under a lowest price technically acceptable (LPTA) evaluation model, prioritizing price while ensuring technical responsiveness and responsibility. The contract requires compliance with Florida statutes, including domestic steel sourcing requirements and prohibitions on conducting business in sanctioned countries or participating in the boycott of Israel, with false certifications subject to immediate termination. The work involves constructing and renovating the facility in strict accordance with technical specifications, standard details, and environmental health and safety requirements, with delivery and performance tied to the project site in East Naples, Florida. Contract administration mandates adherence to detailed packaging and marking protocols, including consecutive container numbering and clear display of the Purchase Order number on all shipments, with the County retaining the right to reject non-compliant deliveries. Payment processing will follow internal Application for Payment forms rather than federal systems like WAWF, and financial tracking includes retainage provisions, though no federal accounting codes are specified. Contractors must secure comprehensive insurance with Collier County named as an additional insured, maintain E-Verify enrollment for all hires, and submit bonds, as-built drawings, warranties, and operational documentation. Final acceptance requires resolution of all punch list items, regulatory permits, and occupancy certifications, with deadlines for final completion set at 30 or 45 calendar days based on contract value. The County reserves the right to issue emergency work directives, with formal change orders to follow within 30 days. All proposals must be submitted electronically through the county’s online procurement portal, with no paper submissions permitted, and deviations from prescribed forms may result in disqualification.
Procurement

POSTED

about 22 hours ago

DEADLINE

in about 1 month
View Details
NAICS: 236220
New
Federal
W50S8126RA010The 104th Fighter Wing is seeking vendor proposals to repair and renovate Building 25, a approximately 25,000 square foot facility at Barnes Air National Guard Base in Westfield, Massachusetts, under solicitation number W50S8126RA010. The project, designated as Project AXQD232620, falls under NAICS code 236220 for commercial and institutional building construction and does not utilize any set-aside provisions. The solicitation was posted on June 26, 2026, with a response deadline of July 21, 2026, at 2:00 PM Eastern Time. A mandatory site visit was added to the documentation on the same date as the posting, and details can be found via the PIEE link provided in the solicitation. The work is to be performed at the base located in Westfield, Massachusetts, with the U.S. Air Force’s W7NE Uspfo Activity Maang 104 managing the procurement. Primary point of contact is SMSgt Freeman Knowlton, reachable at freeman.knowlton.1@us.af.mil, with TSgt Kristen Phipps as the secondary contact at kristen.phipps@us.af.mil. All submissions and inquiries should be directed through the SAM.gov portal linked in the solicitation.
W7NE Uspfo Activity Maang 104

POSTED

about 22 hours ago

DEADLINE

in 9 days
View Details
NAICS: 236220
New
Federal
Z--NIFC 100-ADM RepairsThe National Interagency Fire Center is seeking proposals under solicitation 140L0626R0002 for comprehensive repairs and upgrades to its Administration Building located in Boise, Idaho, under a Total Small Business Set-Aside. The scope includes demolition, renovation, and addition of new stair towers, with significant work involving the removal, modification, and installation of VRF equipment, along with extensive electrical, mechanical, communications, and safety system upgrades. The project is governed by detailed specifications spanning over 500 pages and architectural drawings totaling 67 pages, which mandate strict adherence to construction standards, labeling protocols per NEMA Z535 and UL 969, voltage color-coding requirements, and compliance with ASME A13.1 for piping. All work must align with the 95% Design Development Specifications issued in October 2025 and must be executed while minimizing disruption to ongoing federal operations within the NIFC campus. The contract requires a firm fixed-price structure with performance to begin within 10 calendar days of award and be completed within 180 days. Pricing is to be submitted via SF1442 with a lump-sum structure covering mobilization, demolition, and construction, with no government-provided estimated value. Proposals must include extensive documentation, including a technical approach, experience summary, schedule with critical path analysis, and past performance records, evaluated on a best-value continuum where price accounts for 50% of the award criteria and the remaining 50% is equally distributed among experience, technical approach, schedule, and past performance. Offerors must comply with stringent limitations on subcontracting, requiring at least 15% self-performance, and must provide 100% performance and payment bonds as well as a 20% bid guarantee. The contract enforces federal labor standards including a minimum wage of $15.00 per hour under Executive Order 14026, compliance with the Davis-Bacon Act, and requirements for employment eligibility verification, whistleblower protections, and anti-kickback procedures. All submissions must be sent electronically in PDF and Excel formats within a 20 MB file limit, following strict naming conventions and volume formatting. Final payment requires submission of payrolls, subcontractor payment substantiation, the limitations on subcontracting worksheet, and a release of claims, with invoicing conducted exclusively through the Treasury’s IPP portal.
National Interagency Fire Center

POSTED

about 22 hours ago

DEADLINE

in 20 days
View Details
NAICS: 236220
New
Federal
Y1DZ--556-23-104 CON: Chilled Water Piping from Bldg.188 to Bldg.3This solicitation, Amendment 0004 to IFB Solicitation No. 36C25226B0027, is a sealed bid for the construction of chilled water piping from Building 188 to Buildings 1, 3, and 48 at the Captain James A. Lovell Federal Health Care Center in North Chicago, Illinois. The project, identified as 556-23-104, requires the provision of all tools, labor, and materials to complete a fully functional system in compliance with VHA Master Specifications Divisions 00–48 and referenced sections covering sustainable design, firestopping, plumbing, boiler plant, and HVAC common work results. Work must adhere to detailed packaging and marking standards, including delivery in original manufacturer-sealed packaging with legible labeling for manufacturer, type, color, production run, and manufacture date, with prohibited use of damaged or opened containers. The contract mandates strict adherence to safety protocols per USACE EM 385-1-1, requiring a dedicated Site Safety and Health Officer separate from supervisory roles, certified Competent Persons for asbestos, electrical, crane, demolition, fall protection, and other hazards, along with comprehensive safety documentation including a signed safety policy, Activity Hazard Analyses, and site-specific orientation training for all personnel. The acquisition is exclusively reserved for certified Service-Disabled Veteran-Owned Small Businesses (SDVOSBs), with eligibility contingent upon verification in the SBA certification database and mandatory completion of the VAAR 852.219-75 Certificate of Compliance for Subcontracting Limitations, for which a deviation has been permitted. All offerors must maintain current registration in the System for Award Management (SAM), including annual updates to Online Representation and Certifications Application (ORCA), and must submit electronic bids via SAM.gov using PDF format with searchable, editable text and disabled security restrictions. Bids require a guarantee of at least 20% of the bid amount, not to exceed $3 million, and, if awarded, the contractor must furnish Performance and Payment Bonds on SF-25 and SF-25A forms equal to the full contract value. Performance must be completed within 360 calendar days after Notice to Proceed, with milestones defined for submittal reviews, mobilization, demolition, construction completion, and closeout. The estimated contract value ranges between $2 million and $5 million, with payment processed electronically through the VA’s EIPPS system
252-NETWORK Contract Office 12 (36C252)

POSTED

about 22 hours ago

DEADLINE

in 5 days
View Details
NAICS: 236220
New
Federal
Misawa AB - Membrane Storage Shelters - Design-BuildThe 356th ETSG Contracting Office is preparing to solicit two separate design-build projects at Misawa Air Base in Aomori Prefecture, Japan, with a formal solicitation expected to be released on 4 August 2026. Although the solicitation will consolidate both projects into a single posting, two distinct awards will be made—one for Site 1 (C-1) with an estimated budget between $1,000,000 and $5,000,000, and another for Site 2 (A-1) ranging between $3,000,000 and $7,000,000. Offerors may bid on one or both sites, but each will be awarded independently. A mandatory pre-solicitation site visit is scheduled for 3 August 2026 at 0900 JST at the Misawa Air Base Visitor Control Center, and all participants must submit an attendee list with full names, driver’s license copies, and vehicle details by 30 July 2026 at 0900 JST to the designated points of contact. No additional site visits will be held after the formal solicitation is posted. All questions must be directed to the primary and secondary points of contact, with responses provided within two business days and posted to SAM when relevant. The NAICS code for this effort is 236220, and there is no set-aside designation.
FA5025 356 Eceg Pk

POSTED

about 22 hours ago

DEADLINE

in 14 days
View Details
NAICS: 236220
New
Federal
Z2JZ--Upgrade Transitional Rehabilitation (TR) House Bathrooms IFB# 36C26326B0023, PN: 636-24-505 Grand Island VA Medical Center, Grand Island, Nebraska
Network Contract Office 23 (36C263)

POSTED

about 22 hours ago

DEADLINE

N/A
View Details

More opportunities from Department Of Veterans Affairs → Pcac (36C776)

Same awarding agency

NAICS: 236220
New
Federal
Z1DA--646A4-22-700 | EHRM Infrastructure Upgrades | Pittsburgh-Heinz, PAThis contract solicitation, identified as 36C77626R0071, is a Service-Disabled Veteran-Owned Small Business (SDVOSBC) set-aside for EHRM Infrastructure Upgrades at the VA Pittsburgh Healthcare System’s H.J. Heinz III Campus in Pittsburgh, Pennsylvania. The project, designated as 646A-22-700, requires comprehensive construction and system upgrades to support the Electronic Health Records Modernization initiative, including telecommunications infrastructure such as bonding busbars, cable trays, and network cabinets; HVAC systems like computer-room air conditioners, ductwork, refrigerant and hydronic piping with testing and commissioning; and electrical and security systems including fire detection, alarm systems, and electronic safety controls. All work must comply with Division 27 standards, VA Infrastructure Standards for Telecommunications Spaces, NFPA 70, ANSI/TIA-606-C, and specific VAAR and FAR clauses, including 52.236-5 and 852.236-91. The contract enforces strict material handling requirements: all hardware and paint must be delivered in original sealed containers labeled with manufacturer details, catalog numbers, project number, batch codes, and safety instructions; adhesives must be maintained in original packaging under manufacturer-specified ambient conditions; and all instrumentation and cabling must be permanently labeled according to industry standards. The evaluation method is Lowest Price Technically Acceptable (LPTA), with technical qualifications serving as a pass/fail gate—offers must demonstrate the ability to meet all minimum requirements to be considered, after which award will be made to the lowest-priced acceptable offer. The contract mandates a lump sum price for Line Item 0001 in whole dollar amounts, submitted via three separately emailed volumes: a 30-page technical proposal, a 20-page price proposal with SF-1442 and SF-24 bid guarantee, and an administrative volume. Proposals must be submitted electronically by August 3, 2026, to designated VA email addresses, with hard copies rejected. The prime contractor must provide four hours of manufacturer-led training for VA personnel, comprehensive operating and maintenance manuals, and comply with stringent testing protocols for security systems, including field and factory performance verification witnessed by the COTR. Bonding requirements include Performance and Payment Bonds under FAR 52.228-15, with premium adjustments available under VAAR 852
Commercial and Institutional Building Construction

POSTED

about 22 hours ago

DEADLINE

in 16 days
View Details
NAICS: 236220
New
Federal
Construct ERHM Infrastructure Upgrades - University Drive - Pittsburgh, PAThe contract, titled Construct ERHM Infrastructure Upgrades - University Drive - Pittsburgh, PA, with solicitation number 36C77626R0082_1, is a Firm Fixed Price solicitation issued by the Department of Veterans Affairs through the Program Contracting Activity Central in Independence, Ohio, for infrastructure modifications across multiple buildings on the VAPHS University Drive campus to support the Electronic Health Records Modernization system. The scope involves construction work on Buildings 1, 5, 8, 29, 30, 33, and associated site areas, encompassing approximately 3,030 square feet of existing space and 11,600 square feet of new tower additions, including structural renovations, reconfigurations, new walls, doors, finishes, and upgrades to telecommunication closets. The work includes furnishing and installing comprehensive electronic systems such as security hardware, physical access controls, communications transmission equipment, data transmission media, local processors, video and signal transmission systems, and a fully commissioned Electronic Safety and Security cabling system with integrated networks, CCTV, intercoms, and time synchronization. All new building controllers must be native BACnet and capable of stand-alone operation, with strict documentation requirements including riser diagrams, LAN routing plans, O&M manuals matching construction documents verbatim, and a digitally archived system in a common desktop-readable format. The contract mandates delivery of all materials in sealed manufacturer containers bearing clear labeling of manufacturer name, product type, batch number, instructions, and safety precautions, with supplemental labeling for federal specifications and application surfaces. Lumber must bear grade marks, ceiling grid labels must meet specific UV-resistant polyester dimensions and color requirements, and valve lists must be on 8.5 x 11-inch punched plastic-coated cards. Performance is governed by a 730-calendar-day timeline from Notice to Proceed, with strict adherence to a detailed project schedule including fabrication, delivery, installation, and testing milestones. The evaluation method is Lowest Price Technically Acceptable, requiring offerors to pass critical gates including demonstrating at least two but no more than five comparable prior construction projects, submitting a complete small business subcontracting plan if applicable, and maintaining active SAM registration. Submission requires three separate PDF volumes—Technical, Price, and Administrative—emailed to designated addresses with strict formatting: Times New Roman 12-point font, 1-inch margins, 30-page limit for Technical, 20-page limit for Price, each under 5MB,
Commercial and Institutional Building Construction

POSTED

about 22 hours ago

DEADLINE

in 10 days
View Details
NAICS: 236220
New
Federal
Y1DZ--EHRM Infrastructure Upgrades Tier 1 Construction 695-21-700 MilwaukeeThe contract for the EHRM Infrastructure Tier 1 Construction Project at the Clement J. Zablocki VA Medical Center in Milwaukee, Wisconsin, is a Service-Disabled Veteran-Owned Small Business (SDVOSB) set-aside under NAICS code 236220, with a total estimated value between $50 million and $100 million. The project encompasses a comprehensive range of construction and infrastructure upgrades across the entire VA campus, including electrical and HVAC system enhancements, fiber optic and communication network upgrades, physical security improvements, hazardous material abatement, building demolition, and the installation of a fully functional, stand-alone capable controls system. All work must be executed in phased sequences coordinated with VA personnel, including the Construction Period Services Architect/Engineer, Commissioning Agent, VA Shops, and OIT staff, with strict adherence to day and off-shift scheduling for demolition and telecommunications room activities. The contract requires a firm fixed-price structure with lump sum pricing for both design and construction components, submitted in whole dollar amounts, and a detailed division cost breakdown as specified in Attachment 3. Performance is expected to begin within ten calendar days of notice to proceed and complete within 1,460 calendar days. Proposals must be submitted exclusively via email in three separately transmitted volumes—Technical, Price, and Administrative—with each volume not exceeding twenty-five pages in Times New Roman, 12-point, single-spaced format, and must be searchable PDFs under five megabytes. All offerors must be certified by the SBA as SDVOSBs at the time of submission and award, with failure to meet this criterion resulting in automatic disqualification. Evaluation is based on a best-value trade-off approach where past performance, technical approach, project team qualifications, and phasing narrative collectively outweigh price considerations. Technical requirements include strict adherence to packaging, labeling, and quality control standards for materials, with all products required to be delivered in original sealed packaging and inspected prior to installation. Contractors must comply with extensive administrative and security protocols, including annual IT security training, Rules of Behavior compliance, personal identity verification for personnel, and submission of monthly progress reports, safety documentation, and photographic milestones to facilitate payment through VA’s electronic invoice system using AIA G702/G703 forms. Additionally, bonding, insurance, Buy American compliance, and adherence to federal and VA information security policies are mandatory, with any violations of confidentiality or security provisions permitting contract termination or payment withholding.
Commercial and Institutional Building Construction

POSTED

about 22 hours ago

DEADLINE

in 12 days
View Details
NAICS: 541614
New
Federal
Q702--San Diego Research and Development Facility Initial Outfitting, Transition, and Activation ServicesThe Department of Veterans Affairs Veterans Health Administration plans to issue a firm-fixed-price contract for Initial Outfitting Transition and Activation (IOTA) Services to support the activation of the new San Diego Research & Development Facility. This facility, spanning approximately 44,000 net usable square feet and including 100 parking spaces, represents a significant expansion to the VA San Diego Healthcare System’s capabilities for Veteran Healthcare Research & Development. The contract period is expected to last 35 months and aims to provide the necessary contractor services to help facilitate the launch and operational readiness of the new facility. This procurement is classified as a 100% Service-Disabled Veteran-Owned Small Business (SDVOSB) set-aside, consistent with the VA’s Veterans First Contracting Program, and will be conducted under FAR Parts 12 and 37. Eligible bidders must be verified by the VA as an SDVOSB and meet the applicable small business size standard for NAICS code 541614. The solicitation is anticipated to be posted around May 15, 2026, with a close date tentatively set for June 8, 2026, though these dates may change. Interested parties are encouraged to prepare for potentially truncated response times and are directed to submit any questions via email to the designated Contracting Officer, Kathleen Klotzbach.
Process, Physical Distribution, and Logistics Consulting Services

POSTED

2 days ago

DEADLINE

in about 1 month
View Details
NAICS: 236220
New
Federal
Y1DA--573-21-106 EHRM Infrastructure Upgrades and Data Center Construction - Gainesville VAMCThe Department of Veterans Affairs, through its Program Contracting Activity Central, is soliciting bids for the design-bid-build EHRM Infrastructure Upgrades and Data Center Construction project at the Malcolm Randall VA Medical Center in Gainesville, Florida. This procurement is issued as an Invitation for Bids (IFB) under FAR Part 14 and is exclusively reserved for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), with offers from non-SDVOSB entities automatically disqualified. The contract will be awarded on a firm-fixed-price basis, with an estimated value between $20 million and $50 million, and a performance period of approximately 921 calendar days from the notice to proceed. The scope of work includes demolishing an existing temporary trailer and constructing a new one-story data center building, approximately 3,931 square feet in footprint, housing a 1,177 square foot primary data center room, an entrance room, storage and staging areas, mechanical and electrical support spaces, and a separate generator room. Concurrently, all existing telecommunications infrastructure across the campus will be removed, and 59 telecom rooms — some reused and others newly designed — will be upgraded with new enclosures and cabling. The entire medical campus will remain fully operational during construction, requiring meticulous coordination of room closures, shutdowns, and scheduled off-hour work for critical spaces with the Contracting Officer’s Representative. The project is classified under NAICS code 236220 with a size standard of $45 million, and all responses must be submitted electronically via SAM.gov by the deadline of September 1, 2026. Proposals must originate from verified SDVOSB concerns, and all inquiries must be submitted in writing to the designated contract specialist; telephone inquiries will not be accepted. The award is expected in late September 2026, with work to commence shortly thereafter in Gainesville, Florida.
Commercial and Institutional Building Construction

POSTED

3 days ago

DEADLINE

in about 2 months
View Details
NAICS: 221210
New
Federal
Z2DA--Notice of Intent to Sole Source VISN 22 Phoenix UESC Phase 2The Department of Veterans Affairs plans to award a sole-source, firm-fixed-price task order to Southwest Gas Corporation for Phase 2 of the Utility Energy Services Contract at the Carl T. Hayden VA Medical Center in Phoenix, Arizona. This phase follows the completion of an Investment Grade Audit in Phase 1 and will encompass engineering, construction, commissioning, and an 11-year Measurement and Verification period for a suite of energy conservation measures, including boiler and chiller replacements, heat recovery systems, lighting retrofits, building automation upgrades, steam trap and insulation improvements, water conservation fixtures, cooling tower enhancements, and solar photovoltaic system replacements. The implementation period is estimated at 33 months, with funding derived from a hybrid model combining VA non-recurring maintenance funds and utility-arranged financing. The action is authorized under 42 U.S.C. § 8256, which permits federal agencies to enter into energy service contracts with utility providers serving the facility, and sole-source justification stems from Southwest Gas being the exclusive utility serving the medical center with the statutory authority to deliver UESC services. This acquisition is a direct follow-on to prior UESC work already performed by Southwest Gas under Phase 1, and selecting another provider would necessitate redoing the Investment Grade Audit, duplicating design and engineering efforts, risking project inconsistencies, and introducing significant schedule delays. While this notice does not constitute a solicitation, responsible entities that believe they may meet the statutory criteria under 42 U.S.C. § 8256 and can deliver the full scope of integrated services—including financing coordination, phased construction in an active medical environment, and long-term measurement and verification—may submit a capability statement of no more than five pages. Submissions must include evidence of legal eligibility as a serving utility for the facility, proven experience with similar UESC projects, and the capacity to complete work without disrupting patient care. Responses are due by July 23, 2026, and must be submitted electronically to the designated Contracting Officer, with no reimbursement provided for preparation costs. The government reserves full discretion to determine whether to proceed without competition based on the responses received.
Natural Gas Distribution

POSTED

3 days ago

DEADLINE

in 5 days
View Details
NAICS: 238290
New
Federal
J035--502-24-102 | Replace Elevators in Bldg 7 & 9 | Pineville, LAThe contract is for the replacement of elevators in Buildings 7 and 9 at the Alexandria VA Medical Center in Pineville, Louisiana, under the project title J035--502-24-102 and solicitation number 36C77626R0101. This is a Design-Bid-Build construction project with a Firm-Fixed-Price contract structure, estimated to range between $5 million and $10 million. The work must be performed in accordance with specifications and design documents to be provided by the Department of Veterans Affairs during the solicitation process, ensuring safe and compliant conditions for electrical system maintenance. Performance is expected to last approximately 365 calendar days, beginning upon issuance of the Notice to Proceed, and all work must occur at the specified location: 2495 Shreveport Highway, Pineville, Louisiana, 71360. This solicitation is exclusively reserved for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), with offers from any other entity deemed ineligible. The NAICS code 238290 applies, with a size standard of $22 million, and offerors must maintain current representations and certifications in the System for Award Management. Evaluation will follow Lowest Priced Technically Acceptable procedures, meaning technical acceptability is a threshold requirement and awards will go to the lowest-priced proposal that meets all technical standards. The response deadline is June 15, 2026, at 2:00 PM Eastern Time, with all inquiries required to be submitted in writing via email to Mario Hairston or Scott Elias; telephone inquiries are not permitted. The contract will be administered by the Program Contracting Activity Central under the Department of Veterans Affairs, with the office located in Independence, Ohio.
Other Building Equipment Contractors

POSTED

4 days ago

DEADLINE

in 6 days
View Details
NAICS: 236220
New
Federal
Z2DA--689-22-700 EHRM IU West Haven VAMC This ONLY for the PCAC VISN 1 Construction MATOC PoolThe contract pertains to the Design Bid Build Electronic Health Record Modernization Infrastructure Upgrades at the West Haven VA Medical Center, identified by solicitation number 36C77626R0106 and title Z2DA--689-22-700, issued by the Department of Veterans Affairs’ Program Contracting Activity Central. The project is scoped for comprehensive infrastructure enhancements across multiple buildings, including 1, 2, 3, 4, 5, 6, 11, 11A, 12, 14, 15, 16A, 21, 22, 24, 27, 34, 35, 35A, 36, 36A, 12A, 14A, 15A, 2B, and site-wide areas, to support the EHRM initiative. Work includes upgrading facility fiber networks to each Telecommunications Room with redundant runs and mains to demarcation points, installing new data drops, adding electrical outlets and power capacity in all TRs, upgrading power distribution systems, enhancing HVAC distribution as needed, conducting physical security assessments and upgrades aligned with the PSRDM 2021 VA Standard, abating hazardous materials, and constructing a new data center. The requirement is restricted exclusively to contractors within the PCAC VISN 1 Construction MATOC IDIQ Pool and is set aside entirely for Service-Disabled Veteran-Owned Small Businesses. The estimated construction value ranges from $20 million to $50 million, with a period of performance of approximately 730 calendar days from the Notice to Proceed. The solicitation is governed by FAR Parts 15, 16, and 36 under NAICS code 236220, with a size standard of $45 million. The place of performance is specified as 950 Campbell Ave, West Haven CT 06516, and the response deadline is July 31, 2026, at 1:00 PM Eastern Time. While this is a presolicitation notice, it confirms the intent to issue a Request for Proposal in accordance with the outlined parameters, with evaluation procedures to be detailed in the full solicitation.
Commercial and Institutional Building Construction

POSTED

5 days ago

DEADLINE

in 13 days
View Details
NAICS: 236220
New
Federal
Z2DA--EHRM Upgrades - White River Junction, VTThe contract pertains to the EHRM Infrastructure Upgrades at the VA Medical Center in White River Junction, Vermont, under solicitation number 36C77626R0092, and is strictly a 100% set-aside for Service-Disabled Veteran-Owned Small Business (SDVOSB) concerns. All offerors must be certified by the U.S. Small Business Administration and actively listed in the SBA database at both proposal submission and award times; failure to meet this requirement renders a proposal ineligible. The procurement follows FAR Part 15 procedures for negotiated contracts and is classified under NAICS code 236220 for Commercial and Institutional Building Construction. Proposals must be submitted electronically as four searchable PDF volumes by 5:00 PM ET on August 6, 2026, and sent via email to Jennifer Braaten and Megan Dohm. The solicitation strictly prohibits hard copies, hyperlink submissions, or drop-box deliveries, and requires a Firm Fixed Price structure with pricing submitted in whole dollar amounts only. Technical questions must be submitted in writing to Jennifer Braaten by July 23, 2026, and only solicitation amendments published on SAM.gov will constitute official changes. The scope of work includes comprehensive upgrades to the facility’s fiber optic backbone with redundant runs to all Telecommunications Rooms, enhanced power distribution, electrical infrastructure upgrades including high-voltage systems (12,470V and 480V), HVAC improvements, physical security assessments, asbestos and lead remediation, and full renovation of existing space including data center work. All materials must be delivered in manufacturer-sealed containers with proper labeling, protected throughout handling and storage, and stored in climate-controlled environments. Key deliverables encompass cybersecurity systems, controls systems, electrical grounding, and full commissioning across multiple divisions. The project has a 450-calendar-day performance period following Notice to Proceed, and contractors must submit a detailed CPM schedule, monthly progress updates, and a Division Cost Breakdown. Evaluation is based on a best-value approach, prioritizing technical factors—Project Experience, Key Personnel, Key Trades, and Past Performance—significantly over price, with recency of prior projects limited to the last five years or 75% completion at solicitation posting. All personnel must undergo VA vetting, pass background checks, be pre-approved by the VA, and comply with VA Directive 0710. The contract incorporates numerous FAR and VAAR clauses,
Commercial and Institutional Building Construction

POSTED

5 days ago

DEADLINE

in 19 days
View Details
NAICS: 611430
Federal
Training and Compliance Program DevelopmentThe contract involves developing and delivering comprehensive training programs aimed at ensuring ongoing regulatory compliance among medical billing staff within the Department of Veterans Affairs. The training will cover critical areas including VA policies, HIPAA regulations, CMS updates, and claim processing workflows, with the goal of maintaining accurate and lawful billing practices across all operations. The work requires expertise in adult learning methodologies, regulatory compliance frameworks, and healthcare billing systems to create engaging, effective, and up-to-date educational content tailored to the needs of VA personnel. This subcontract is categorized under NAICS code 611430 for other educational support services and carries a response deadline of July 20, 2026, with a posted date of July 10, 2026. The performance location and specific office details are not provided, and no set-aside classification is indicated. The contract is managed under the agency designation Pcac 36C776, which operates under the broader authority of the Department of Veterans Affairs, and all deliverables must align with federal compliance standards and the operational requirements of VA medical billing units.
Professional and Management Development Training

POSTED

8 days ago

DEADLINE

in 2 days
View Details
NAICS: 541512
Federal
Secure Remote Work Environment Setup and IT SupportThe contract requires the establishment and maintenance of a secure remote IT environment tailored for processing VA claims, with a strong emphasis on data confidentiality, robust access controls, and full compliance with Department of Veterans Affairs security protocols and legacy system constraints. The solution must enable authorized personnel to safely access and manage claims data remotely while ensuring that all technical configurations align with federal cybersecurity standards and VA-specific operational requirements. Ongoing support services must be available to sustain system integrity, address vulnerabilities, and adapt to evolving security threats or regulatory changes. This subcontract is classified under NAICS code 541512 for computer systems design services and is issued by the Department of Veterans Affairs through the PCAC contracting office. The opportunity was posted on July 10, 2026, with an established deadline for responses on July 20, 2026, at 6:00 PM. While no set-aside type is specified, performance is expected to be conducted in support of VA operations without a defined geographic location specified in the place of performance. The successful vendor will be responsible for delivering a scalable, resilient, and audit-ready infrastructure that upholds the highest standards of data protection and system reliability for critical veteran services.
Computer Systems Design Services

POSTED

8 days ago

DEADLINE

in 2 days
View Details
NAICS: 541611
Federal
Supervisory and Managerial Staffing for Billing OperationsThe contract seeks qualified supervisors and managers with three to five or more years of experience in outpatient billing to oversee claims processing teams in alignment with Veterans Affairs staffing standards. These professionals will be responsible for ensuring accurate, efficient, and compliant handling of billing operations, with a strong emphasis on adherence to VA regulations and operational requirements. The role demands leadership experience in a healthcare billing environment, particularly in managing teams focused on claim submission, denial management, and revenue cycle integrity. This is a subcontract opportunity under NAICS code 541611, issued by the Department of Veterans Affairs through PCAC, with a response deadline of July 20, 2026. The place of performance and exact location details are not specified, indicating flexibility in work location as long as compliance with VA requirements is maintained. The solicitation is open to vendors capable of providing experienced leadership personnel to support VA’s billing infrastructure, with an emphasis on expertise in outpatient billing systems, team supervision, and regulatory compliance. All proposers must demonstrate proven capability in delivering high-quality supervisory oversight in a federal healthcare billing context.
Administrative Management and General Management Consulting Services

POSTED

8 days ago

DEADLINE

in 2 days
View Details