Construction: Taylorsville High School Addition
Contract Overview
Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.
AI Contract Overview
The Granite School District is soliciting proposals for a General Contractor to manage the Taylorsville High School Addition project in Taylorsville, Utah. The scope of work includes the construction of new office, classroom, and athletics wings, as well as the remodeling of existing office and classroom spaces. Key interior improvements involve refreshing the commons area and cafeteria and consolidating two food labs into a single culinary arts lab. Exterior site improvements include the installation of new tennis courts, a softball press box, the relocation of batting cages, general landscaping, and the creation of a new curb and gutter for an ADA drop-off. Technical requirements specify the use of aggregate piers for soil improvement and composite open web floor joists for MEP traversal. The project is scheduled to begin on December 14, 2026, with a final completion date of July 6, 2029. While not phased, the work must follow a strict sequence: the new main office must be finished by October 1, 2027, to allow the conversion of the old office into a counseling area starting October 4, 2027. Work on the commons, cafeteria, and culinary arts lab must occur during summer recesses. Due to the presence of asbestos-containing materials identified in the main building and relocatable units, the contractor must comply with NESHAP and EPA/OSHA regulations. This solicitation is limited to respondents prequalified in DB27-009-RFSQ, with a response deadline of November 19, 2026, and a recommended award date of November 24, 2026.
General Info
Agency
Place of Performance
UT, USASet-Aside
Timeline
Response Deadline
Organization & Contact Information
Full Description
The purpose of this Request for Proposals (RFP) is to enter into a contract to provide General Contractor for the construction of a new office wing, new classroom wing, new athletics wing, remodeling of existing classroom and office spaces, and miscellaneous site improvements at Taylorsville High School according to the attached Project Manual for Taylorsville High School Addition.
It is anticipated that this RFP will result in a single contract award to the responsive and responsible vendor with the highest score justified by the procurement code. Please review Instructions to Respondents to know how scoring will occur for this Request for Proposal. Only Respondents that were prequalified in DB27-009-RFSQ may respond to this solicitation.
Pre-Bid Meeting: Attendance is required - See Project Manual document for details.
It is anticipated this expenditure will require GSD Board approval. Award recommendation will be presented at the 11/24/2026 board meeting. Final award will be issued after board approval is given.
Similar Contracts
Same NAICS industry code
More opportunities from Utah
Same awarding agency
Ready to Pursue This Opportunity?
Get AI-powered intelligence on this solicitation and the ones like it
Every page of the solicitation package shredded into a compliance breakdown
AI-powered matching based on your capabilities and past performance
Competitor and incumbent history on the requirement
Automated alerts on amendments, Q&A deadlines, and award
Join 750+ contractors already using CLEATUS
