Psst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveCLEATUS Webinar: AI for Government Contracting — Free Webinar — Wednesday, August 5 at 2:00 PM EDT

Register Free →

Get CLEATUSFree Trial

Get CLEATUSFree Trial

Search

Top

Back to Contracts

General Construction Management & Site Coordination

Active

Federal

Response Deadline08/30/2026, 04:00:00 AM UTC

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

The contract entails comprehensive construction management and site coordination for a project under the Department of Defense, specifically managed by W2SD Endist New York, with performance centered at location 39855. It covers the entire construction lifecycle from demolition and site preparation through trade coordination, quality control, and strict adherence to federal and safety regulations. The scope requires seamless integration of multiple trades and continuous oversight to ensure compliance with all applicable codes and standards. As a subcontract opportunity, it is open for bidding with a response deadline of August 30, 2026, and is classified under NAICS code 236220 for commercial and institutional building construction. No set-aside provisions are specified, and the opportunity is available to eligible subcontractors without geographic or demographic restrictions indicated.

General Info

Comprehensive construction management for DoD project at 39855, all trades, strict compliance, bid due August 30, 2026.

Agency

Department Of Defense → W2SD Endist New YorkView Agency

NAICS

236220 - Commercial and Institutional Building ConstructionView NAICS

Place of Performance

39855, NY, USA

Set-Aside

NONE

Documents

(0)

No documents available

AI Contract Breakdown

Uniform Contract Format

No contract breakdown available.

Cannot generate Contract Breakdown because no documents were found from this contract's source.

Timeline

PostedJul 29

subcontract

Response DeadlineAug 30

Submission deadline

Response Deadline

08/30/2026, 04:00:00 AM UTCin about 1 month

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more

AgencyDepartment Of Defense → W2SD Endist New York

ContactsNo contacts available

OfficeN/A

Organization / Agency

Department Of Defense → W2SD Endist New York

View Agency Profile

Office AddressN/A

ContactsNo contact information available

Full Description

Show more

Oversight of full construction lifecycle including demolition, site preparation, trade coordination, quality control, and compliance with federal and safety codes.

Similar Contracts

Same NAICS industry code

Sources Sought/Market Intelligence: Fort Carson Equipment Concentration Site - Potential Use of Progressive Design Build using Other Transaction Authority (OTA)The U.S. Army Corps of Engineers, Louisville District, is seeking market intelligence through a voluntary Request for Information to explore industry interest and capability in delivering a $75 million Equipment Concentration Site complex at Fort Carson, Colorado. The project involves designing and constructing a fully functional Area Maintenance Support Activity shop, General Purpose Warehouse, and Organizational Storage Building, with specialized infrastructure such as vehicle wash racks, bi-level loading ramps, heavy equipment parking, and extensive site work across a 48-acre parcel. The Government intends to pursue a Progressive Design-Build delivery model under Other Transaction Authority (10 U.S.C. § 2808a), a flexible statutory mechanism distinct from traditional contracts and tailored for military construction projects incorporating innovative technologies to enhance resilience, reduce costs, and accelerate delivery. This approach allows for collaborative design and risk mitigation in Phase 1, culminating in a Guaranteed Maximum Price proposal for Phase 2 construction, with the Government retaining an off-ramp option if the GMP is not agreed upon. Respondents are asked to provide detailed insights into their firm’s experience with OTA-based projects, progressive design-build execution, open-book pricing mechanisms, and handling of long-lead items and risk allocation. The Government seeks input on innovative construction materials and methods that could improve efficiency or facility performance, along with barriers to adopting such technologies under traditional procurement rules. Specific questions address compensation for Phase 1 work if the project is abandoned, appropriate milestone payments under an OTA, data rights arrangements for proprietary designs, phased bonding structures, and surety timelines. The inquiry also probes subcontractor integration strategies, local labor and supply chain constraints in the Colorado Springs region, and the value of early contractor involvement compared to conventional methods. Responses must include company profile details, socioeconomic classification, and technical responses to the full spectrum of questions, with submissions due by August 7, 2026, to the designated point of contact. Participation is non-binding and does not obligate the Government to issue a solicitation, nor will respondents be reimbursed for preparation costs.

W072 Endist Louisville

POSTED

about 9 hours ago

DEADLINE

N6945026RJX03: Building 101 (B101) Component Spray Booth ReplacementThe contract N6945026RJX03 is a solicitation for the replacement of the component spray booth at Building 101, issued by the Naval Facilities Engineering Systems Command Southeast under the Department of Defense. It is designated as a Historically Underutilized Business (HUBZone) Set-Aside, meaning only qualified small businesses located in HUBZones are eligible to compete, in accordance with FAR 19.13. The North American Industry Classification System code is 236220, indicating the work falls under commercial and institutional building construction. The solicitation was posted on July 29, 2026, and responses are due by August 24, 2026, at 3:59 PM Eastern Time. The performance location is at Naval Air Station Jacksonville, Florida, with a zip code of 32212. Primary contact for inquiries is Monica Gummerus, reachable at 904-542-1606 or monica.a.gummerus.civ@us.navy.mil, with Stephen Sparks listed as the secondary point of contact. The full details and submission portal are available via the SAM.gov link provided.

Navfacsyscom Southeast

POSTED

about 9 hours ago

DEADLINE

N33191-26-R-0032 Design-Build Maritime Center of Excellence, Bizerte, TunisiaThe U.S. Navy, through the Naval Facilities Engineering Systems Command Europe, Africa, and Central, has issued a presolicitation notice for the Design-Build Maritime Center of Excellence in Bizerte, Tunisia, under contract number N33191-26-R-0032. This procurement is classified under NAICS code 236220 for Commercial and Institutional Building Construction and is intended to develop a state-of-the-art facility to support maritime operations, training, and logistics. The solicitation is open to qualified contractors capable of delivering a design-build solution that meets the Department of Defense’s functional, technical, and operational requirements for the site. The response deadline is August 14, 2026, at 1:00 PM Eastern Time, with proposals due prior to this date to be considered for award. The contracting office is located in FPO, AE, with Daniel Magrino serving as the primary point of contact for all inquiries, reachable via email at daniel.k.magrino.civ@us.navy.mil or by phone at 202-781-3544. While the place of performance is confirmed as Bizerte, Tunisia, specific site details are not provided in the presolicitation, and interested parties are advised to review the attached Pre-Solicitation File for comprehensive project scope, technical specifications, and submission guidelines. The procurement is not currently set aside for any small business programs or other socio-economic categories, and all eligible entities may respond. The official presolicitation document can be accessed via the provided SAM.gov link.

Navfacsyscom Europe Africa Central

POSTED

about 9 hours ago

DEADLINE

Z2DA--618-CSI-240, SPS Equipment Site Prep 36C263-26-AP-1525 - FY26 NRM OSThe contract titled Z2DA--618-CSI-240, SPS Equipment Site Prep 36C263-26-AP-1525 - FY26 NRM OS is a solicitation issued by the Department of Veterans Affairs through the Network Contract Office 23 located in Saint Paul, Minnesota. It is designated as a Service-Disabled Veteran-Owned Small Business Set-Aside, meaning only eligible SDVOSBs may compete for award, in accordance with FAR 19.14. TheNorth American Industry Classification System code 236220 applies, indicating the work involves construction of commercial and institutional buildings. The place of performance is in Minneapolis, Minnesota, with a zip code of 55417. The solicitation was posted on July 29, 2026, and responses are due by August 3, 2026, at 7:00 PM Eastern Time. Amendment 2 has been issued to address additional questions received during the solicitation period. Primary point of contact for inquiries is Contract Specialist Dean Flanders, reachable via email at dean.flanders@va.gov or by phone at 320-247-0331. The full solicitation details can be accessed online through the SAM.gov portal.

Network Contract Office 23 (36C263)

POSTED

about 9 hours ago

DEADLINE

RFP 47PD5326R0051 ND0047ZZ Domestic Recirculation Repairs Fargo, NDThe contract involves the repair and expansion of an undersized and improperly designed recirculating hot water system at the Federal Courthouse in Fargo, North Dakota, a building constructed around 1998 with a basement and three floors. The existing system, with its water heater and recirculation pump located in the basement, requires complete modification to install new circulating hot water piping that runs through all occupied floors, eliminating excessive delays in hot water delivery to fixtures. The work includes general construction tasks such as ceiling and wall patching and painting, and must strictly follow the GSA project drawings and manual dated December 2024, along with the PBS Core Building Standards Memorandum and Division-specific requirements from the project manual covering general requirements, existing conditions, and finishes. The solicitation is a Total Small Business Set-Aside under NAICS Code 236220, restricted to small businesses located in North Dakota, and requires bidders to demonstrate past experience as a Design Build contractor on at least two similar projects completed within the past eight years. Proposals must be submitted electronically by 10:00 a.m. CDT on August 10, 2026, to the Contracting Officer, and must include the SF 1442, a Price Proposal, a Technical Proposal satisfying the pass/fail past experience requirement, a Bid Bond, and GSA Form 527, alongside an active SAM registration and Unique Entity Identifier. The contract will be awarded using the Lowest Price Technically Acceptable method, with evaluation focused solely on technical acceptability and price, and no cost or non-cost factors weighted beyond pass/fail thresholds. All pricing must reflect full knowledge of site and local conditions, and unbalanced pricing may result in proposal rejection. The contractor must provide performance and payment bonds as mandated by FAR 52.228-15, maintain required insurance including $500,000 commercial general liability and $100,000 employers’ liability coverage, comply with OSHA Lead standards and use appropriate personal protective equipment, and adhere to Buy American provisions unless an exception is granted. Work must commence within one day of receiving the Notice to Proceed, achieve substantial completion within 120 calendar days, and complete all remaining work within 60 days thereafter. Payment terms require electronic invoicing with GSA Form 2419 and an updated Schedule of Values, with progress payments processed within 14 days and subcontractor payments within seven days,

Pbs Project Delivery West - Branch C

POSTED

about 9 hours ago

DEADLINE

Replace Greenhouse 3 and Renovate Headhouse Heating System (Stoneville, MS)The U.S. Department of Agriculture’s Agricultural Research Service is soliciting quotes for the replacement of Greenhouse 3 and the renovation of the Headhouse Heating System at the Jamie Whitten Delta States Research Center in Stoneville, Mississippi, under solicitation number 1232SA26Q0885. This is a combined synopsis/solicitation issued as a Request for Quotation under FAR Part 12, exclusively set aside for small businesses as a Total Small Business Set-Aside, with a size standard of $45 million and NAICS code 236220. All responsible small business concerns may submit quotations, but only those that attended the mandatory site visit and demonstrate acceptable or neutral past performance are eligible for award. The solicitation requires adherence to FAR 12.201-1(b)(2), incorporating standard clauses including labor standards such as 52.222-6 through 52.222-15, construction requirements under 52.236-5, changes under 52.243-4, and inspection of construction under 52.246-12. The contract also mandates compliance with anti-discrimination and DEI certification clauses, whistleblower rights, and trafficking in persons prohibitions, with full acceptance of terms contingent on the SF-1442 form submission. Quotations must be submitted via email to Spencer Hamilton at spencer.hamilton@usda.gov by 12:00 p.m. EST on August 7, 2026, following a series of amendments that extended the original deadline. Offerors must maintain active SAM.gov registration with a valid Unique Entity Identifier, complete all required annual representations and certifications electronically, and hold firm pricing for 90 days post-submission. The scope includes demolition and replacement of Greenhouse 3 with a masonry kneewall, translucent polycarbonate glazing, evaporative cooling, automatic shade systems, adjustable plant tables, and water and control systems, plus an optional renovation of the Headhouse heating system involving replacement of piping and fan coil units and removal of a fume hood. All materials must be asbestos-free, packaging must meet DOT and EPA standards for hazardous waste and asbestos, and products manufactured more than three years before delivery are prohibited. The contractor is required to comply with EM 385-1-1, OSHA, NFPA 70E, Buy American Act, and Civil Rights Act

USDA Ars Afm Apd

POSTED

about 9 hours ago

DEADLINE

REPAIR COLLIER GYM, P-1949, CP HUMPHREYSThis contract, titled REPAIR COLLIER GYM, P-1949, CP HUMPHREYS, is solicited under number W91QVN26RA077 and was posted on July 29, 2026, with a response deadline of August 12, 2026, at 4:00 a.m. It is classified as a combined solicitation under NAICS code 236220 for building construction and is restricted to MATOC vendors only, as specified in the attached documentation. The work is to be performed at Collier Gym, P-1949, Camp Humphreys, with no additional location details provided beyond the general site. The contracting office is under the Department of Defense, specifically the 0411 Aq Hq Contract Augmented office, located in APO, AP, 96271-5289. Primary point of contact for inquiries is Su Kyong Choe, reachable via email at sukyong.choe.ln@army.mil or phone at 315-755-0638. No set-aside type is designated, and bidders must ensure compliance with the attached requirements and conditions outlined in the solicitation and its first amendment.

0411 Aq Hq Contract Augmented

POSTED

about 9 hours ago

DEADLINE

ND-GARRISON DAM NFH-ROOF REPAIRThe contract for ND-GARRISON DAM NFH-ROOF REPAIR is a small business set-aside solicitation under NAICS code 236220, exclusively available to small businesses, with a response deadline of August 14, 2026. It is managed by the Department of the Interior through the Gaoa Fws office located in Falls Church, Virginia, and seeks repairs to the roof structure at the Garrison Dam National Fish Hatchery. The solicitation number is 140FGA26Q0054 and was posted on July 29, 2026, indicating the government’s intent to award a combined contract for this construction-related work. The primary point of contact for inquiries is Channel Pedersen, reachable via email at Channel_Pedersen@ios.doi.gov or by phone at 2104014735, with the full details andSubmission portal accessible through the SAM.gov platform. The exact location of performance is not specified within the provided data, but the work is understood to be at the Garrison Dam facility.

POSTED

about 9 hours ago

DEADLINE

GLAC REPLACE GENERATOR COMPONENTSThe contract titled GLAC REPLACE GENERATOR COMPONENTS is a solicitation issued by the Department of the Interior through the Imr Northern ROCKIES office located in Yellowstone National Park, Wyoming. The solicitation, identified by number 140P1426R0025, was posted on July 29, 2026, with a response deadline of August 24, 2026. It falls under the NAICS code 236220, indicating it pertains to commercial and institutional building construction, and is intended for the replacement of generator components. The primary point of contact for inquiries is Sally Leitch, reachable via email at sally_leitch@ios.doi.gov or by phone at 7204505172. The place of performance is not explicitly defined beyond the agency’s location, suggesting work may be performed at or near the agency’s operational site in Wyoming. No set-aside type is specified, meaning the opportunity is open to all eligible contractors without preference for small businesses or other designated categories.

Imr Northern ROCKIES(12200)

POSTED

about 9 hours ago

DEADLINE

Construct Headquarters and Operations Building, Baucau, Timor-LesteThe U.S. Department of Defense, through NAVFACSYSCOM Far East, is soliciting design-build services for the construction of a Headquarters and Operations Building at Baucau Airfield in Timor-Leste under solicitation number N4008426R4998, with a projected contract value between $1 million and $5 million. The project, classified under NAICS code 236220, requires contractors to adhere to Unified Facilities Criteria, the International Building Code, or host nation requirements. A pre-solicitation site visit is scheduled for July 8, 2026, from 10:00 to 12:00 local time at Baucau Airfield, with the designated meeting point at the airfield entrance. Attendance is strictly contingent upon prior submission of a Base Access Request by the May 21, 2026, deadline; contractors who failed to submit the request by that date are barred from participating. Only two participants, one driver, and one vehicle per company are permitted on the visit, with the driver required to remain in the vehicle at all times. Contractors are responsible for their own transportation and must supply an active SAM registration in PDF format. All personnel must be listed in an Excel spreadsheet named “Encl 1 Personnel Roster_[Short Company Name]” using proper case formatting, and submitted as a single, bookmarked PDF titled “[Company Name]_IDs” with bookmarks matching the roster order. Foreign nationals must provide a valid passport bio page valid for at least six months beyond submission, while local citizens must present a national LTO driver’s license. No JPEG files, password-protected documents, or unauthorized site visits will be accepted, and violations may lead to disqualification. The formal solicitation is expected to be released shortly after the site visit, with a response deadline set for August 6, 2026. Primary point of contact is Artitar Udit, and secondary is Rondel Williams, both via U.S. Navy email addresses.

Navfacsyscom Far East

POSTED

about 9 hours ago

DEADLINE

DY-BO131-4P -Renovate Facades, Replace Windows/Doors & Repair Drainage of Bldgs. #8404 & #8405, Baumholder MILCOMThe U.S. Army’s 409th Contracting Support Brigade is soliciting proposals under a two-step sealed bidding process for the renovation of Buildings #8404 and #8405 at the Baumholder Military Community in Germany, designated as Project DY-BO131-4P. The work includes comprehensive facade restoration and natural stone masonry repair to prevent water infiltration, replacement of all exterior windows and doors, minor roof repairs, and upgrades to drainage systems, walkways, and lighting. The contract will be awarded as a Firm-Fixed-Price, single-award contract with a mandatory 365-calendar-day performance period. Step One requires only technical proposals submitted electronically in English as PDF files, detailing the proposed methods, materials, and schedules in compliance with German DIN standards for civil (B3), architectural (B4), electrical (B5), and engineering services (B6). Offerors must submit proof of legal authorization to do business in Germany, a detailed progress schedule meeting the timeline, evidence of satisfactory past performance, and supporting documentation such as sketches, material specifications, and adherence to TRGS and MLAR guidelines. Attachments including site plans, asbestos surveys, stormwater drainage maps, and photos are available to guide proposal development and must be referenced where applicable. Pricing is excluded from Step One submissions; in Step Two, only offerors whose technical proposals were deemed acceptable may submit sealed bids in Euros, with the award going to the lowest responsive aggregate bid for CLIN 0001 (Building 8404) and CLIN 0002 (Building 8405). The Government reserves the right to award only the Base Bid if funding is insufficient. All proposals must be self-contained and submitted without additional explanation, and the Government may determine acceptability solely on the basis of the submitted materials without requesting clarifications. Bidders may submit multiple technical proposals, each evaluated independently, and those found unacceptable will receive formal notification. Only contractors with valid German business registrations and full compliance with U.S. Army access and security requirements—including AT Level I training, iWATCH training, OPSEC awareness, and Personal Identity Verification under FAR 52.204-9—will be eligible. Final acceptance at the project site requires submission of bilingual as-built documentation in both digital and hard copy formats, with 95% completeness prior to preliminary acceptance, and all work must meet stringent quality standards including crack-bridging waterproofing systems and proper substrate preparation confirmed through photos and thickness

0409 Aq Hq Contract

POSTED

about 9 hours ago

DEADLINE

***SOURCES SOUGHT NOTICE*** U.S. NAVAL HOSPITAL YOKOSUKA ALTERATION PROJECTThis notice is a sources sought announcement issued by the Naval Facilities Engineering Systems Command Far East for a major construction project at United States Naval Hospital Yokosuka in Japan, with an estimated value between $100 million and $250 million. The intent is to identify qualified contractors capable of executing a Design-Bid-Build project consisting of three interdependent packages: Package A, which is the base bid involving electrical infrastructure and must be completed before other work begins; and Packages B and C, which are optional and pertain to alterations in Buildings 1400 and 1407 and the operating room renovation respectively, both of which may be exercised and performed concurrently after contract award. The work encompasses comprehensive renovations across multiple critical hospital departments including the Emergency Department, Inpatient Pharmacy, Radiology, Sterile Processing, Surgery Suites, and Laboratory, and requires compliance with Unified Facilities Criteria, NFPA 99, ABA accessibility standards, and DoD antiterrorism requirements. Contractors must be fully licensed to operate in Japan, possess valid permits from Japanese authorities, and comply with all local labor laws and regulations, while not being eligible for U.S. Status of Forces Agreement benefits. The contract will be awarded on a firm-fixed-price basis with performance periods of 578 days for Package A, 1,627 days for Package B, and 986 days for Package C, and must include demolition, reconstruction, hazardous material abatement, mechanical and electrical upgrades, and installation of medical equipment. Interested parties must submit a comprehensive capabilities package via email exclusively, not exceeding 12 single-sided pages, that includes up to five project examples with narrative details and mandatory information such as Unique Entity ID and CAGE code, all submitted no later than 1530 JST on August 10, 2026. No payments or reimbursements are provided for responses, and all submissions are treated as proprietary and non-binding for sourcing and planning purposes only, with no evaluation letters or award notifications issued for this notice.

Navfacsyscom Far East

POSTED

about 9 hours ago

DEADLINE

More opportunities from Department Of Defense → W2SD Endist New York

Same awarding agency

Structural & Seismic RetrofittingThe contract entails structural reinforcement and seismic retrofitting work to ensure compliance with current building code requirements and load capacity standards, focused on enhancing the safety and integrity of a facility located in 39855. The project is classified as a subcontract under NAICS code 238110, indicating it falls under the specialty trade contractors category for structural steel and precast concrete work. The solicitation was posted on July 29, 2026, with a firm deadline for responses on August 30, 2026, at 4:00 AM. The contracting activity is under the Department of Defense through its W2SD Endist New York entity, though specific details regarding the office address and point of contact are not provided. The work must be performed at the designated site without additional location specifications, and there is no set-aside designation indicated for small businesses or other categories.

Poured Concrete Foundation and Structure Contractors

POSTED

about 9 hours ago

DEADLINE

in about 1 month

Environmental Compliance & Indoor Air Quality TestingThis contract encompasses environmental compliance and indoor air quality testing services including radon testing, formaldehyde monitoring, asbestos and lead abatement, and the preparation of environmental clearance reports in accordance with established safety standards. The work is scoped to ensure the identification, mitigation, and documentation of hazardous materials within facilities, with a focus on protecting occupant health and regulatory adherence. All activities must be conducted under strict protocols to meet federal and industry-specific requirements for environmental remediation and air quality verification. The contract is classified as a subcontract under NAICS code 541620, indicating it involves environmental consulting and related services. It was posted on July 29, 2026, with a response deadline of August 30, 2026, and is being administered by the Department of Defense through its W2SD Endist New York entity. Performance is expected to occur at a location identified by the ZIP code 39855, though specific address details are not provided. The subcontract is part of a broader effort to maintain compliance with environmental safety mandates across DoD facilities, requiring qualified vendors to deliver accurate testing results and formal documentation to confirm clearance of hazards before occupancy or use.

Environmental Consulting Services

POSTED

about 9 hours ago

DEADLINE

in about 1 month

Interior Fit-Out & Finish WorkThe contract pertains to interior fit-out and finish work for a Department of Defense project under the NAICS code 238350, covering drywall installation, doors, windows, finish carpentry, flooring, and all related interior finishes. All materials must comply with low-formaldehyde emission standards to ensure indoor air quality and environmental safety. Work is to be performed at a location identified by the city code 39855, with a response deadline of August 30, 2026, at 4:00 a.m. The contract is structured as a subcontract and was posted on July 29, 2026, under the agency name W2SD Endist New York. No set-aside designation is specified, and the place of performance lacks detailed geographic information beyond the city identifier. Interested parties must submit responses prior to the deadline to be considered for award.

Finish Carpentry Contractors

POSTED

about 9 hours ago

DEADLINE

in about 1 month

Fire Protection & Sprinkler System InstallationThe contract entails the installation and certification of automatic sprinkler and fire suppression systems meeting NFPA standards, specifically for a Department of Defense facility located in 39855. It is classified as a subcontract under NAICS code 238290, which covers other building installation services, and was posted on July 29, 2026, with a firm deadline for responses on August 30, 2026, at 4:00 AM. The work must be performed in compliance with all applicable fire safety codes and certification requirements to ensure full operational readiness and regulatory adherence. The contracting entity, W2SD Endist New York, is acting on behalf of the Department of Defense, though no point of contact or specific office address details are provided, and the place of performance is limited to a single ZIP code with no further geographic precision. Bidders are expected to possess the technical expertise, certifications, and resources necessary to execute the project in accordance with federal defense infrastructure standards.

Other Building Equipment Contractors

POSTED

about 9 hours ago

DEADLINE

in about 1 month

Accessibility Compliance & ADA-Compliant ConstructionThe contract calls for the design and construction of fully accessible infrastructure elements including routes, entrances, restrooms, signage, and parking areas, all must meet exacting compliance standards under the Americans with Disabilities Act and the Architectural Barriers Act. Work must be executed to ensure universal accessibility, with precise attention to dimensions, clearances, materials, and operational features prescribed by these federal guidelines. The project is structured as a subcontract under the NAICS code 238990 for other specialized construction activities, and performance is expected to be completed at a location identified by the zip code 39855. The solicitation was posted on July 29, 2026, with a submission deadline of August 30, 2026, at 4:00 a.m. Eastern Time. The contracting entity is identified as W2SD Endist New York under the Department of Defense, indicating this effort supports a federal facility or installation. There is no set-aside designation specified, meaning any qualified contractor may bid. All work must adhere strictly to accessibility mandates, with no tolerance for noncompliance, and contractors are expected to demonstrate technical expertise in ADA and ABAAS implementation, including potential coordination with inspection authorities and documentation of compliance measures throughout the project lifecycle.

All Other Specialty Trade Contractors

POSTED

about 9 hours ago

DEADLINE

in about 1 month

Plumbing & Piping Systems InstallationThe contract titled Plumbing & Piping Systems Installation pertains to the installation of water supply, sewer, drainage, and plumbing fixtures in strict adherence to applicable environmental and plumbing codes. It is structured as a subcontract under the NAICS code 238220, indicating classification within plumbing, heating, and air-conditioning contractors. The opportunity was posted on July 29, 2026, with a response deadline of August 30, 2026, at 4:00 AM, requiring all proposals to be submitted prior to this time. The place of performance is designated in the location identified as 39855, though specific city and state details are not provided. The contracting entity is listed as W2SD Endist New York under the Department of Defense, signaling a defense-related project with stringent regulatory and compliance requirements. All work must align with federal standards for infrastructure installation, emphasizing technical precision, environmental responsibility, and adherence to plumbing regulations.

Plumbing, Heating, and Air-Conditioning Contractors

POSTED

about 9 hours ago

DEADLINE

in about 1 month

Electrical Systems & Fire Alarm InstallationThe contract entails a full electrical systems installation covering power distribution, lighting, and outlets, with full integration of a fire alarm system compliant with NFPA 72 standards. The work is scoped as a subcontract under the NAICS code 238210, which pertains to electrical contracting services, and is being managed by the Department of Defense through its W2SD Endist New York organization. Performance of the work is designated for a location with the city identifier 39855, though specific state and zip details are not provided. The opportunity was posted on July 29, 2026, with a response deadline of August 30, 2026, at 4:00 AM, indicating a competitive window for qualified subcontractors to submit proposals. All systems must be installed to meet rigorous safety and regulatory requirements, particularly around fire alarm functionality, ensuring full alignment with federal codes and defense operational needs.

Electrical Contractors and Other Wiring Installation Contractors

POSTED

about 9 hours ago

DEADLINE

in about 1 month

HVAC System Installation & CommissioningThe contract entails the comprehensive supply, installation, and testing of HVAC systems complete with ductwork and ventilation infrastructure, all engineered to meet strict environmental and technical specifications. A critical requirement is the use of CFC-free insulation materials to ensure compliance with ecological standards and sustainability mandates. The work falls under NAICS code 238220 and is structured as a subcontract, with performance expected at the location identified as 39855. The opportunity was posted on July 29, 2026, with a firm deadline for responses set for August 30, 2026, at 4:00 AM. This procurement is managed under the auspices of the Department of Defense through its agency W2SD Endist New York, indicating the project supports defense-related infrastructure needs. All systems must be fully commissioned and verified to operational standards prior to acceptance.

Plumbing, Heating, and Air-Conditioning Contractors

POSTED

about 9 hours ago

DEADLINE

in about 1 month

Ready-Mix Concrete & Construction Materials SupplyThe contract is for the supply of ready-mix concrete, fire-retardant treated wood, and other certified construction materials that must meet specific technical specifications required for construction projects. It is structured as a subcontract under the Department of Defense, with the agency name listed as W2SD Endist New York, and is identified by the NAICS code 327320 which corresponds to ready-mix concrete manufacturing. The opportunity was posted on July 29, 2026, with a firm deadline for responses set for August 30, 2026, at 4:00 a.m. The place of performance is designated as location 39855, though specific city or state details are not provided, indicating the work may be directed to a defined project site or region under federal jurisdiction. All materials supplied must be certified and compliant with applicable technical standards to ensure safety, durability, and regulatory alignment. This subcontract does not include any set-aside provisions and is open to qualified suppliers capable of delivering the required materials on schedule and to specification.

Ready-Mix Concrete Manufacturing

POSTED

about 9 hours ago

DEADLINE

in about 1 month

US ARMED FORCES RECRUITING STATION - 2,255 GSF office space in a retail plazaThe U.S. Army Corps of Engineers, New York District, is seeking lease proposals for approximately 2,255 square feet of commercial office space with parking for eight vehicles, located within a quarter-mile radius of Main Street in Oneonta, New York. The space must include a secondary egress, and the lessor is required to use the Government’s standard lease form. Proposals must include a proposed rental amount that covers water, sewer, common area maintenance, real estate taxes, and insurance. All responses are due by 12:01 a.m. on August 30, 2026, and inquiries should be directed to Jane Arnold at jane.e.arnold@usace.army.mil. Any entity submitting a proposal must be registered in the System for Award Management (SAM.gov) prior to contract award, and registration requires obtaining a Unique Entity Identifier. A notarized letter appointing an authorized Entity Administrator is mandatory for activation of the SAM record, and while registration can be temporarily activated before submission of the letter, the signed notarized document must be received by the GSA Federal Service Desk within 30 days to maintain active status. Payments will be made exclusively via electronic funds transfer, and contractors are urged to initiate SAM registration immediately, as the process can take several weeks. There is no fee to register, and entities are advised to verify their registration status using their CAGE or Unique Entity Identifier to ensure compliance and avoid delays in potential award.

POSTED

about 9 hours ago

DEADLINE

in about 1 month

US ARMED FORCES RECRUITING CENTER - 1,900 GSF office space in a retail plazaThe U.S. Army Corps of Engineers, New York District, is seeking lease proposals for approximately 1,900 square feet of commercial office space and parking for two vehicles within a quarter mile of Western Avenue in Albany, New York. The space must include a secondary egress and must be leased using the Government’s standardized lease form. Proposals must include a proposed rental amount that covers water, sewer, common area maintenance, real estate taxes, and insurance. All submissions are due by 12 a.m. Eastern Time on August 30, 2026. Interested parties must contact Jane Arnold at jane.e.arnold@usace.army.mil for additional details. Any contractor awarded a contract must be registered in the System for Award Management (SAM.gov) and must have a Unique Entity Identifier. Registration is free but requires a notarized letter appointing an authorized Entity Administrator, which must be submitted to the GSA Federal Service Desk within 30 days of activation to maintain eligibility. Payments will be made exclusively via electronic funds transfer. Contractors are strongly advised to initiate SAM registration immediately due to processing times that may extend several weeks, and should verify their registration status using their CAGE or Unique Entity Identifier prior to submission. Failure to complete these requirements will prevent award and payment.

POSTED

about 9 hours ago

DEADLINE

in about 1 month

US ARMED FORCES RECRUITING STATION -3,360 GSF office space in a retail plazaThe U.S. Army Corps of Engineers, New York District, is seeking lease proposals for approximately 3,360 square feet of commercial office space and parking for eight vehicles within a one-quarter mile of Commercial Drive in New Hartford, also known as New York Mills, New York. The space must include a secondary egress and must be leased using the Government’s standard lease form. Proposals must include a comprehensive rental amount covering water, sewer, common area maintenance, real estate taxes, and insurance. All responses are due by 12:01 a.m. on August 30, 2026, and inquiries should be directed to Jane Arnold at jane.e.arnold@usace.army.mil. Contractors must be actively registered in the System for Award Management (SAM.gov) prior to any potential award, and all payments will be made via electronic funds transfer. Registration requires obtaining a Unique Entity Identifier and submitting a notarized letter appointing an authorized Entity Administrator, which must be sent to the GSA Federal Service Desk within 30 days of activation to maintain validity. While initial registration can be completed quickly, the full process including verification may take several weeks; therefore, early registration is strongly advised. There is no cost to register in SAM, and prospective bidders are reminded that failure to complete registration in time could delay or prevent contract award.

POSTED

about 9 hours ago

DEADLINE

in about 1 month