Skip to main contentPsst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveFree Webinar — Wednesday, November 11 at 2:00 PM ET

Register Free →

IDIQ Boundary Maintenance Beaver Lake Project

Awarded
W9127S26DA016Federal

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

The IDIQ Boundary Maintenance Beaver Lake Project, identified by solicitation number W9127S26DA016, is an award notice issued by the Department of Defense through the W076 Endist Little Rock office. This contract is designated as a Total Small Business Set Aside under NAICS code 561730, focusing on landscaping and groundskeeping services. The project will be performed in Rogers, Arkansas, with administrative oversight based in Little Rock. Primary coordination for this contract is managed by Deborah Oswalt and Carole Householder.

General Info

DOD small business contract for landscaping and groundskeeping at Beaver Lake, Arkansas.

Contract Value

$1,590,000

NAICS

561730 - Landscaping Services

Place of Performance

Rogers, AR, USA

Set-Aside

SBA

Award Issued Date

Documents

0

No documents available

Documents will appear here when they are available.

AI Contract Breakdown

Uniform Contract Format

No documents to break down

The breakdown needs solicitation documents. None were found from this contract's source.

Timeline

PhaseAwarded
Posted

Award Notice

Awarded

Contract was awarded

Ready to pursue this opportunity?

Get full access to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more
AgencyDepartment Of Defense → W076 Endist Little Rock
Contacts2 people available
OfficeLITTLE ROCK, AR, 72201-3225, USA
Office AddressLITTLE ROCK, AR, 72201-3225, USA

Full Description

Show more
https://api.sam.gov/prod/opportunities/v1/noticedesc?noticeid=d6edd7a49b524276a71be35d8a636a20

Similar Contracts

Same NAICS industry code

NAICS: 561730
New
SLED
IT, Lot Cleanup, Vegetation Control, Debris Removal, and Metal Product Decommissioning and Removing
Solicitation # RFP-Lot-Cleanup-CCT-IT-10_15.pdf
The Confederated Tribes of the Colville Reservation is soliciting proposals for lot cleanup, vegetation control, debris removal, and metal product decommissioning services for five designated lots located in Nespelem and Omak, Washington. The selected contractor will be responsible for providing all labor, equipment, and transportation to mow grass and weeds, remove loose garbage and abandoned materials, and decommission specific equipment or fixtures. All waste must be transported to authorized facilities in compliance with local, state, and federal regulations, and the contractor must immediately report any hazardous or contaminated materials discovered on-site. The contract term is for an as-needed period not to exceed three years, with potential year-to-year modifications. Proposals are due by November 5, 2026, and will be evaluated based on a 100-point scale, with a preference given to responsible Indian Offerors whose prices are within 10% of the lowest non-Indian bid. Required submission materials include a detailed approach, contractor profile, and resumes for key personnel, with a total page limit of 30 pages. Awardees must provide proof of insurance and sign a certification regarding debarment and suspension. Financial terms include a 25% retainage or a performance bond for contracts exceeding $100,000, and all payments are contingent upon the availability of funds within the tribal treasury's fiscal year, which runs from October 1 to September 30.
Confederated Tribes of the Colville Reservation

POSTED

about 6 hours ago

DEADLINE

in 2 days
View Details
NAICS: 561730
New
SLED
27-13 Green Canopy Initiative - Tree Removals
Solicitation # 27-13
Montclair State University is soliciting bids for the Green Canopy Initiative - Tree Removals project, which involves the removal of approximately 500 trees. This project is structured as a Single Prime General Construction Contract and will be executed in two distinct phases: Phase 1 during winter break from December 17, 2026, to January 14, 2027, and Phase 2 during the summer from June 1, 2027, to August 18, 2027. All work must be completed by August 18, 2027. The contract award will be granted to the lowest responsible bidder whose proposal is most advantageous to the university, with evaluations based on price and other factors, though prior negative experience may lead to disqualification. Bidders must submit their proposals through the Workday Strategic Sourcing portal by December 2, 2026, at 2:00 p.m. Required submission materials include a bid bond set at 10% of the cost, a consent of surety for 100% of the project cost, and a schedule of participation demonstrating good faith efforts to include Small Business Enterprises and Disabled Veteran-Owned Businesses. The successful contractor must provide performance and payment bonds each equal to 100% of the total contract price and adhere to the New Jersey Prevailing Wage Act, OSHA safety standards, and the New Jersey Uniform Construction Code. The university's Vice President of Finance serves as the designated Contracting Officer for this initiative.
Montclair State University

POSTED

about 7 hours ago

DEADLINE

in 29 days
View Details
NAICS: 561730
New
SLED
Dune Matrix Enhancement- Pensacola Beach - National Coastal Resilience Fund NFWF
Solicitation # PD 25-26.118
Solicitation PD 25-26.118 is an Invitation to Bid issued by the Escambia County Office of Purchasing for the Dune Matrix Enhancement project at Pensacola Beach. Funded by the National Fish and Wildlife Foundation National Coastal Resiliency Fund, the project aims to improve coastal wildlife habitat and storm resiliency. The scope of work includes the installation of approximately 78,710 units of native vegetation, including sea oats, panic grass, and diversity groundcover, along with the installation of 7,095 feet of post-and-rope fencing, 5,384 feet of sand fencing, and necessary signage. Additionally, the contractor is responsible for removing asphalt debris across approximately 24,004 square yards of the beach. The contract will be awarded to the most responsive and responsible firm offering the lowest total bid, with the County reserving the right to award on an all-or-none or lot-by-lot basis. Performance must be substantially completed within 150 consecutive calendar days from the Notice to Proceed, with a total completion window of 180 days, excluding documented weather delays. A 180-day warranty period is required to ensure plant survivability and fencing condition. Bidders must be licensed in the State of Florida and comply with various federal and state regulations, including the Build America, Buy America Act, E-Verify, and a strict Cone of Silence policy prohibiting unauthorized communication during the procurement process. Administrative requirements include the submission of bids via the OpenGov portal, the provision of performance and payment bonds, and adherence to federal labor standards such as the Davis-Bacon Act and the Copeland Anti-Kickback Act. Technical specifications mandate that plant materials be sourced from the Florida or Alabama Gulf Coast and installed using super absorbent polymer pre-hydrating gel. Payment will be made within 30 days of invoice approval in accordance with the Local Government Prompt Payment Act of Florida.
Purchasing

POSTED

about 7 hours ago

DEADLINE

in 7 days
View Details

More opportunities from Department Of Defense → W076 Endist Little Rock

Same awarding agency

NAICS: 236220
New
Federal
Department of Veteran Affairs - Personnel Security Adjudication Center
Solicitation # W9127S27RA008
The Department of Veteran Affairs, through the U.S. Army Corps of Engineers District Little Rock, is soliciting bids for the turnkey design-build construction of the Personnel Security Adjudication Center (PSAC) at the Eugene J. Towbin VA Healthcare Center campus in North Little Rock, Arkansas. The project involves the creation of a two-story, 10,000 square foot facility designed to accommodate approximately 75 full-time equivalents, including a parking lot with a minimum capacity for 25 vehicles. A contingent option exists for the installation of a physical security fence featuring automated gate access and controls. A critical requirement of the project is achieving ICD 705 accreditation for secured construction areas, which necessitates stringent personnel vetting and compliance with classified information nondisclosure agreements. This is a total small business set-aside contract with a performance completion date of December 31, 2029. Award will be determined using a best value tradeoff methodology, where technical approach is the most important factor, followed by the proposed contract summary schedule, with combined non-price factors outweighing price. Bidders must provide performance and payment bonds and adhere to Davis-Bacon Act prevailing wage requirements. Proposals are submitted through a two-phase selection process, requiring detailed documentation on past performance, execution approach, and management teams. Invoicing and payment will be processed electronically via Wide Area WorkFlow.
Commercial and Institutional Building Construction

POSTED

6 days ago

DEADLINE

in 16 days
View Details
NAICS: 561720
Federal
Janitorial Services, DeQueen Project Office
Solicitation # W9127S27QA004
Solicitation W9127S27QA004 is a request for quotation issued by the US Army Corps of Engineers, Little Rock District, for non-personal janitorial cleaning services at the DeQueen Project Office in DeQueen, Arkansas. This procurement is a 100 percent Small Business Set-Aside under NAICS code 561720. The scope of work includes providing all personnel, equipment, and supplies necessary to maintain several adjacent buildings, including a public customer service lobby and a vehicle compound. The contract structure consists of a base period running from the date of award through October 31, 2027, with two subsequent 12-month option years. Award will be determined based on price only, and offerors must maintain an active SAM registration to be eligible. The contractor is required to provide a designated Contract Manager and a work leader, both of whom must be fluent in English. Performance will be monitored by the Contracting Officer's Representative through a Quality Assurance Surveillance Plan, and the contractor must implement a formal quality control plan and adhere to EM 385-1-1 and OSHA safety standards. All cleaning chemicals used must be appropriately labeled with Safety Data Sheets provided within two weeks of award. Quotes must be submitted in PDF format to the designated point of contact by November 4, 2026, at 10:00 AM CST.
Janitorial Services

POSTED

12 days ago

DEADLINE

in about 14 hours
View Details

Earlier notices in this NAICS code

Posted before this notice, open and closed

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Miguel
Hillary
Keith Deutsch
Christine

Join 750+ contractors already using CLEATUS