Skip to main contentPsst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveFree Webinar — Wednesday, August 5 at 2:00 PM EDT

Register Free →

Utility Coordination & Environmental Protection

Active
Federal

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

General Info

Agency

Department Of The Interior → Dsc Contracting Services DivisionView Agency

NAICS

541620 - Environmental Consulting ServicesView NAICS

Place of Performance

CO

Set-Aside

NONE

Documents

(0)

No documents available

AI Contract Breakdown

Uniform Contract Format

No contract breakdown available.

Cannot generate Contract Breakdown because no documents were found from this contract's source.

Timeline

Posted

subcontract

Response Deadline

Submission deadline

Response Deadline

Ready to pursue this opportunity?

Start your free trial to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more
AgencyDepartment Of The Interior → Dsc Contracting Services Division
ContactsNo contacts available
OfficeN/A
Organization / Agency
Department Of The Interior → Dsc Contracting Services Division
View Agency Profile
Office AddressN/A
ContactsNo contact information available

Full Description

Show more
Provide environmental compliance oversight, utility locates, and mitigation planning to protect natural resources during construction.

Similar Contracts

Same NAICS industry code

NAICS: 541620
New
SLED
Environmental Compliance and Documentation ServicesThe contract is for Environmental Compliance and Documentation Services under a subcontract awarded by Marine Maintenance for the Port of Seattle, aimed at ensuring full regulatory adherence during excavation and waste management operations. The work supports compliance with standards set by the EPA and state environmental agencies, with a strong focus on maintaining audit-ready records and proper documentation throughout all phases of activity. This includes tracking, reporting, and managing paperwork required for regulatory inspections and environmental audits to minimize risk and uphold legal obligations in real-time operational environments. The services are classified under NAICS code 541620, indicating environmental consulting and related technical support, and are intended to provide continuous compliance assistance wherever excavation and hazardous or non-hazardous waste handling occurs under the Port’s jurisdiction. The contract does not specify a geographic location beyond the Port of Seattle, and while no set-aside provisions are in place, the solicitation is posted as of July 2026, with a public-facing link available for further details. The scope demands expert knowledge of federal and state environmental regulations and the ability to produce clear, accurate, and timely documentation that meets both operational needs and regulatory scrutiny.
Marine Maintenance

POSTED

1 day ago

DEADLINE

N/A
View Details
NAICS: 541620
New
SLED
Comprehensive Regional Resilience PlanningThe contract titled Comprehensive Regional Resilience Planning is a subcontract issued by the Coastal Bend Council of Governments in Texas to develop regional strategies that address climate-related risks including sea-level rise, flooding, and disaster recovery planning for coastal communities. The work requires the contractor to design, implement, and coordinate resilience initiatives that enhance community preparedness and adaptive capacity in the face of escalating environmental threats. The scope centers on integrating scientific data, stakeholder input, and policy frameworks to create actionable, region-specific plans that support long-term sustainability and emergency response capabilities. Responses to the solicitation are due by August 31, 2026, and the effort falls under NAICS code 541620, indicating it involves environmental consulting services. The contract does not specify a set-aside type or a defined place of performance beyond the broader Texas coastal region, and the performance location remains unspecified in the posted details. The opportunity is accessible via the Texas SmartBuy portal, and while no point of contact information is provided, interested parties must submit proposals prior to the deadline to be considered for award. The initiative underscores a strategic focus on localized climate adaptation with broad implications for public safety, infrastructure planning, and regional economic stability.
COASTAL BEND COUNCIL OF GOVERNMENTS

POSTED

1 day ago

DEADLINE

in about 1 month
View Details
NAICS: 541620
New
SLED
Environmental and Regulatory Compliance ConsultingThe contract is for Environmental and Regulatory Compliance Consulting with a focus on coordinating CEQA documentation and ensuring adherence to state environmental regulations and agency mandates, specifically those from the Division of the State Architect and the Office of the State Fire Marshal. The work will be performed in Sacramento and requires expertise in navigating complex environmental review processes, interfacing with regulatory bodies, and delivering compliant documentation in alignment with California’s environmental standards. The contract is structured as a subcontract under NAICS code 541620, which classifies it as environmental consulting services, and it is being procured by the California Department of General Services on behalf of the state. The opportunity was posted on July 24, 2026, with a response deadline of August 20, 2026, indicating a timeline for proposers to submit qualifications and technical approaches. There is no specified set-aside or preference category, and no point of contact information is provided in the data. Interested parties must respond through the California eProcurement portal at the provided link, and the work will require demonstrated experience in environmental compliance, regulatory coordination, and familiarity with California’s public infrastructure regulatory environment. The absence of detailed performance metrics or deliverables in the data suggests proposers will need to clearly articulate their methodology and experience to meet the stated objectives.
California Department of General Services

POSTED

1 day ago

DEADLINE

in 24 days
View Details
NAICS: 541620
New
SLED
Commissioning Agent (CxA) for Building SystemsThe contract requires the development and implementation of commissioning and monitoring-based commissioning plans to ensure all building systems achieve and sustain high-performance benchmarks aligned with LEED, Zero Net Energy, and Zero Net Carbon objectives. The successful contractor will be responsible for overseeing the integration, testing, and ongoing verification of HVAC, lighting, controls, and other mechanical and electrical systems to guarantee they operate as designed and meet stringent energy and environmental targets throughout the building’s lifecycle. This includes continuous data collection, performance analysis, and adjustment protocols to maintain optimal efficiency and compliance with state sustainability mandates. The work is structured as a subcontract under the California Department of General Services with a NAICS code of 541620, indicating specialized engineering and technical services. Performance is expected to be centered in Sacramento, California, with a response deadline of August 20, 2026. The solicitation is open for qualified firms to submit proposals addressing comprehensive commissioning strategies that align with California’s aggressive climate goals, emphasizing long-term operational performance over initial construction-phase checks. While no set-aside provisions are specified, the agency prioritizes technical expertise in building systems optimization and energy performance validation to support public sector sustainability initiatives.
California Department of General Services

POSTED

1 day ago

DEADLINE

in 24 days
View Details

More opportunities from Department Of The Interior → Dsc Contracting Services Division

Same awarding agency

NAICS: 237310
New
Federal
Y--GOGA 319407 - Bridge PreservationThe contract pertains to bridge preservation work across ten structures within the Golden Gate National Recreation Area, with a performance period of 200 calendar days expected to begin in late 2026. The project requires comprehensive maintenance activities including concrete repair, guardrail and steel rail painting, timber replacement, fence and tree removal, sidewalk joint repair, stormwater management installation, hazardous materials abatement, and traffic control measures—all while operating within a fully accessible national park environment. Work sites are located in sensitive and remote areas such as Stinson Beach, Rodeo Lagoon, Point Bonita, Crissy Field, and Point Lobos, with limited staging space, no disruption to shuttle bus operations, and logistical challenges due to the 5-mile distance from suppliers and lodging. The work must comply with environmental and cultural resource protection standards, emphasizing minimal impact on natural areas and visitor experience. The anticipated contract type is Firm-Fixed-Price, and the estimated value ranges between $5 million and $45 million, aligning with the NAICS code 237310 for highway, street, and bridge construction. The Department of the Interior, through the DSC Contracting Services Division based in Denver, Colorado, is the procuring agency, with Shellie Murphy as the designated Contracting Officer and Dane Cooper as the primary point of contact for inquiries. Only a Sources Sought Survey Questionnaire is currently available, serving as a market research tool to evaluate industry capabilities prior to the formal solicitation expected in summer or fall of 2026. The government is considering a small business set-aside and is seeking responses from firms with demonstrated experience in federal bridge preservation, bonding capacity, and sensitive environmental project execution. Proposals must be submitted via email by May 6, 2026, and include the completed questionnaire and a capabilities statement; no formal contract clauses, delivery schedules, or pricing structures exist at this stage. Bonding requirements, environmental compliance protocols, and adherence to federal and industry standards such as those from the FHWA, ASTM, AASHTO, and NPS are anticipated but remain pending finalization in the upcoming RFP. Payment will be processed through the Denver Service Center Contracting Services, with invoicing likely conducted through WAWF. No specific packaging, labeling, or bar-coding requirements are defined, and no COR, COTR, or PCO details are currently assigned.
Highway, Street, and Bridge Construction

POSTED

2 days ago

DEADLINE

in 15 days
View Details
NAICS: 237990
New
Federal
Y--KNRI 257081¿ Knife River Indian Village National HThe contract pertains to the Elbee Bend Bank Stabilization project at the Knife River Indian Villages National Historic Site, requiring comprehensive riverbank stabilization, earthwork, excavation support, site restoration, and environmental mitigation. The scope includes clearing and grubbing, earth excavation and fill, riprap installation, topsoil application, seeding, stormwater permit compliance, and adherence to strict archaeological and historic preservation protocols. All work must comply with detailed technical specifications outlined in over 500 pages of attachments, including geological investigations, geotechnical recommendations, permit conditions, and wage determinations. The project is governed by strict delivery and handling requirements, mandating manufacturer-original packaging, labeling for handling and installation, and sustainable material standards such as minimum 45% post-consumer recycled content in paperboard and minimal, recyclable packaging per ASTM D5834. Performance is capped at 365 days from notice to proceed, with a target completion date of June 12, 2026, and includes provisions for liquidated damages, suspension of work, and time extensions as prescribed by FAR clauses. The solicitation, issued under number 140P2026R0086 by the Department of the Interior's DSC Contracting Services Division, is a negotiated RFP requiring submission of two electronic volumes—technical and business/price—via email by 5:00 PM local time on August 6, 2026. Proposals are evaluated using the Best Value Continuum Tradeoff Process, with five equally weighted non-price factors: Technical Approach and Schedule, Project Experience, Key Personnel Experience, Management Approach, and Past Performance, each carrying equal importance to Price, which is assessed for fairness, reasonableness, and potential imbalances. Small business participation is a distinct evaluation factor, with maximum credit given to small business offerors. The contract includes five CLINs: three base items—Mobilization/Demobilization, River Embankment Stabilization, and Site Restoration—and two bid alternates for Topsoil/Erosion Control and Temporary Access Road/River Crossing. Contractors must comply with SAM registration, UEI validation, and specific representations, and are required to assign designated key personnel with no substitutions allowed for the first 30 days of performance. Payment is processed exclusively through the IPP system, requiring draft invoices seven days in advance, signed COR approval or email confirmation, and submission of detailed supporting documentation including payment certifications, schedules, and a DI
Other Heavy and Civil Engineering Construction

POSTED

3 days ago

DEADLINE

in 25 days
View Details
NAICS: 237310
New
Federal
Y--HAFE 242454, Pavement Preservation Project The National Park Service, through the Department of the Interior’s Denver Service Center, is conducting market research for a pavement preservation project at Harpers Ferry National Historical Park in West Virginia, under solicitation number HAFE 242454. This is a Sources Sought Notice, not a solicitation for proposals, and no formal bids are being accepted at this time. The agency seeks input from small businesses capable of performing comprehensive roadway and bridge preservation services, including asphalt pavement preservation activities such as street sweeping, crack sealing, chip sealing, surface sealing, and deep patching, along with pavement marking installation and removal, drainage improvements, earthwork, traffic control, and tree protection. The anticipated project scope includes mobilization and quality control measures, with performance constrained to minimize visitor impact by limiting work to one lane closures and operating between 9:00 a.m. and 3:30 p.m., subject to seasonal closures. The project is estimated to have a value between $1 million and $5 million, with a proposed period of performance of 140 calendar days, accommodating weather-related delays. The acquisition is structured as a Total Small Business Set-Aside under NAICS code 237310, with a small business size standard of $45 million in annual revenue. Small businesses interested in being considered for future procurement must submit company identification details including name, UEI number, address, point of contact, phone, and email, along with a statement affirming their size status under NAICS 237310 and their bonding capacity—though formal bonding letters are not required at this stage. Respondents must also provide evidence of past performance on projects of similar size, scope, and complexity, and may optionally submit marketing materials such as capability statements. All responses are due by May 8, 2026, at 9:00 a.m. Mountain Time, submitted via email to Contracting Officer Rachel Dyer. The NPS plans to issue a formal Request for Proposals in late summer or fall of 2026, at which time performance and payment bonds will be mandatory, and specific evaluation criteria, inspection protocols, and contract administration details will be formalized. The work will occur entirely within the park’s West Virginia facility, requiring strict adherence to environmental protections and site preservation measures to ensure undisturbed surroundings throughout construction.
Highway, Street, and Bridge Construction

POSTED

3 days ago

DEADLINE

in 5 days
View Details
NAICS: 237310
New
Federal
Y--DEWA 310424 - Safety and Pavement Improvements to The contract pertains to safety and pavement improvements along Route 209 and McDade Trail within the Delaware Water Gap National Recreation Area, identified by PMIS numbers 310424, 325752, and 324741, with an estimated value exceeding $10 million and a performance period of 544 calendar days following the notice to proceed. The scope encompasses pavement preservation, slope stabilization using percussion-driven earth anchors, culvert repairs, guardrail replacement with Natina-coated materials, boardwalk construction featuring steel H-piles and concrete structures, erosion and sedimentation control, stormwater management via HDPE piping and regenerative conveyance systems, and installation of wayfinding signage not compliant with MUTCD standards. The project requires strict adherence to construction standards across multiple divisions including earthwork, concrete, transportation, utilities, and pollution control, with all work subject to visual inspection and testing per AASHTO, ASTM, or designated agency procedures, and results must be reported to the Contracting Officer within 24 hours of sampling. The solicitation is structured as a negotiated Request for Proposal under FAR Part 15, utilizing the Best Value Continuum Tradeoff Process, where non-price factors—project experience, technical approach, key personnel, and other criteria—are significantly more important than price, and the government may select a higher-priced proposal based on superior technical merit. All proposals must be submitted via email to specified NPS addresses with strict formatting rules, including separate technical and business volumes with specific naming conventions and file size limits not exceeding 38 MB per attachment or 100 MB per email. Compliance with SAM registration, UEI, and small business representation requirements is mandatory, with the procurement designated as a Small Business Set-Aside. Key personnel including a Project Manager, Safety Manager, Environmental Specialist, and others must be assigned with restrictions on substitutions during the first 30 days of performance. The contractor is required to use the Invoice Processing Platform (IPP) for payment submissions, following a two-step process requiring a draft package sent to the COR and CMR at least seven days in advance, with final invoice upload contingent upon a signed cover letter, or alternatively upon confirmation of the draft email if the letter is not received within the timeframe. Materials must be delivered undamaged in original manufacturer packaging with full labeling, including lot numbers, expiration dates, and safety information for pavement marking products, and must utilize biodegradable or recyclable packaging to the greatest extent possible. The
Highway, Street, and Bridge Construction

POSTED

4 days ago

DEADLINE

in 2 days
View Details
NAICS: 237110
New
Federal
Y--GRCA 318719_Temporary WWTP at North RimThe U.S. Department of the Interior, through its Denver Service Center Contracting Services Division, is preparing to procure the installation of a temporary wastewater treatment plant at the North Rim of Grand Canyon National Park under solicitation number 140P2026R0075. This project, identified as GRCA 318719, is designed to provide interim wastewater treatment capacity for campgrounds and visitor facilities while the permanent system undergoes upgrades. The work is to be performed at the North Rim, Arizona, a remote, high-elevation location with seasonal access limited to May through October and restricted road and staging areas. The facility must meet effluent standards set by the Arizona Department of Environmental Quality and will be constructed without requiring helicopter transport of materials or equipment. The estimated contract value exceeds $10 million, with a projected performance period of 420 calendar days following notice to proceed. The requirement is currently unfunded but has a high expectation of future funding availability. This procurement is structured as a total small business set aside under NAICS code 237110, which carries a size standard of $45 million in annual revenue, with the government actively seeking to maximize participation by small businesses, veteran-owned small businesses, small disadvantaged businesses, and women-owned small businesses. Prospective offerors must hold an active registration in the System for Award Management and possess a DUNS number to be eligible. The solicitation is scheduled to be issued in June 2026, with proposals due by July 29, 2026. While the pre-solicitation notice outlines the overall scope, performance requirements, and set-aside status, detailed specifications, drawings, evaluation criteria, contract clauses, and submission instructions will be provided in the official solicitation documents, which have not yet been released. All award-related information and contract administration details remain pending the formal release of the solicitation.
Water and Sewer Line and Related Structures Construction

POSTED

4 days ago

DEADLINE

in 3 days
View Details
NAICS: 237310
New
Federal
SC Multi Parks (CONG, COWP, KIMO, NISI) - PavementThe Department of the Interior, through its DSC Contracting Services Division, is conducting market research for a pavement preservation project encompassing four national park sites in South Carolina: Congeree National Park, Cowpens National Battlefield, Kings Mountain National Military Park, and Ninety Six National Historic Site. This presolicitation action, identified by solicitation number 140P2026R0054 and classified under NAICS code 237310, aims to gather industry input to determine the feasibility of a potential small business or socio-economic set-aside and to inform the structure of a future competitive Request for Proposals expected to be issued in fall 2026. The project will involve pavement preservation activities across 11.48 roadway miles and 0.71 parking miles, with the goal of extending pavement life and deferring more costly rehabilitation. The anticipated contract, if solicited, will be awarded as a Firm-Fixed-Price (FFP) with an estimated performance period of 132 calendar days following the Notice to Proceed, inclusive of weather-related delays. Critical performance constraints require that all parks remain fully operational during construction, with particular emphasis on maintaining public access to roads and parking areas during the week of July 4th. Construction at Kings Mountain National Military Park must conclude before October 1, while no work is permitted at Congeree National Park during the Synchronized Firefly Festival (mid-May to early-June) or between October 15 and 18. Winter construction may be necessary, and staging areas are limited, requiring approval from the Contracting Officer’s Representative. Bonding and insurance requirements are anticipated to include bid, performance, and payment bonds. Respondents are asked to provide company details including UEI, contact information, and socio-economic certifications such as HUBZone, WOSB, SDVOSB, or other veteran- or Native American-owned business status to assist the government in determining appropriate set-aside options. No technical specifications, drawings, or formal proposal packages are available at this stage, as this is strictly a market research tool with no proposals being accepted.
Highway, Street, and Bridge Construction

POSTED

5 days ago

DEADLINE

in 25 days
View Details