Monica Albert is a Compliance/Procurement Analyst. Monica is associated with 22 contracts. Activity spans Commercial and Institutional Building Construction, Flooring Contractors, and Building Inspection Services.
Person Profile
Contracting officer information and contact details
Solicitation SHARP IFB-2026-089-PS is a private, non-governmental request for bids for the complete fire damage rehabilitation of a single-story residential triplex located at 6141, 6143, and 6145 Terrell Drive in Citrus Heights, California. The project scope includes selective demolition, structural repairs, complete replacement of building systems, interior and exterior finishes, and site work, including restorative landscaping. All work must be performed within the existing building footprint to ensure code compliance and meet California Building Code standards. The contract is a lump-sum fixed price agreement with a performance period of 270 calendar days.
Eligible bidders must be licensed Class B General Building Contractors and are required to attend at least one mandatory pre-bid meeting. Bids are due by November 10, 2026, and must include a contractors qualification statement and a pricing proposal. For bids exceeding 300,000 dollars, a 5 percent bid bond is required, and the successful awardee must furnish performance and payment bonds for 100 percent of the contract price within ten calendar days of the notice of award. The project is not subject to prevailing wages. Liquidated damages for delays are set at 100 dollars per unit per calendar day.
Solicitation SHARP IFB-2026-089-PS, issued by The Sharp Investment LLC, seeks competitive lump-sum bids for the complete fire damage rehabilitation of a single-story triplex located at 6141, 6143, and 6145 Terrell Drive in Citrus Heights, California. The comprehensive scope of work includes selective demolition, structural repairs, and the full replacement of building systems, including electrical wiring, HVAC, plumbing, and the installation of a new residential fire sprinkler system and fire-rated wall assemblies to meet California Building Code standards. Exterior requirements involve replacing roof trusses, framing, roofing, and installing energy-efficient windows and doors, while interior work covers all finishes from wallboard and painting to cabinetry and flooring. The project also includes hardscape repairs and restorative landscaping, with the property remaining vacant during the 270-calendar day performance period.
Bids must be submitted by 2:00 pm on November 10, 2026. Required submission documents include a pricing proposal, a Contractors Qualification Statement detailing key personnel and similar project experience, and a bid bond equal to 5 percent of the bid price for projects exceeding 300,000 dollars. The successful bidder must provide performance and payment bonds for 100 percent of the contract price within ten calendar days of the award. Award decisions will be based on the bidder's experience, capacity, and past performance with SHRA. Notably, this is a private non-governmental solicitation and is not subject to prevailing wages. The contract includes liquidated damages of 100 dollars per unit for each calendar day of delay.
SHARP LLC is soliciting lump sum bids for the demolition, preparation, and installation of new Luxury Vinyl Plank (LVP) flooring and wall base at the Sierra Vista and Sutterview Apartments in Sacramento, California. The scope of work includes the removal of existing vinyl plank and carpet tiles, substrate leveling, and the installation of Mohawk Dealer Solutions III Caramel LVP and 6-inch brown cove base in first-floor common areas, offices, and corridors. All work must adhere to RFCI, ASTM F710, and CFI standards, utilizing low-VOC or zero-VOC materials and ADA-compliant transition strips. The project is strictly time-sensitive, with a mandatory completion and invoicing deadline of December 31, 2026.
Bidders must hold a current California State License Board C-15 Flooring and Floor Covering Contractor license or an acceptable Class B license. The agency may award contracts to a single contractor for both sites or separate contractors based on the lowest responsive and responsible bid per location. Required submissions include a bidders questionnaire, pricing proposals, and proof of insurance for general liability, workers compensation, and commercial auto. For bids exceeding 300,000 dollars, a 5 percent bid bond is required, and the successful awardee must provide 100 percent performance and payment bonds within ten calendar days of the notice of award. This project is not subject to prevailing wage requirements and follows the California Minimum Wage. Liquidated damages are set at 100 dollars per unit for each calendar day of delay.
SHARP LLC is soliciting bids for the removal and replacement of flooring at the Sierra Vista Apartments and Sutterview Apartments in Sacramento, California. The scope of work includes the demolition of existing vinyl plank and carpet tiles, substrate preparation in accordance with ASTM F710, and the installation of Mohawk Dealer Solutions III Luxury Vinyl Plank in Caramel with 6-inch brown cove base. Bidders must hold a C-15 Flooring and Floor Covering Contractor license and may submit proposals for either one or both properties. All work, including final site inspections and invoice submissions, must be strictly completed by December 31, 2026.
The project requires strict adherence to OSHA standards and the use of low-VOC or zero-VOC materials meeting RFCI FloorScore standards. While not subject to prevailing wage requirements, the California Minimum Wage applies to all labor. Financial security requirements include a bid bond of 5 percent for bids exceeding 300,000 dollars, and the successful awardee must provide performance and payment bonds for 100 percent of the contract price. Additionally, contractors must maintain comprehensive insurance coverage as specified by SHARP Investment LLC. Liquidated damages for delays are set at 100 dollars per unit per calendar day. Proposals must be submitted via the OpenGov portal by October 23, 2026.
SHARP LLC is soliciting competitive sealed bids under IFB-2026-071-PS for interior painting services at three residential mid-rise apartment properties in Sacramento: Washington Plaza (1318 E Street), Sierra Vista (2300 K Street), and Sutterview Apartments (2526 L Street). The scope of work includes complete surface preparation, minor patching, sanding, priming, and finish painting of corridors, hallways, common areas, community rooms, and office areas. All work must utilize best-grade Pittsburgh Paints (PPG) products, specifically low-VOC or zero-VOC paints to maintain indoor air quality. The project is not subject to prevailing wage requirements, with the California Minimum Wage being the applicable rate.
Qualified bidders must hold a current C-33 Painting and Decorating Contractor license from the California State License Board. Proposals must provide fixed, lump-sum pricing for two options at each location: paint only and paint and primer. The contract requires a performance and payment bond of 100 percent of the contract price, and a bid bond of 5 percent is required for bids exceeding 300,000 dollars. Additionally, contractors must meet comprehensive insurance requirements, including commercial general liability and workers compensation. The period of performance is 120 calendar days from the effective date, with liquidated damages set at 100 dollars per unit for each calendar day of delay. Bids are due by September 2026, with the final award based on the lowest responsive and responsible bidder.
The Auburn Falls RAD Project is being issued by the Sacramento Housing Authority Repositioning Program (SHARP), Inc., a separate nonprofit entity unaffiliated with the Sacramento Housing and Redevelopment Agency (SHRA). SHRA is explicitly not involved in or a party to this contract, and any mentions of SHRA in the system should be disregarded. This solicitation, numbered 2605-MAkp, was posted on May 27, 2026, with a response deadline of July 7, 2026. The project involves state and local government entities in California, with the office and primary place of performance located in Sacramento, CA.
Key contacts for this solicitation include Ahmad Shoaib, Program Manager, and Monica Albert, Compliance/Procurement Analyst, both reachable via email and phone as listed. The contract falls under the category of a solicitation, but no specific set-aside designation or NAICS code is provided. Interested parties can find further details and submit responses through the procurement portal link provided. This project underscores SHARP’s independent role in managing housing-related initiatives distinct from SHRA’s direct oversight.
The Sacramento Housing and Redevelopment Authority (SHRA) is seeking a comprehensive, portfolio-wide assessment of the HVAC systems across its extensive public housing inventory of over 2,000 units throughout Sacramento. This diverse housing stock includes single-family homes, duplexes, townhomes, and apartment buildings, many of which are legacy properties with limited historical mechanical documentation. The selected consultant will be tasked with documenting the current condition of HVAC equipment, identifying systems that require repair, replacement, or upgrades, and developing a detailed 10-year capital investment roadmap. Additionally, the assessment aims to prepare SHRA for engaging HVAC vendors in ongoing preventive maintenance services, ensuring systems function safely, efficiently, and reliably while complying with all applicable federal, state, and local regulations. Where historical records are unavailable, the consultant must conduct independent evaluations aligned with industry standards.
The contract, titled "HVAC Pilot Property Assessments, Residential," is being solicited by the Procurement Services Division of California, with a posted date of March 12, 2026, and a response deadline of April 23, 2026. The agreement will be governed under the latest SHRA standard contract terms as of September 2025 and includes provisions to ensure compliance with Section 3 of the Housing and Urban Development Act of 1968, promoting labor and business participation from eligible individuals and firms. The compliance package mandates detailed reporting, benchmarks for labor hours worked by Section 3 workers, and required contract inclusions, fostering social equity considerations in contractor engagement. The key contacts for this solicitation are the Assistant Director of Housing - Property Management, Cecette Hawkins, and Compliance/Procurement Analyst, Monica Albert.
The Sacramento Housing and Redevelopment Agency is seeking to establish a qualified list of law firms and hearing officers to provide legal services across various designated service areas. This list will include firms with specialized expertise in litigation and transactional matters, which will be utilized on an as-needed basis over a five-year period starting January 1, 2026, and concluding on December 31, 2030. The Agency will assign cases based on the firms' areas of specialty, experience, and cost considerations, although it retains the flexibility to contract with other firms outside the list if necessary. For certain specialty areas with limited caseloads or cost-efficiency considerations, only one law firm may be included on the list, while other areas may have multiple firms.
The solicitation, titled "Legal Services," is posted under number 2524-MA and is open for responses until October 7, 2025. The contract size ranges from $500,000 to $5,000,000, and the services are to be performed within California. Interested firms or hearing officers can contact Monica Albert via email or phone for further details. The procurement process is managed through an online portal, providing additional information and updates related to the solicitation.
The Sacramento Housing Authority Repositioning Program (SHARP) is seeking a qualified consultant to conduct RAD Physical Condition Assessments (RPCA) for public housing properties undergoing conversion through the HUD Rental Assistance Demonstration (RAD) Program. The scope includes preparing PCA reports that compare traditional and green building requirements, performing energy audits, and establishing utility consumption baseline reports. The selected contractor must be registered with HUD and possess extensive experience with HUD’s Physical Needs Assessment processes, including familiarity with e-tool requirements, to ensure accurate and compliant assessments.
The contract, valued between $500,000 and $2,000,000, is open to qualified firms with expertise in physical condition evaluations and energy analysis within California. The project was posted on August 18, 2025, with a response deadline of September 8, 2025. The primary point of contact is Monica Albert, reachable via email or phone, and interested parties can find additional details through the procurement portal. The program aims to support the successful conversion and modernization of public housing assets by leveraging comprehensive assessments to inform rehabilitation and green building strategies.
The Sacramento Housing and Redevelopment Agency (SHRA) is seeking proposals from qualified firms to provide professional accounting services related to the management of properties under the Sacramento Housing Authority Repositioning Program (SHARP). The scope of services includes bookkeeping, accounting, and financial reporting to support SHARP-controlled properties. The contract aims to establish a partnership with a single firm capable of delivering these financial services efficiently and accurately, with the contract value estimated between $50,000 and $200,000.
The solicitation, titled "SHARP Accounting Services," was posted on August 15, 2025, with a deadline for responses set for September 25, 2025. The project is managed by the Procurement Services Division of California, and interested firms can contact Monica Albert via email or phone for further information. The contract falls under the NAICS code 541211, indicating a focus on accounting, bookkeeping, and auditing services, and is open to firms capable of fulfilling the outlined requirements within the specified budget range. More details about the project and submission procedures are available through the provided online portal.
