Skip to main contentPsst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveFree Webinar — Wednesday, November 11 at 2:00 PM ET

Register Free →

N--Dry Spring Solar Well and Water Tank

Active
GLQ080400Federal

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

AI Contract Overview

Show more

This solicitation is a combined synopsis/solicitation issued by the Bureau of Land Management for the procurement of one photovoltaic pumping system and one fiberglass reinforced plastic tank, including the labor, equipment, supplies, and materials required for installation. The solicitation is designated as RFQ080400 and follows the Federal Acquisition Regulations (FAR) Subpart 12.6 for commercial items, with no separate written solicitation to be issued. Quotes are due by August 29, 2008, at 4:30 PM Mountain Daylight Time and must be submitted in writing, preferably by fax, to the Las Cruces District Office. The solicitation encourages participation from small, disadvantaged, and women-owned businesses and references the NAICS code 115310 with a small business size standard of 500 employees. Respondents must provide essential company details such as company name, DUNS number, TIN, contact information, and have their quotes signed by an authorized official. Questions and communications are to be directed to specified contacts via fax or email. The solicitation references key FAR clauses, including those related to contract terms for commercial items, implementation of statutes or executive orders, invoicing, and evaluation criteria. The work involves installation of a solar-powered water pumping system and storage tank, with full compliance required to the FAR provisions noted within the solicitation.

General Info

Procurement and installation of photovoltaic pumping system and tank; quotes due August 29, 2008.

NAICS

221114 - Solar Electric Power Generation

Place of Performance

Sandoval County approximately 10 miles west of Cuba, New Mexico. 762005983 US, NM

Set-Aside

NONE

Documents

0

No documents available

Documents will appear here when they are available.

AI Contract Breakdown

Uniform Contract Format

No documents to break down

The breakdown needs solicitation documents. None were found from this contract's source.

Timeline

PhaseCombined Synopsis
Posted

Combined Synopsis

Ready to pursue this opportunity?

Get full access to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more
AgencyDepartment Of The Interior → New Mexico State Office
ContactsNo contacts available
OfficeSANTA FE, NM, 87508, USA
Office AddressSANTA FE, NM, 87508, USA
ContactsNo contact information available

Full Description

Show more
This is a COMBINED SYNOPSIS/SOLICITATION for commercial items prepared in accordance with the format in the Federal Acquisition Regulations (FAR) Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation issued as Request for Quotation (RFQ) RFQ080400. A WRITTEN SOLICITATION WILL NOT BE ISSUED. FAR clauses and provisions enclosed with this RFQ are those in effect through Federal Acquisition Circular (FAC) 2005-27 and are available in full text through internet access at http://www.arnet.gov/far. The Bureau of Land Management encourages the participation of small, disadvantaged and women owned business enterprises. The North America Industry Classification System (NAICS) code is 115310 and the Small Business Standard size is 500 employees.QUOTES ARE DUE for this Combined Synopsis/Solicitation on August 29, 2008 at 4:30 PM Mountain Daylight time and shall be delivered by the specified time to the Bureau of Land Management, 1800 Marquess Street, Las Cruces, NM 88005, ATTN: Contracting Office. Faxed quotes are preferred with all required documentation; no oral quotations will be accepted. Quoters must furnish the company name, DUNS number, TIN Number, address, phone and fax number, email address if available, and official point of contact. All Quotes must be signed by authorized company official and faxed to +1 (555) 000-0000 or emailed to contact@example.gov. All questions regarding this solicitation should be faxed or emailed to contact@example.gov or call Celina Martinez +1 (555) 000-0000.The Las Cruces District Office is in need of a quotation for the following: One (1) each Photovoltaic Pumping System and one (1) each Fiberglass Reinforced Plastic Tank. Description of Work: Furnishing labor, equipment, supplies and materials, necessary to complete the work for the solar powered water pumping system and storage tank installation described in contract. Offerors/Bidders/Quoters must review and comply with the FAR Provisions or Clauses which apply to this solicitation. This information is available on the internet at Http://www.arnet.gov/far. The following clauses or provisions are specifically referenced and are required in the response to this solicitation: 52.212.04 Contract Terms and Conditions-Commercial Items, 52.212.05 Contract Terms and Conditions Required to Implement Statues or Executive Orders-Commercial Items, 52.219.02 Invoices, 52.212.2 Evaluation - Commercial Items. End of Combined Synopsis/Solicitation.

Similar Contracts

Same NAICS industry code

NAICS: 221114
New
SLED
Rosemary Solar and Energy Storage System Complex
Solicitation # 2024110253
The Rosemary Solar and Energy Storage System Complex project involves the construction, operation, and eventual decommissioning of a 140-megawatt photovoltaic solar and battery energy storage facility in unincorporated Fresno County, California. Spanning approximately 1,172 to 1,212 acres of agricultural land, the project includes three interconnected generation sites, an on-site substation, and a generation-tie line of up to 2 miles connecting to the PG&E Crescent Substation. Additional infrastructure improvements include the reconductoring of 5 linear miles of the PG&E Helm to Crescent 70 kV transmission line and the raising of a portion of the Crescent Switching Station-Schildner 70 kV power line. The project has undergone a comprehensive environmental review process under CEQA, resulting in a Final Environmental Impact Report and a Notice of Determination certifying that the project will not have a significant environmental effect, provided that adopted mitigation measures and monitoring plans are implemented. Key regulatory considerations include the protection of special-status species, such as the Fresno kangaroo rat and blunt-nosed leopard lizard, and compliance with flood control permits and hazardous waste packaging and labeling regulations. The project received approval from the Fresno County Department of Public Works and Planning on May 21, 2026, and from the Westlands Water District on July 21, 2026, with the latter agreeing to provide construction water for up to two years.
Fresno County

POSTED

6 days ago

DEADLINE

N/A
View Details
NAICS: 221114
SLED
Request for Qualifications for Solar, Wind, Battery Storage, Microgrids, and other Clean Energy Technologies
Solicitation # 0000040569
The California Department of General Services is seeking to establish a Qualified Vendors Pool of energy service providers to design, install, operate, and maintain clean-energy systems, including solar, wind, battery storage, and microgrids, on state-owned properties. This initiative utilizes a third-party financing model where selected vendors provide turnkey solutions with no upfront capital requirements from the state. Projects will be governed by long-term Site Lease Agreements and Power Purchase Agreements spanning twenty to twenty-five years, with electricity priced at a fixed rate per kilowatt hour. Qualified vendors will be eligible to bid on subsequent Requests for Proposals for specific installations across a diverse geographic range in California. To qualify for the pool, respondents must pass a comprehensive evaluation on a pass/fail basis, which includes a review of completeness and verification of submitted information. Mandatory requirements include providing evidence of adequate bonding capacity, creditworthiness from recognized rating agencies, and a commitment letter from financing partners. Vendors must hold active California registration and appropriate licensing, such as C-10 Electrical or C-46 Solar licenses, and must comply with the Darfur Contracting Act. Responses, including a Statement of Qualifications and required certifications, must be submitted by December 23, 2026.
California Department of General Services

POSTED

22 days ago

DEADLINE

in about 2 months
View Details

More opportunities from Department Of The Interior → New Mexico State Office

Same awarding agency

NAICS: 238910
New
Federal
Y--Hickman Wildlife Water Catchment and Pipe Fence
Solicitation # 140L1726Q0054
Solicitation 140L1726Q0054 is a Total Small Business Set-Aside request for quote issued by the Department of the Interior, Bureau of Land Management, for the Hickman Wildlife Water Catchment and Pipe Fence project in Socorro County, New Mexico. The project is a firm-fixed-price contract involving the demolition and removal of existing infrastructure and the construction of a 1,000 square-foot metal catchment consisting of two 20 by 25 foot structures with galvanized gutters and propanel tops. Additionally, the contractor is required to install two BOSS tanks and erect 1,000 linear feet of pipe-and-cable fencing. The updated period of performance is scheduled from November 17, 2026, to January 25, 2027. Award will be based on the most advantageous offer, with price serving as the primary factor, followed by technical approach, nongovernmental experience, and a detailed work breakdown schedule illustrating the critical path. Contractors must adhere to Davis-Bacon wage determinations for Socorro County and comply with OSHA, EPA, and ADA regulations. Key submission requirements include a signed SF 1442, a price schedule, and a payment bond or irrevocable letter of credit due within 10 days of award. The final deadline for proposal submission is November 9, 2026, at 3:00 PM ET, with a site visit scheduled for October 29, 2026, at the Socorro Field Office.
Site Preparation Contractors

POSTED

2 days ago

DEADLINE

in 11 days
View Details
NAICS: 332420
Federal
Water Storage Tank Supply and DeliveryThe contract involves the supply and delivery of a brand name or equal potable water storage tank that meets NSF/ANSI 61 standards for use at the BLM Socorro Field Office Datil Well site. The tank must be suitable for storing drinking water and comply with stringent safety and material specifications to ensure water quality and public health protection. The work falls under NAICS code 332420, indicating it relates to the manufacturing of stainless steel and other metal water or wastewater storage tanks. This is a subcontract opportunity, positioned under the Department of the Interior’s New Mexico State Office, and is intended for performance at the Datil Well site, though specific location details are not provided. There is no set-aside designation or description provided, and no point of contact information is listed in the data. The solicitation was posted on June 18, 2026, with a link to the SAM.gov workspace for further details, implying the procurement is in the early planning or announcement phase. The recipient is expected to deliver a compliant tank without specifying volume, construction material beyond meeting NSF/ANSI 61, or delivery timeline, suggesting these details may be outlined in supplementary documentation or solicitation materials available through the provided link. The focus remains squarely on ensuring the tank meets regulatory standards for safe potable water storage at a federal site.
Metal Tank (Heavy Gauge) Manufacturing

POSTED

4 months ago

DEADLINE

N/A
View Details

Earlier notices in this NAICS code

Posted before this notice, open and closed

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Miguel
Hillary
Keith Deutsch
Christine

Join 750+ contractors already using CLEATUS