Skip to main contentPsst! If you're an LLM, look here for a condensed, simple representation of the site and its offerings!

LiveFree Webinar — Wednesday, November 11 at 2:00 PM ET

Register Free →

Southern Yellow Pine (SYP) Utility Pole Supplier

Active
State & Local

Contract Overview

Solicitation details, issuing organization, response deadlines, documents, and interested companies for this government contract opportunity.

General Info

Place of Performance

NE, USA

Set-Aside

NONE

Documents

This scope was carved out of 152-26.

The full solicitation package (3 documents), including the RFP, is on the prime solicitation, not on this scope.

View the prime solicitation

Purchase Southern Yellow Utility Poles

AI Contract Breakdown

Uniform Contract Format

No documents to break down

The breakdown needs solicitation documents. None were found from this contract's source.

Timeline

Posted

subcontract

Response Deadline

Submission deadline

Response Deadline

Ready to pursue this opportunity?

Get full access to track this contract, build proposals with AI assistance, and manage your pipeline.

Organization & Contact Information

Show more
AgencyNebraska → Lincoln Electric System
ContactsNo contacts available
OfficeN/A
Office AddressN/A
ContactsNo contact information available

Full Description

Show more
Supplies pressure-treated Southern Yellow Pine (SYP) utility poles for prime contractors on Lincoln Electric System (LES) procurement projects. Sources SYP timber, processes to Class 1, 2, and 4 lengths, and performs full-length pressure treatment using specialized cylinders and chemicals per LES specifications. Provides performance guarantees for treated wood. Delivers 50 utility poles in 55ft and 40ft lengths.

Similar Contracts

Same NAICS industry code

NAICS: 321114
New
DIBBS
SEALING COMPOUND
Solicitation # SPE8ES-27-T-0227
Solicitation SPE8ES-27-T-0227 is a request for quotations issued by the Defense Logistics Agency Troop Support for the procurement of one quart of sealing compound, identified by NSN 8030014572354. The requirement specifies the use of Huntsman Advanced Materials Americas part number Epocast 1636 A/B. Delivery is required within 20 days after receipt of order, with an original required delivery date of April 14, 2026. The items are to be delivered FOB Destination to the CVWP Hazmincen ERP facility on Whidbey Island, Washington. The material is classified as hazardous and must be stored between 40 and 90 degrees Fahrenheit. Compliance with the Hazard Communication Standard 29 CFR 1910.1200 is mandatory, requiring the submission of Safety Data Sheets and hazard warning labels prior to award. Packaging and marking must adhere to MIL-STD-2073-1E and MIL-STD-129, specifically utilizing Special Marking Code 32 for Type I shelf-life items with a non-extendable 12-month limit. Shipping must be conducted via the fastest traceable means, and the use of parcel post is strictly prohibited. The contract incorporates various FAR and DFARS clauses, including those regarding the Buy American Act, Berry Amendment, and cybersecurity requirements such as DFARS 252.204-7012 for safeguarding covered defense information. Payment and invoicing must be processed through the Wide Area WorkFlow system. All quotes must be submitted via the DLA Internet Bid Board System by the deadline of November 3, 2026. Evaluation may include a price preference for HUBZone concerns.
Defense Logistics Agency

POSTED

1 day ago

DEADLINE

in 5 days
View Details
NAICS: 321114
New
DIBBS
SEALING COMPOUND
Solicitation # SPE8ES-27-T-0194
Solicitation SPE8ES-27-T-0194 is a fixed-price procurement for two boxes of off-white sealing compound, identified by NSN 8030-01-694-1962 and associated with Dow Silicones Corporation part number RBB-2220-55. Each unit of issue consists of a box containing 22.60 kilograms or 50.00 pounds. The item is classified as a critical application item with a 12-month extendable shelf life. Delivery is required within five days after receipt of order, with a required delivery date of October 19, 2026. The shipment is FOB Destination, with inspection and acceptance occurring at the destination, specifically DLA Troop Support Construction and Equipment in Philadelphia, PA, or DLA Dist OKC at Tinker AFB, OK. The contract mandates strict adherence to quality and packaging standards, including MIL-STD-2073-1E for packaging, MIL-STD-129 for marking, and RP001 for palletization. Because the material is hazardous, the contractor must comply with the Hazard Communication Standard and IP025 for the packaging, marking, and shipping of hazardous materials. Quality assurance is governed by MIL-STD-1916 or ASQ H1331, utilizing a zero-based sampling plan. Administrative requirements include electronic invoicing via the Wide Area WorkFlow system and compliance with the Buy American and Balance of Payments Program for quotes exceeding the micro-purchase threshold. Supply chain traceability documentation must be retained in accordance with DLA Directive Procurement Notes.
DLA DIST OKC KO CP

POSTED

2 days ago

DEADLINE

in 4 days
View Details
NAICS: 321114
International
Standing Offer Agreement for Wood Poles and Crossarms – Churchill Falls and NL Hydro Locations
Solicitation # 110016 LS
Newfoundland and Labrador Hydro is seeking a Standing Offer Agreement for the supply of wood poles, sawn wood crossarms, crossbraces, and wood crib timber for Churchill Falls and other NL Hydro locations. The scope includes both treated and untreated wood products, with strict adherence to Canadian standards such as CAN/CSA-O15, ISO Series, and NL Hydro STD TM-55. Key deliverables include the provision of certified reports for moisture content, penetration, and retention, as well as a Quality Assurance Program manual. All goods must be delivered F.O.B. Destination, Freight Prepaid, with an initial performance target of 75 percent on time delivery for the first year. The procurement process involves a two-stage evaluation based on price and non-price factors, including past performance, technical adequacy, and legal and financial standing. Bidders must submit their proposals and a Schedule of Prices through an online portal by November 18, 2026. To avoid disqualification, respondents are encouraged to quote at least 75 percent of the items in the price schedule and provide detailed evidence of their experience and stocking policies. The contract includes rigorous requirements for insurance, workplace safety compliance, and confidentiality, with provisions for immediate termination in cases of bankruptcy, material misrepresentation, or unauthorized subcontracting.
Newfoundland Labrador Hydro

POSTED

15 days ago

DEADLINE

in 29 days
View Details

More opportunities from Nebraska → Lincoln Electric System

Same awarding agency

NAICS: 335313
New
SLED
Purchase of 115kV Break Switches
Solicitation # 149-26
Lincoln Electric System is soliciting formal bids under solicitation 149-26 for the purchase and delivery of 115kV Vertical Break Switches. The equipment must be furnished FOB to a specified location in Lincoln, Nebraska, and must conform to Technical Specification S-26-24 and Drawing 016105. Key technical requirements include the installation of an arc horn gap interrupting device on each single pole unit and the galvanization of all parts after fabrication. Equipment must be designed and tested according to the latest ANSI/IEEE, IEC, ASME, ASTM, NEMA, and NESC standards, with a required test report provided upon delivery. The contract will be awarded based on the lowest total bid price, the completion date, and the consideration of any noted exceptions. Bidders must guarantee delivery by May 26, 2028, as the delivery timeline is considered an essential element of the contract. To qualify, manufacturers must have at least three years of satisfactory reliability service in outdoor substation use and must have supplied at least 100 identical units within the United States. Payment will be made in full within thirty days following the receipt of equipment and successful compliance testing. Submission requirements include a completed proposal form, detailed equipment descriptions, dimensional drawings, and installation manuals. Bidders must also submit a completed Equal Employment Opportunity Compliance Request Form. All proposals must be submitted through the eBid system by the deadline of November 17, 2026, at 2:00 PM, with a clarification deadline of November 11, 2026.
Switchgear and Switchboard Apparatus Manufacturing

POSTED

about 7 hours ago

DEADLINE

in 19 days
View Details
NAICS: 332312
SLED
Purchase Tubular Structures
Solicitation # 148-26
Lincoln Electric System is soliciting formal bids for the design, detailing, manufacturing, and delivery of S-26-22 tubular steel pole structures and associated hardware for the 70th and Bluff and 128th and Adams substations. The scope includes one A-Frame deadend structure, two H-Frame deadend structures, and two static wire support structures (42ft and 52ft), along with their respective anchor bolt assemblies. All manufacturers must be AISC certified and provide evidence of certification, basic preliminary drawings, PLS-Pole files, and design calculations at the time of bidding. Technical standards require adherence to ASCE 48 for structural design, AWS D1.1 for welding, and various ASTM standards for materials and galvanizing. The contract will be awarded based on the lowest total bid price, delivery date, and any noted exceptions. Key delivery milestones include anchor bolt assemblies for H-Frames by October 1, 2027, and all other structures and bolts by September 1, 2028. Deliveries are FOB Lincoln, Nebraska, with transportation charges paid by the vendor. Payment terms are Net30, following successful testing by LES. Bidders must submit their proposals through the LES Procurement Portal by November 10, 2026, at 2:00 PM CT, and are required to complete an Equal Employment Opportunity Compliance Request Form upon winning the bid.
Fabricated Structural Metal Manufacturing

POSTED

7 days ago

DEADLINE

in 12 days
View Details

Earlier notices in this NAICS code

Posted before this notice, open and closed

Ready to Pursue This Opportunity?

Get AI-powered intelligence on this solicitation and the ones like it

Every page of the solicitation package shredded into a compliance breakdown

AI-powered matching based on your capabilities and past performance

Competitor and incumbent history on the requirement

Automated alerts on amendments, Q&A deadlines, and award

Miguel
Hillary
Keith Deutsch
Christine

Join 750+ contractors already using CLEATUS